FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

What Every Project Participant Needs to Know About Delay Claims

August 05, 2024 — Andrew G. Vicknair - The Dispute Resolver
A “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays. I. Types of Delays Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule. Read the court decision
Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

---

What is the Effect of an Untimely Challenge to the Timeliness of a Trustee’s Sale?

April 13, 2017 — Ben Reeves - Snell & Wilmer Real Estate Litigation Blog
Ever wonder what happens if a person challenges the timeliness of a trustee’s sale after the sale already occurred? Waiver of the argument of course! And, in the case of Wells Fargo Bank, N.A. v. Waltner, the affirmance of an eviction judgment. In the Waltner case, Wells Fargo Bank, N.A., as Trustee for WaMu Mortgage Pass-Through Certificates, Series 2005-PR4 Trust (the “Bank”), purchased a residential property at a trustee’s sale in September 2015. The Bank gave the occupant of the house, Sarah Waltner (“Waltner”), notice to vacate the property, but she did not do so. Accordingly, the Bank filed a summary action to evict Waltner, which the trial court ultimately granted. After the trial court granted the Bank relief, Waltner filed a motion to dismiss and a motion to vacate the eviction judgment arguing, among other things, that the judgment was void because the Bank conducted the trustee’s sale after the statute of limitations expired. Both motions were denied, and Waltner appealed. Read the court decision
Read the full story...
Reprinted courtesy of Ben Reeves, Snell & Wilmer
Mr. Reeves may be contacted at breeves@swlaw.com

---

Persimmon Offers to Fix Risky Homes as Cladding Crisis Grows

February 22, 2021 — Olivia Konotey-Ahulu - Bloomberg
Persimmon Plc, the U.K.’s biggest homebuilder, has offered to pay for work on potentially unsafe buildings in the wake of the cladding scandal that arose from London’s Grenfell Tower fire. The firm has made a provision of 75 million pounds ($104 million) in its 2020 results for any necessary repair work on 26 buildings it developed that may be affected by the issue, it said in a statement Wednesday. It no longer owns the properties and said it would provide support where owners failed to accept their legal responsibilities. “The concern around now banned cladding is affecting many thousands of homeowners who live in high-rise buildings right across the country,” Chairman Roger Devlin said in the statement. “We believe we have a clear duty to act to address this issue.” Read the court decision
Read the full story...
Reprinted courtesy of Olivia Konotey-Ahulu, Bloomberg

---

Primer Debuts on Life-Cycle Assessments of Embodied Carbon in Buildings

August 20, 2018 — Engineering News-Record
A recently released primer for the use of a life-cycle assessment approach to analyze the environmental impacts of buildings is considered a small but necessary step toward the ambitious goal of getting to net-zero embodied carbon and operational greenhouse gas emissions in the construction, operation and decommissioning of buildings. The LCA guide comes after the release of the first-of-its-kind benchmarking database of embodied carbon in existing buildings. And another first—a tool to calculate embodied carbon in construction—is on the horizon. Read the court decision
Read the full story...
Reprinted courtesy of Engineering News-Record
ENR may be contacted at ENR.com@bnpmedia.com

---

Standard Lifetime Shingle Warranties Aren’t Forever

April 03, 2013 — CDJ STAFF
Olympia Construction’s roofing division explained to the web site Thurston Talk how long “lifetime” warranties on shingles really last. Your lifetime? You’re likely to live out the effective period of your lifetime shingle warranty. They note that 100% coverage of the shingle replacement typically lasts only for ten years (and does not cover removal of the existing defective shingles). After that, coverage continues to decline without covering any of the labor. And this can be significant, since they noted that they have seen cases in which a batch of defective shingles means that every home on the block has a defect claim. Read the court decision
Read the full story...
Reprinted courtesy of

---

Canada to Ban Foreigners From Buying Homes as Prices Soar

April 25, 2022 — Brian Platt & Ari Altstedter - Bloomberg
Canada will ban most foreigners from buying homes for two years and provide billions of dollars to spur construction activity in an attempt to cool off a surging real-estate market. The measures will be contained in Finance Minister Chrystia Freeland’s budget on Thursday, according to a person familiar with the matter, asking not to be named because the matter is private. The move signals that Prime Minister Justin Trudeau is becoming more assertive about taming one of the developed world’s most expensive housing markets -- and that the government is growing more concerned about the political backlash to inflation and the rising cost of housing. Reprinted courtesy of Brian Platt, Bloomberg and Ari Altstedter, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

---

Wildfire Is Efficient Proximate Cause of Moisture Reaching Expansive Soils Under Residence

November 05, 2014 — Tred R. Eyerly - Insurance Law Hawaii
The court considered whether a wildfire (covered risk) or moisture in the soils (excluded risk) was the cause of damage to the insureds' home. Encompass Ins. Co. v. Berger, 2014 U.S. Dist. LEXIS 142870 (C.D. Cal. Oct. 7, 2014). In May 2009, the Jesusita Fire caused damage to the insureds' home and surrounding area. The west wall of the house was burned, causing damage to a bedroom. A shed, hot tub, wooden decks and some vegetation, including eucalyptus trees, were damaged. The insureds submitted a claim to Encompass. Eventually, Encompass spent $400,000 repairing the property. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

A Word to the Wise: The AIA Revised Contract Documents Could Lead to New and Unanticipated Risks - Part II

October 16, 2018 — George Talarico - Construction Executive
Part I addressed general conditions, revised insurance terms, revisions that affect owner’s required insurance and revisions that affect contractor’s required insurance. REVISIONS THAT AFFECT DISPUTE RESOLUTION A seemingly minor but noteworthy change is to the definition of “Claim.” Under Section 15.1 a “Claim” is defined to:

• include a request for a modification of contract time; and
• exclude any requirement that an owner must file a claim to impose liquidated damages.

Notably, any request relating to contract time must be brought within the specified time period for Notice of Claim and in the prescribed manner. There are at least two traps for the unwary. First, even though email is regularly used for communications among the parties, the revised contract documents do not recognize email as an acceptable form of delivery of a Notice of Claim. Second, an unwary contractor may wrongly assume that an owner’s failure to assert a claim for LDs means that LDs will not be imposed. This may lull the contractor into failing to timely assert its own claim for a time extension and thereby waiving its ability to do so. Reprinted courtesy of George Talarico, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Talarico may be contacted at gtalarico@sillscummis.com

---