SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Standard For Evaluating Delay – Directly from An Armed Services Board Of Contract Appeal’s Opinion

October 04, 2021 — David Adelstein - Florida Construction Legal Updates
Sometimes, it is much better to hear it from the horse’s mouth. That is the case here. The Armed Services Board of Contract Appeal’s (ASBCA) opinion in Appeals of -GSC Construction, Inc., ASBCA No. 59402, 2020 WL 8148687 (ASBCA November 4, 2020) includes an informative discussion of a contractor’s burden when it encounters excusable delay and, of importance, the standard for evaluating delay. It’s a long discussion but one that parties in construction need to know, appreciate, and understand. EVERY WORD IN THIS DISCUSSION MATTERS. Construction projects get delayed and with a delay comes money because time is money. Many claims are predicated on delay. These can be an owner assessing liquidated damages due to a delayed job or a contractor seeking its costs for delay. Either way, the standard for evaluating delay and the burdens imposed on a party cannot be understated and, certainly, cannot be overlooked. For this reason, here is the discussion on evaluating delay directly from the horse’s mouth in the Appeal of-GSC Construction, Inc.:

The critical path is the longest path in the schedule on which any delay or disruption would cause a day-for-day delay to the project itself; those activities must be performed as they are scheduled and timely in order for the project to finish on time. Wilner v. United States, 23 Cl. Ct. 241, 245 (1991). In Yates-Desbuild Joint Venture, CBCA No. 3350 et al., 17-1 BCA ¶ 36,870, our sister board compiled an excellent and very helpful synopsis of the standards for evaluating delay claims, which I adopt nearly verbatim among the discussion that follows.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Walkability Increases Real Estate Values

June 18, 2014 — Beverley BevenFlorez-CDJ STAFF
CNBC reported that environmentally-conscious Millennials are looking for homes that are within walking or biking distance to stores and work. The “areas that offer so-called walkability should see more home buyers and renters than those that don't.” "Cities that want to thrive in our new economic and demographic realities will need to find ways to create and support more of these dynamic, productive walkable districts that are in high demand," Geoff Anderson, CEO of Smart Growth America, told CNBC. Anderson, “in conjunction with George Washington University School of Business, released a new report ranking the walkability of the nation's 30 largest metropolitan areas.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Construction Litigation Roundup: “A Less Than Valiant Effort”

June 21, 2024 — Daniel Lund III - Lexology
A Miller Act claimant in federal court in New Jersey in relation to a VA medical center project found itself on the wrong end of the law and was sent packing by the court. The claimant had supplied products for the project to general contractor Valiant Group, LLC, pursuant to a purchase order from the GC. The general contractor allegedly refused to pay the supplier, leading to the claim against the GC and its payment bond surety in the amount of $126,900. The supplier also sought recovery under the federal Prompt Payment Act, 31 U.S.C. §§ 3901-07. State law claims were asserted as well. Chipping away at the federal law claims – the claims forming the asserted basis for federal court jurisdiction for the case – the court first dispensed with the Prompt Payment Act claim. According to the court, allegations that the general contractor had “wrongfully and improperly withheld remuneration… despite [having] ‘received payment from the U.S. Department of Veterans Affairs’" – whether or not accurate – did not trigger the Act. The court wrote: “The Prompt Payment Act was enacted ‘to provide the federal government with an incentive to pay government contractors on time by requiring agencies to pay penalties . . . on certain overdue bills . . . [and] was later amended to include provisions applicable to subcontractors.’… Absent from the Act, however, are ‘any explicit provisions for subcontractor enforcement if the prime contractor fails to make timely payment.’… This is because the Act ‘merely requires that the prime contractor's contract with the subcontractor include the specified payment clause. [It] does not require the prime contractor to actually make payments to the subcontractor[.]’… The Act, therefore, does not ‘give subcontractors an additional cause of action for an alleged breach by a general contractor of a subcontract.’” Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

---

A Game of Texas Hold’em: How Texas Stopped Wage Increases for Salaried Exempt Employees Nationwide

December 03, 2024 — Matthew DeVries - Best Practices Construction Law
Construction contractors often have to deal with classification of employees, particularly those who work in the home office. Today’s guest post by Alexandra Shulman and Leah Lively addresses a recent court decision affecting the wage protection of employees under the the Fair Labor Standards Act (FLSA). On November 15, 2024, a federal court in Texas vacated a U.S. Department of Labor (DOL) rule (the “2024 Rule”) that increased the minimum salary threshold for employees classified as exempt from overtime and minimum wage protections under the FLSA. The Texas court’s decision nullifies the 2024 Rule nationwide, effective immediately. Read the court decision
Read the full story...
Reprinted courtesy of Matthew DeVries, Buchalter
Mr. DeVries may be contacted at mdevries@buchalter.com

---

Illinois Lawmakers Approve Carpenters Union's Legislation to Help Ensure Workers Are Paid What They're Owed

April 19, 2022 — Mid-America Carpenters Regional Council
CHICAGO — Workers around the state have new protections to help ensure they are paid what's owed to them under new legislation that passed the Illinois General Assembly last week. HB5412 makes a primary contractor liable for the failure of a subcontractor to pay wages owed to its workers. The subcontractor would in turn be required to compensate the primary contractor for any wages, damages, interest, penalties or attorneys' fees as a result of the subcontractor's failure to pay wages. "All of us in the Carpenters Union are thrilled to see the Legislature take action on this landmark legislation," said Gary Perinar, Executive Secretary-Treasurer of the Mid-America Carpenters Regional Council. "We have been leading the fight against worker exploitation in every state, and Illinois is showing that hardworking men and women are valued and protected here. When workers are getting ripped off and not paid what they are owed, that should outrage every single person on a job site. I thank Senate President Don Harmon, Speaker Emanuel "Chris" Welch, Leader Evans, and Senator Castro for their unwavering commitment throughout this process to support working families." About the Mid-America Carpenters Regional Council The Mid-America Carpenters Regional Council represents over 52,000 working men and women across 324 counties in Illinois, Missouri, Kansas and Eastern Iowa. The Mid-America Carpenters Regional Council provides the construction and maintenance industries with productive, competitive and certified professionals, encompassing a wide variety of crafts and skills. Read the court decision
Read the full story...
Reprinted courtesy of

---

Policy's One Year Suit Limitation Does Not Apply to Challenging the Insurer's Claims Handling

October 07, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The California Supreme Court held that the policy's suit limitation of one year, consistent with the statute requiring suit be file within twelve months after a loss, did not apply to claims alleging violation of the state's unfair competition law (UCL). Rosenberg-Wohl v. State Farm Fire and Cas. Co., 2024 Cal. LEXIS 3806 (Cal. July 18, 2024). Plaintiff held a homeowners policy issued by State Farm that provided coverage for all risks except those specifically excluded under the policy. The suit limitation provision provided, "Suit Against Us. No action shall be brought unless there has been compliance with the policy provision.The action must be started within one year after the date of loss or damage." On two occasions in late 2018 or early 2019, plaintiff's neighbor stumble and fell as she descended a staircase at plaintiff's residence. Plaintiff discovered that the pitch of the stairs had changed, and replacement of the stairs was required to fix the issue. She contacted State Farm on or around April 23, 2019. On August 9, 2019, plaintiff submitted a claim to State Farm, seeking reimbursement for what she paid to repair the staircase. State Farm denied the claim, advising there was no coverage and identifying several exclusions as potentially applicable. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

The Pandemic of Litigation Sure to Follow the Coronavirus

March 30, 2020 — Aaron Lovaas - Newmeyer Dillion
As the Coronavirus crisis persists, America’s richly diverse private business sector finds itself increasingly subject to unprecedented governmental orders and restrictions that were unheard of only a few weeks ago. While the various “shutdown,” “shelter in place,” and “non-essential business” orders all aim to protect the public health, there is no doubt that the wave of litigation to follow is already swelling. Business interruption, civil authority, and cyber insurance coverages have already been widely discussed as issues certain to be litigated over the coming months and beyond. Additionally, breach of contract litigation is likely to spike as parties attempt to recoup their losses from canceled events, unfulfilled purchase commitments and other unmet obligations. Moreover, regional and national businesses are now in the difficult position of managing their respective affairs to comply with a patchwork of executive orders that are inconsistent from state to state. And, as the pandemic wears on, many are questioning the authority under which some of these executive orders and emergency regulations are being issued in the first place. Indeed, constitutional challenges are almost certain to follow as the business community reframes the characterization of their losses into notions of unconstitutional takings of private property and governmental impairment of private contract rights. Read the court decision
Read the full story...
Reprinted courtesy of Aaron Lovaas, Newmeyer Dillion
Mr. Lovaas may be contacted at aaron.lovaas@ndlf.com

---

Meet the Forum's Neutrals: TOM DUNN

October 21, 2024 — Marissa L. Downs - The Dispute Resolver
Company: Pierce Atwood LLP Office Location: Boston, MA Licensed in: Massachusetts, Rhode Island, California (inactive) Email: rtdunn@pierceatwood.com Website: https://www.pierceatwood.com/people/r-thomas-dunn Law School: McGeorge School of Law (2004 JD) Types of ADR services offered: Arbitration Affiliated ADR organizations: American Arbitration Association Geographic area served: Massachusetts, Rhode Island, and New England Q: Describe the path you took to becoming an ADR neutral. A: Arbitration and alternative forms to avoid and resolve disputes has interested me since law school. Serving as an arbitrator is rewarding both as a neutral helping people close out disputes, but also as an advocate as it reminds me about how best to communicate with the fact finder. Read the court decision
Read the full story...
Reprinted courtesy of Marissa L. Downs, Laurie & Brennan, LLP
Ms. Downs may be contacted at mdowns@lauriebrennan.com

---