SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Delays and Suspension of the Work Under Fixed Price Government Contract

July 22, 2024 — David Adelstein - Florida Construction Legal Updates
Here is an interesting fact pattern and case decided by the Civilian Board of Contract Appeals dealing with (1) force majeure type events and epidemics (Covid-19); (2) suspension of the work; and (3) delays. These are three topics important to all contractors including federal contractors. In Lusk Mechanical Contractors, Inc. v General Services Administration, 2024 WL 1953697, CBCA 7759 (CBCA 2024), a contractor entered into a fixed price contract with the government to repair, replace, and modernize site and building systems at a federal building. The contractor commenced work right before Covid-19. When Covid-19 hit, the government issued the contractor a two-week suspension of work notice on March 27, 2020. The suspension of work allowed off-site administrative work to continue but suspended on-site physical work. The government extended the suspension of work three more times. The contractor could resume work on the exterior on June 1, 2020, but was not permitted to resume work on the interior until July 20, 2020. On the same date that the contractor was able to commence interior work, it submitted a modification for delay caused by the suspension – 64 days for the time period the entire site shutdown, and 51 days for the interior work shutdown. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Alabama Supreme Court Finds No Coverage for Construction Defect to Contractor's own Product

October 21, 2013 — Tred Eyerly — Insurance Law Hawaii
The Alabama Supreme Court followed prior precedent and found that the contractor's faulty workmanship causing damage to his own product did not arise from an occurrence. Owners Ins. Co. v. Jim Carr Homebuilder, LLC, 2013 Ala. LEXIS 122 (Ala. Sept. 20, 2013). The plaintiffs contracted with Carr to construct a new home. After completion of the home and taking occupancy, the plaintiffs noted several problems with the house related to water leaking through the roof, walls and floors, resulting in water damage to various areas of the house. The plaintiffs sued Carr and the case eventually went to arbitration. The arbitrator entered an award in favor of plaintiffs for $600,000. Owners filed an action against Carr for a declaratory judgment seeking to establish there was no coverage because the property damage did not arise from an occurrence. The trial court granted summary judgment to Carr. Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly
Tred Eyerly can be contacted at te@hawaiilawyer.com

---

Supreme Court of Kentucky Holds Plaintiff Can Recover for Stigma Damages in Addition to Repair Costs Resulting From Property Damage

August 15, 2018 — Gus Sara - The Subrogation Strategist
In Muncie v. Wiesemann, 2018 K.Y. LEXIS 257, the Supreme Court of Kentucky considered whether stigma damages[1] in a property casualty case are recoverable in addition to the costs incurred to remediate the actual damage. The court held that stigma damages are recoverable in addition to repair costs, but the total of the stigma damages and repair costs cannot exceed the diminution in the fair market value of the property. The court’s decision establishes that if the repair costs are insufficient to make the plaintiff whole, a recovery for stigma damages up to the amount of the diminution in the market value of the home is appropriate. Appellants Cindy and Jim Muncie incurred significant property damage to their home as a result of an oil leak originating from a neighboring property owned by the Estate of Martha Magel. In 2011, Auto Owners Insurance Company (Auto Owners), the liability carrier for the Estate’s testatrix, Patricia Weisman, filed an impleader complaint in federal court to discharge its obligation to settle the third-party liability claims on behalf of Ms. Weisman. Auto Owners reached a settlement with the Muncies for $60,000 which represented the remediation costs for the actual damage to the property. The settlement release reserved the Muncies’ right to pursue a claim for stigma damages associated with the oil leak. Read the court decision
Read the full story...
Reprinted courtesy of Gus Sara, White and Williams LLP
Mr. Sara may be contacted at sarag@whiteandwilliams.com

---

Examining Construction Defect as Occurrence in Recent Case Law and Litigation

February 05, 2014 — Beverley BevenFlorez-CDJ STAFF
In Lexology, Stephen M. Prignano and Nora A. Valenza-Frost of Edwards Wildman Palmer LLP examined recent case law and litigation to discuss whether or not construction defects are construed as an occurrence in the current legal climate. Prignano and Valenza-Frost stated, “The determination of whether there is coverage under a CGL policy for a construction defect claim requires an insurer to carefully examine the law of the relevant jurisdiction. Courts and legislatures continue to reach different conclusions respecting coverage, and some states have a more well-developed body of law on these issues than others.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Peru’s Former President and His Wife to Stay in Jail After Losing Appeal

August 10, 2017 — John Quigley - Bloomberg
Former President Ollanta Humala and his wife Nadine Heredia will remain in jail while they are investigated for campaign donations involving Brazilian construction companies and the Venezuelan government, a Peruvian court said Friday. The couple, who were given pre-trial detention three weeks ago, had asked the appeal court judges to change the order for one requiring them not to leave the country and to appear regularly before the authorities. The couple turned themselves in on July 13 after Judge Richard Concepcion ordered 18 months of preventive detention for suspected money laundering. Concepcion had said there was sufficient evidence of wrongdoing and grounds to believe Humala and his wife would seek to obstruct the ongoing investigation by the Attorney General’s office. Read the court decision
Read the full story...
Reprinted courtesy of John Quigley, Bloomberg

---

White and Williams Defeats Policyholder’s Attempt to Invalidate Asbestos Exclusions

January 28, 2014 — White and Williams LLP
White and Williams attorneys scored a significant victory for the insurance industry on January 15, 2014, when a federal jury of four men and four women rejected a policyholder’s novel efforts to invalidate asbestos exclusions contained in insurance policies issued between February 1, 1979 and August 1, 1985. In General Refractories Co. v. First State Ins. Co., Civil Action No. 04-CV-3509 (E.D. Pa.), General Refractories Company contended that asbestos exclusions in insurance policies issued by various insurance companies in the late 1970s and 1980s had not been submitted to the Pennsylvania Department of Insurance for approval prior to use and, therefore, were unenforceable. Holding a failure to obtain approval, by itself, would not be sufficient to render the exclusions unenforceable, the Honorable Edmund Ludwig sent the matter to trial to determine whether the Pennsylvania Insurance Commissioner implemented a policy that was uniformly executed by the Insurance Department to disapprove all asbestos exclusions between February 1, 1979 and August 1, 1985, such that the exclusions violated a “dominant public policy.”

Reprinted courtesy of Gregory LoCasale, White and Williams LLP

and Patricia Santelle , White and Williams LLP

Ms. Santelle may be contacted at santellep@whiteandwilliams.com and Mr. LoCasale may be contacted at locasaleg@whiteandwilliams.com. Read the court decision
Read the full story...
Reprinted courtesy of

---

New York’s Highest Court Reverses Lower Court Ruling That Imposed Erroneous Timeliness Requirement For Disclaimers of Coverage

June 18, 2014 — Robert F. Walsh and Paul A. Briganti – White and Williams LLP
On June 10, 2014, the New York Court of Appeals (the state’s highest court) issued a unanimous decision in KeySpan Gas East Corp. v. Munich Reinsurance America, Inc. (No. 110, June 10, 2014), reversing a lower court decision which had erroneously imposed on insurers a duty to disclaim coverage for property damage claims as soon as possible or risk waiving their coverage defenses. White and Williams represented one of the insurance company defendants in the action. The case involved an action against three excess insurers for insurance coverage for underlying environmental claims arising from Manufactured Gas Plant sites. Upon receiving notice of the underlying claims, the three insurers reserved their rights to deny coverage on various grounds, including late notice of an occurrence, pending an investigation. The insurers ultimately denied coverage on the basis of late notice several years later based on information developed in discovery in the litigation. The policyholder/plaintiff KeySpan argued that the insurers had unreasonably delayed in issuing their disclaimers and that there was a triable issue of fact on whether such a delay amounted to a waiver of the late notice defense. Reprinted courtesy of Robert F. Walsh, White and Williams LLP and Paul A. Briganti, White and Williams LLP Mr. Walsh may be contacted at walshr@whiteandwilliams.com; Mr. Briganti may be contacted at brigantip@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Project Delivery Methods: A Bird’s-Eye View

November 01, 2021 — Levi W. Barrett, Nathan A. Cohen & Stewart Shurtleff - ConsensusDocs
For centuries the ability to construct sophisticated structures has been the yardstick for measuring civilizations. Naturally, as our knowledge and capacity to build has evolved and developed over the ages, the methods of project delivery have similarly progressed. From Design-Bid-Build to CM-at-Risk and Design-Build to Integrated Project Delivery, each method developed to fit a very specific need—but each carries its own set of inherent risks and rewards. In this article we explore key aspects and differences among the various delivery methods that are commonly used in today’s construction industry, and provide guidance related to the obligations and risk profiles of the parties involved. Ideally, contractors and construction managers may refer to the advice provided herein when determining whether a proposed delivery method properly fits the requirements of the project under consideration. Reprinted courtesy of Levi W. Barrett, Peckar & Abramson, P.C., Nathan A. Cohen, Peckar & Abramson, P.C. and Stewart Shurtleff, Peckar & Abramson, P.C. Mr. Barrett may be contacted at lbarrett@pecklaw.com Mr. Cohen may be contacted at ncohen@pecklaw.com Mr. Shurtleff may be contacted at sshurtleff@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---