Seattle Washington Building Expert Directory

$24 Million Verdict Against Material Supplier Overturned Where Plaintiff Failed to Prove Supplier’s Negligence or Breach of Contract Caused an SB800 Violation

November 21, 2017 — Jon A. Turigliatto, Esq. & Chelsea L. Zwart, Esq. – Chapman Glucksman Dean Roeb & Barger Bulletin
Originally published by CDJ on March 16, 2017 Acqua Vista Homeowners Assoc. v. MWL Inc. (2017) 2017 WL 371379 COURT OF APPEAL EXTENDS GREYSTONE HOMES, INC. v. MIDTEC, INC., HOLDING THAT CIVIL CODE §936 CREATES A NEGLIGENCE STANDARD FOR CLAIMS AGAINST MATERIAL SUPPLIERS BROUGHT UNDER SB800. The Fourth District California Court of Appeal recently published its decision Acqua Vista Homeowners Assoc. v. MWI, Inc. (2017) 2017 WL 371379, holding that claims against a material supplier under SB800 (Civil Code §895 and §936) require proof that the SB800 violation was caused by the supplier's negligence or breach of contract. Civil Code §936 states in relevant part, that it applies "to general contractors, subcontractors, material suppliers, individual product manufacturers, and design professionals to the extent that the general contractors, subcontractors, material suppliers, individual product manufacturers, and design professionals caused, in whole or in part, a violation of a particular standard as the result of a negligent act or omission or a breach of contract .... [T]he negligence standard in this section does not apply to any general contractor, subcontractor, material supplier, individual product manufacturer, or design professional with respect to claims for which strict liability would apply." Reprinted courtesy of Jon A. Turigliatto, Esq., Chapman Glucksman Dean Roeb & Barger and Chelsea L. Zwart, Esq., Chapman Glucksman Dean Roeb & Barger Mr. Turigliatto may be contacted at jturigliatto@cgdrblaw.com Ms. Zwart may be contacted at czwart@cgdrblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

2023’s Bank Failures: What Contractors, Material Suppliers and Equipment Lessors Can Do to Protect Themselves

May 15, 2023 — Garret Murai - California Construction Law Blog
It has been a tumultuous year for the banking industry. Since the beginning of this year the industry has seen the collapse of Silicon Valley Bank and Signature Bank, the shotgun marriage between failing Credit Suisse and USB, and, most recently, the collapse of First Republic Bank this past week and its purchase by JP Morgan Chase. Indeed, according to the New York Times, these three bank failures cum bailouts alone were bigger than the 25 banks that collapsed during the financial crises of 2008 and some are concerned that it is just the beginning. This, of course, has impacted the stock market, with Forbes reporting that the banking industry lost more than $300 billion in market value as of the end of March. However, it also raises concerns regarding liquidity on construction projects. While the failing banks have either been bought out by other banks or shored up by the federal government, which, in the case of Silicon Valley Bank and Signature Bank, involved the Federal Deposit Insurance Corporation (FDIC), the Treasury Department and the Federal Reserve stepping into to protect depositors by guaranteeing deposits in excess of the current FDIC limit of $250,000, there continues to be concerns over access to cash. This can impact construction projects in several ways. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

In Hong Kong, You Can Find a Home Where the Buffalo Roam

September 17, 2014 — Shai Oster – Bloomberg
To city dwellers worried about mice and rats, spare a thought for Hong Kongers confronting half-ton feral beasts. A few miles from some of the most densely populated neighborhoods in the world, more than 1,000 cows and buffalo from abandoned farms roam the countryside. Development now is pushing them into harm’s way and onto roads. Hong Kong represents an extreme example of the task many communities face of balancing conservation and growth. Wolves sniff near the suburbs of Paris, bears roam Lake Tahoe and moose stumble across the roads of Halifax. There’s a new word to describe how undomesticated animals adapt to man-made environments: synurbanization. Read the court decision
Read the full story...
Reprinted courtesy of Shai Oster, Bloomberg
Shai Oster may be contacted at soster@bloomberg.net

Smart Cities Offer New Ideas for Connectivity

April 05, 2017 — Jennifer Seward - Engineering News-Record
Innovative, technology-driven communities are being designed and constructed for the next generation—and beyond. Although each of them is uniquely planned, experts say the central theme of connectivity is the key to turning concepts into reality. Read the court decision
Read the full story...
Reprinted courtesy of Jennifer Seward, ENR
ENR may be contacted at ENR.com@bnpmedia.com

Proving Impacts to Critical Path to Defeat Liquidated Damages Assessment

December 16, 2019 — David Adelstein - Florida Construction Legal Updates
When a contractor is staring down the barrel of an owner’s assessment of liquidated damages, the burden will fall on the contractor to establish that the delay was attributable to the owner and the owner’s agents. The contractor will want to do this not only to defeat the assessment of liquidated damages, but because it will want to establish that the delay caused it to incur extended field overhead (general conditions) for which the owner is responsible. A contractor supports its burden by proving the impacts to its critical path. “In general, proving an allegation of government-caused delays without a means of showing the critical path is a steep prospect.” James Talcott Construction v. U.S., 2019 WL 1040383, *8 (Fed. Cl. 2019) (unreported opinion) (finding that because contractor did NOT present a critical path analysis it could not support its claim for delay caused by the government). Avoiding the assessment of liquidated damages means the contractor needs to support that it encountered excusable delay and it is/was entitled to an extension of time to complete the project. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Addressing the Defective Stucco Crisis

November 28, 2018 — Wally Zimolong - Supplemental Conditions
I received several emails regarding the expose by Caitlin McCabe and Erin Arvedlund in the Philadelphia Inquirer titled “Rotting Within.” The story outlines the epidemic of defective stucco and other “building envelope” issues in Southeastern Pennsylvania that is causing homes to literally rot from within. Having litigated several of these cases, they are frustrating for both the attorneys that handle them and the homeowners who must deal with the reality that their home is rotting away. The story points to the multiple (and all too common) causes for the epidemic: unskilled subcontractors, lack of oversight and care, and poor construction drawings. The is no quick solution to the crisis and litigation regarding these defects is sure to proliferate. However, there is one potential solution that the story does not cover and which could help alleviate some of the challenges homeowners face in recovering damages for their claims. The Pennsylvania Legislature must act to change the insurance laws in Pennsylvania to make defective construction covered by a developer’s, contractor’s, and subcontractor’s commercial general liability policy (“CGL”). Most homeowners and many attorneys incorrectly assume that defective construction is covered by insurance. This assumption makes sense. If someone operates a car in a negligent manner and hits your car and causes damage, the negligent driver’s insurance company with cover your loss. In reality, Pennsylvania courts follows a minority of states that holds that generally speaking defective workmanship is not a “covered occurrence” under an insurance policy. (There are several exceptions to this rule and thorough discussion is beyond this blog post and would probably bore you.) Read the court decision
Read the full story...
Reprinted courtesy of Wally Zimolong, Zimolong LLC
Mr. Zimolong may be contacted at wally@zimolonglaw.com

Trump Administration Issues Proposed 'Waters of the U.S.' Rule

December 19, 2018 — Pam Radtke Russell - Engineering News-Record
Construction contractors said a proposed revised definition of “Waters of the United States,” released by the Environmental Protection Agency and the Army Corps of Engineers on Dec. 11, would provide their firms with clarity about what types of permits they will need for their construction projects near various bodies of water. Read the court decision
Read the full story...
Reprinted courtesy of Pam Radtke Russell, ENR
Ms. Russell may be contacted at Russellp@bnpmedia.com

Fraud, the VCPA and Construction Contracts

November 26, 2014 — Christopher G. Hill – Construction Law Musings
I’ve discussed the economic loss rule here at Musings on several occasions. The economic loss rule basically states that where one party assumes a duty based in contract or agreement, the Virginia courts will not allow a claim for breach of that duty to go forward as anything but a contract claim. This doctrine makes fraud claims nearly, though not absolutely, impossible to maintain in a construction context. In a majority of instances, fraud and construction contracts are very much like oil and water, leaving parties to fight it out over the terms of a particular contract despite actions by one party or the other that non-lawyers would clearly see as fraud. However, a recent case decided by the Virginia Supreme Court gives at least some hope to those who are seemingly fooled into entering a contract that they would not other wise have entered into. In Philip Abi-Najm, et. al, v Concord Condominium, LLC, several condominium purchasers sued Concord under for breach of contract, breach of the Virginia Consumer Protection Act (VCPA) and for fraud in the inducement based upon flooring that Concord installed that was far from the quality stated in the purchase contract. Based upon these facts, the Court looked at two questions: 1. Did a statement in the contract between Concord and the condo buyers create a situation in which the merger doctrine barred the breach of contract claim, and 2. Did the economic loss rule bar the VCPA and fraud claims? Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, Law Office of Christopher G. Hill, PC
Mr. Hill may be contacted at chrisghill@constructionlawva.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES