Fairfield Connecticut Building Expert Directory

The Association of Southern California Defense Counsel (ASCDC) and the Construction Defect Claims Managers Association (CDMA) Annual Construction Defect Seminar

December 04, 2013 — CDJ STAFF
The Association of Southern California Defense Counsel (ASCDC) and the Construction Defect Claims Managers Association (CDMA) Jointly Present the 2013 Construction Defect Seminar and Holiday Party to be Held Thursday, December 5, at the Hilton Hotel, Costa Mesa Professional development activities will include panel discussions including “What Happened to Simple HOA Actions – Litigating Commercial Projects,” a roundtable discussion by Ross Hart, Keith Koeller, Alex Robertson, Les Robertson, Todd Schweitzer, Wendy Wilcox, and Brian D. Kahn. A timely discussion of California’s “right to repair” laws “SB800 – Is It Still Worth Fighting For?,” will be presented by Nick Cammarota, Timothy Earl, Luke Ryan, Dave Simons, Dave Stern, John Terry, and Adrienne Cohen is also on the the agenda.. Additionally, Assemblyman Donald P. Wagner will serve as the event’s Special Guest Speaker. Bert L. Howe & Associates, Inc. is pleased to return this year as an event sponsor. BHA will be exhibiting our latest inspection data collection system and forensic analysis platforms newly optimized for the new iOS 7. Visitors of the BHA exhibit booth can enter into our drawing for a 16 GB iPad Air with WiFi. Professional development activities will be followed by a holiday party and reception honoring the Orange County Judiciary. The reception will be hosted by Glenn Barger, Adrienne Cohen, and Brian Kahn. It will place from 5:30 p.m. through 7.00 p.m. For further information for the event, please visit http://www.ascdc.org/Events.asp. Read the court decision
Read the full story...
Reprinted courtesy of

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Back Posting with Thoughts on Lien Waivers

May 20, 2015 — Christopher G. Hill – Construction Law Musings
After a week of being unable to post due to the rigors of my solo construction practice, I’m back on the blogging train. For those of you that missed my new musings this past week, I hope that you had a chance to look through some of the past Guest Post Friday posts for some good stuff to read. During the course of my busy week last week, a question came up regarding the mechanic’s lien waivers that commercial construction companies routinely execute as part of the payment process. The waiver forms vary, but each essentially states that in exchange for payment the payee, whether a subcontractor or supplier (or even general contractor) waives its future rights to record a mechanic’s lien for the work that is covered by the payment received. Most if not all of these forms further require a certification that the funds paid will either be used to pay suppliers or that suppliers have already been paid. This general description is not the reason for this post. As is always the case in the Commonwealth of Virginia where the contract is king and a court is unlikely to reinterpret any written contractual document, the devil is in how that waiver is worded. Some waivers are worded in such a way that they essentially require a payee to certify receipt of the funds prior to payment being received. These same forms require the same pre-payment certification that all suppliers and subcontractors of the payee have already been paid. In short they require a payee to both place complete trust in the payor that the check will be paid and that the check will not bounce while in many cases (often with an unstated “wink and nod”) claiming payment was already made when all know the likelihood is that it has not. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, Law Office of Christopher G. Hill, PC
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Withdrawal Liability? Read your CBA

July 10, 2018 — Wally Zimolong – Supplemental Conditions
Withdrawal liability is a huge issue facing unionized employers. According to Bloomberg, 93% of the Top 200 largest pension plans are underfunded by a combined $382 billion. Contractors that withdraw from a multi-employer pension plan can face hundreds of thousands or millions of dollars in assessed withdrawal liability. However, employers may be able to avoid that liability, plus the legal and consulting fees to fight it, by simply reading their collective bargaining agreement. Read the court decision
Read the full story...
Reprinted courtesy of Wally Zimolong, Zimolong LLC
Mr. Zimolong may be contacted at wally@zimolonglaw.com

Read Her Lips: “No New Buildings”

November 18, 2011 — CDJ STAFF

Martha Johnson, the head of the General Services Administration, has said that her agency will not be building any new buildings in the near future. Among other duties, the GSA is responsible for the building, renovating, and leasing of federal office space. The White House had proposed $840 million in new construction, the Senate only $56 million. The House did not appropriate any money for the agency to use for new construction.

In addition to cutbacks on new buildings, Congress is suggesting only $280 million in repairs of existing government buildings. In order to cut back, the GSA has dropped plans to renovate their own offices in favor of renovations at the Department of Homeland Security and the Food and Drug Administration.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

Strangers in a Strange Land: Revisiting Arbitration Provisions to Account for Increasing International Influences

July 16, 2023 — William Underwood - ConsensusDocs
Arbitration is nothing new. Neither is globalization. But the two are coming together in ways that have incrementally influenced the manner in which many arbitrations are now conducted. And this merits a re-examination of old arbitration clauses to account for some of these new influences. With that in mind, this article will examine some basic considerations when examining arbitration agreements within a construction industry that continues to see the increasing participation of foreign companies in domestic projects. Although this is not a comprehensive review of best drafting practices, nor is it a full survey of the differences between domestic and international arbitration, this article will nonetheless highlight a few basic concepts to keep in mind when reviewing arbitration clauses. As a basic starting point, the continuing globalization of the construction industry has led to distinct impacts on the ways in which parties conduct arbitrations in the United States. The increased participation of international companies in domestic construction projects has naturally led to the application of international legal concepts to domestic alternative dispute resolution. And the increasing prevalence of these international concepts has led to a number of important trends that can impact the way arbitrations are handled. Read the court decision
Read the full story...
Reprinted courtesy of William Underwood, Jones & Walker (ConsensusDocs)
Mr. Underwood may be contacted at wunderwood@joneswalker.com

U.S., Canada, Mexico Set New Joint Clean-Energy Goal

June 30, 2016 — Tom Ichniowski – Engineering News-Record
The U.S., Canada and Mexico have agreed to boost their combined clean-energy generation to 50% of electricity production by 2025, from 37% last year. Read the court decision
Read the full story...
Reprinted courtesy of Tom Ichniowski, Engineering News-Record
Mr. Ichniowski may be contacted at ichniowskit@enr.com

Elyria, Ohio, to Invest $250M to Halt Illegal Sewage into Black River

December 18, 2022 — Jim Parsons - Engineering News-Record
Elyria, Ohio, will invest nearly $250 million in capital improvement projects over the next 20 years to eliminate longstanding discharges of untreated sewage into the Black River, 10 miles upstream from Lake Erie. The plan is part of a consent decree negotiated with federal and state regulators following more than 1,000 illegal discharges from the city's sewer system into the river or its tributaries since 2011. Reprinted courtesy of Jim Parsons, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES