Fairfield Connecticut Building Expert Directory

Client Alert: Catch Me If You Can – Giorgio Is No Gingerbread Man

November 26, 2014 — Steven M. Cvitanovic, Jesse M. Sullivan, & Colin T. Murphy - Haight Brown & Bonesteel LLP
In Giorgio v. Synergy Management Group, LLC (2014) Case No. B248752, a California Court of Appeal held in an opinion published on November 6, 2014, that the Los Angeles County trial court did not abuse its discretion in permitting service by publication on Defendant John Giorgio ("Giorgio") after numerous attempts to find his current address produced a single address in Los Angeles from which mailed service was returned. The Court ruled that publication in a Los Angeles newspaper was proper because Plaintiff had a reasonable belief that service by publication in that county was most likely to give actual notice to the party to be served.” In this intentional tort action, Synergy Management Group, LLC ("Synergy") alleged in its Complaint that Giorgio converted assets of Synergy's assignor by submitting false expense reports which resulted in the misappropriation of the assignor's assets. Synergy personally served Giorgio with the original Complaint at a North Carolina airport and Giorgio failed to respond. Synergy subsequently filed a First Amended Complaint and attempted service via an address in the Netherlands. Again, Giorgio did not respond. Synergy then filed a request for entry of default against Giorgio which was entered that day. Reprinted courtesy of Haight Brown & Bonesteel LLP attorneys Steven M. Cvitanovic, Jesse M. Sullivan and Colin T. Murphy Mr. Cvitanovic may be contacted at scvitanovic@hbblaw.com; Mr. Sullivan may be contacted at jsullivan@hbblaw.com; and Mr. Murphy may be contacted at cmurphy@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Hunton Insurance Partner Among Top 250 Women in Litigation

October 05, 2020 — Hunton Insurance Recovery Blog
Benchmark Litigation recently identified the Top 250 Women in Litigation. The list is based on an extensive research process, feedback from clients, and one-on-one interviews. Benchmark has identified the litigators who have participated “in some of the most impactful litigation matters in recent history” and have earned “hard-won respect of their peers and clients.” Lorelie S. Masters was included in the list for the seventh time. Reprinted courtesy of Hunton Andrews Kurth LLP Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Proving Impacts to Critical Path to Defeat Liquidated Damages Assessment

December 16, 2019 — David Adelstein - Florida Construction Legal Updates
When a contractor is staring down the barrel of an owner’s assessment of liquidated damages, the burden will fall on the contractor to establish that the delay was attributable to the owner and the owner’s agents. The contractor will want to do this not only to defeat the assessment of liquidated damages, but because it will want to establish that the delay caused it to incur extended field overhead (general conditions) for which the owner is responsible. A contractor supports its burden by proving the impacts to its critical path. “In general, proving an allegation of government-caused delays without a means of showing the critical path is a steep prospect.” James Talcott Construction v. U.S., 2019 WL 1040383, *8 (Fed. Cl. 2019) (unreported opinion) (finding that because contractor did NOT present a critical path analysis it could not support its claim for delay caused by the government). Avoiding the assessment of liquidated damages means the contractor needs to support that it encountered excusable delay and it is/was entitled to an extension of time to complete the project. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Recent Statutory Changes Cap Retainage on Applicable Construction Projects

March 11, 2024 — Patrick McKnight - The Dispute Resolver
Recent reforms to certain state retainage laws have reduced the lawful amount of withholding permitted on construction projects. In theory, retainage allows an owner to mitigate the risk of incomplete or defective work by withholding a certain portion of payment until the construction project is substantially complete. Recent statutory developments in Washington, New York, and Georgia represent significant changes in how much an owner may retain on applicable construction projects in those jurisdictions. The details of each state’s retainage laws vary in many important respects. Most states set caps at 5% or 10%, with important variations depending on the type of project and the amount of progress completed. Some states require retainage to be held in an escrow account, but most do not. Many federal construction projects allow up to 10% retainage, while other federal agencies do not require any retention. See 48 CFR § 52.232-5(e) - Payments Under Fixed-Price Construction Contracts. The ongoing motivation for retainage reform is typically framed in terms of reducing delays in getting payment to subcontractors who complete their scope of work on time and free from defects. Read the court decision
Read the full story...
Reprinted courtesy of Patrick McKnight, Fox Rothschild LLP
Mr. McKnight may be contacted at pmcknight@foxrothschild.com

Scientists found a way to make Cement Greener

October 01, 2014 — Beverley BevenFlorez-CDJ STAFF
According to Futurity, scientists say by “paying attention to concrete’s atomic structure…they could make it better and more environmentally friendly.” Cement currently is “the third-largest source of carbon dioxide released to the atmosphere.” Materials scientist Rouzbeh Shahsavari stated that “[t]he heart of concrete is C-S-H—that’s calcium, silicate, and hydrate (water). There are impurities, but C-S-H is the key binder that holds everything together, so that’s what we focused on.” The team spent a year in research and “looked at defects in about 150 mixtures of C-S-H to see how the molecules lined up and how their regimentation or randomness affected the product’s strength and ductility.” Read the court decision
Read the full story...
Reprinted courtesy of

Former Hoboken, New Jersey Mayor Disbarred for Taking Bribes

September 17, 2014 — Beverley BevenFlorez-CDJ STAFF
The New Jersey Law Journal reported that Peter Cammarano III, a former Hoboken, New Jersey, mayor, was disbarred after admitting “four years ago that he took $25,000 in bribes from a federal informant in exchange for promising his help in getting approval for a high-rise.” Cammarano “was one of 44 public officials and rabbis arrested in July 2009 as part of a massive federal investigation, known as Operation Bid Rig, into public corruption and money laundering operations.” The Disciplinary review board had recommended a three year suspension, however, the New Jersey Supreme Court rejected that recommendation. “An elected official who sells his office—who offers favored treatment in exchange for money—betrays a solemn public trust,” Justice Barry Albin wrote for the court, as quoted by the New Jersey Law Journal. “This form of corruption is corrosive to our democracy and undermines public confidence in honest government, and its rippling pernicious effects are incalculable.” “I believe the Disciplinary Review Board’s decision was right,” Joseph Jr. Hayden, Cammarano’s attorney, told the New Jersey Law Journal. “There were sufficient mitigating factors to justify only a suspension.” Read the court decision
Read the full story...
Reprinted courtesy of

Contractors Must Register with the L&I Prior to Offering or Performing Work, or Risk Having their Breach of Contract Case Dismissed

March 27, 2023 — Jill Guingcangco - Ahlers Cressman & Sleight PLLC
The Washington State Legislature has an interest in protecting the public from “unreliable, fraudulent, financially irresponsible, or incompetent contractors” (RCW 18.27.140), which is why contractors are required to register with the Department of Labor and Industries (“L&I”) before advertising, offering to do work, or performing any work as a contractor. RCW 18.27.020. Accordingly, if a contractor brings an action for the collection of compensation or sues for breach of contract for work they performed, that individual is required to allege and prove that, at the time they performed the work, they were a registered contractor. RCW 18.27.080. In Dobson v. Archibald,1 Dobson worked as a longshoreman, but also simultaneously performed home repair work for pay during her off time. Dobson never registered as a contractor with L&I. Dobson acquired customers for her home repair work through a referral process. Dobson was referred to Archibald through a mutual friend who Dobson performed some home repair work for. Archibald subsequently hired Dobson to refinish the hardwood floors in Archibald’s home. Read the court decision
Read the full story...
Reprinted courtesy of Jill Guingcangco, Ahlers Cressman & Sleight PLLC
Ms. Guingcangco may be contacted at jill.guingcangco@acslawyers.com

Architect Sues over Bidding Procedure

November 13, 2013 — CDJ STAFF
The city of Louisville, Ohio is being sued by an architect who claims that city officials split projects into parts in order to circumvent state laws on public bidding. Rodney Meadows, the architect who filed the suit, also claims he is not motivated by any interest in working for the city. “I wouldn’t want to work with them,” he said. Nor is he seeking damages in the suit. The project at contention is Louisville’s renovations of an existing building for the Police Department. The city has spent $328,692 on the renovations, but state law says that projects costing more than $25,000 or $50,000 (depending on other matters) must be put out for public bidding. But city officials contend they haven’t broken the law. “A significant amount of work was done by our own people,” said E. Thomas Ault, the Louisville city manager. Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES