Cambridge Massachusetts Building Expert Directory

Don’t Kick the Claim Until the End of the Project: Timely Give Notice and Preserve Your Claims on Construction Projects

December 10, 2015 — Christopher G. Hill – Construction Law Musings
For this week’s Guest Post Friday, we welcome Tara L. Chadbourn. Tara is an attorney with ReavesColey PLLC in Chesapeake, VA, where she concentrates her practice on construction law, litigation and commercial litigation. Tara counsels owners, contractors, subcontractors and materials suppliers in various government and commercial construction matters. Tara can be reached at tara.chadbourn@reavescoley.com. You may have experienced and have certainly heard of the scenario in which a contractor waits to address a claim as part of project closeout, only to realize the applicable deadline has already passed. While there may have been discussions about claims during the course of the project, contractors cannot rely upon oral conversations about outstanding claims. Instead, contractors must be vigilant in satisfying notice requirements and preserving claims. While entitlement must still be proven, a contractor’s chances of recovery increase greatly if the contractor abides by notice requirements and consciously preserves claims in the following ways. Contractors Must Acquaint Themselves with Contractual Notice Provisions: Many prime and subcontract agreements contain stringent notice provisions that require the contractor to give notice within a certain time period or else the claim is expressly waived. The deadline for notice is often only a few days after the occurrence giving rise to the claim or the contractor becoming aware of the claim. To avoid waiver, contractors must carefully review their contracts for provisions requiring notice of a claims for adjustment for a variety of situations to include unforeseen site conditions, trade sequencing changes, project delay or scope of work changes. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, Law Office of Christopher G. Hill, PC
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Best Lawyers Recognizes Twenty White and Williams Lawyers

September 04, 2018 — White and Williams LLP
Twenty White and Williams lawyers were recognized on the 2019 Best Lawyers in America list. Inclusion in Best Lawyers is based entirely on peer-review. The methodology is designed to capture, as accurately as possible, the consensus opinion of leading lawyers about the professional abilities of their colleagues within the same geographical area and legal practice area. Best Lawyers employs a sophisticated, conscientious, rational, and transparent survey process designed to elicit meaningful and substantive evaluations of quality legal services. Read the court decision
Read the full story...
Reprinted courtesy of White and Williams LLP

Termination for Convenience Clauses: Maybe More Than Just Convenience

June 06, 2022 — Robert C. Shaia - ConsensusDocs
A contractor begins work on a project and everything is going well, until one day the owner informs the contractor that it is being terminated for convenience. Possibly, there is no discussion about alleged defects, reasons for the termination, or any damages the owner might seek against the contractor. In that moment, the contractor may be unaware of any perceived wrongdoing or problems with its work. The industry has typically accepted that, in this scenario, the owner implicitly waives the right to any remedies against the contractor, except those expressly set forth in the contract. Reasonable minds might assume that, if the owner believed it needed to seek further remedies, it would terminate the contractor for cause instead of convenience. And often overlooked during contract negotiations are the benefits of including an express “waiver of remedies” in the termination for convenience section. Read the court decision
Read the full story...
Reprinted courtesy of Robert C. Shaia, Watt, Tieder, Hoffar, & Fitzgerald, LLP (ConsensusDocs)
Mr. Shaia may be contacted at rshaia@watttieder.com

On Rehearing, Fifth Circuit Finds Contractual-Liability Exclusion Does Not Apply

November 26, 2014 — Tred R. Eyerly – Insurance Law Hawaii
On rehearing, the Fifth Circuit determined that the contractual-liability exclusion did not apply to bar coverage for damage caused by the insured contractor to the home it constructed. Crownover v. Mid-Continent Cas. Co., 2014 U.S. App. LEXIS 20727 (5th Cir. Oct. 29, 2014).The court withdrew its prior opinion, summarized here. Arrow Development, Inc. contracted with the Crownovers to construct a home. The contract had a warranty-to-repair clause, which, in paragraph 23.1, provided that Arrow would "promptly correct work . . . failing to confirm to the requirements of the Contract Documents." After the Crownovers moved in, cracks began to appear in the walls and foundation of the home. Additional problems with the heating, ventilation, and air conditioning ("HVAC") caused leaking in the exterior lines and air ducts inside the home. To compensate for defects in the HVAC system, the system's mechanical units ran almost continuously in order to heat or cool the home. Because they were overburdened, the mechanical units had to be replaced. The Crownovers paid several hundred thousand dollars to fix the problems with the foundation and HVAC system. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

New York Court Permits Asbestos Claimants to Proceed Against Insurers with Buyout Agreements

December 06, 2021 — Patricia B. Santelle & Frank J. Perch, III - White and Williams LLP
A recent New York federal district court decision addresses a number of issues in the context of asbestos coverage involving an insolvent insured, holding that policy buyout agreements between the insured and its insurers did not bar actions by certain tort judgment creditors against some of the settling insurers, and further finding that such agreements can constitute fraudulent conveyances, especially where the proceeds of the settlement are not reserved for payment of insured claims. In the litigation pending in the Western District of New York (Mineweaser v. One Beacon Insurance Company, et al., No. 14-CV-0585A), certain asbestos plaintiffs sought recovery from excess insurers for judgments obtained against an insolvent asbestos supplier (Hedman Resources, formerly known as Hedman Mines), which ceased operations in 2007 due to insolvency. Hedman had at one time been a subsidiary of Gulf & Western. As of 2009-2011, the excess insurers of Gulf & Western were advised of exhaustion of primary insurance as well as Hedman’s insolvency. Reprinted courtesy of Patricia B. Santelle, White and Williams LLP and Frank J. Perch, III, White and Williams LLP Ms. Santelle may be contacted at santellep@whiteandwilliams.com Mr. Perch may be contacted at perchf@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

Privette: The “Affirmative Contribution” Exception, How Far Does It Go?

August 10, 2020 — Courtney Arbucci, Peter A. Dubrawski & Austin F. Smith - Haight Brown & Bonesteel
In Horne v. Ahern Rentals, Inc. (No. B299605, filed 6/10/2020 ord. publ. 6/10/2020), Plaintiffs filed a wrongful death action against Defendant Ahern Rentals, Inc. (“Ahern”) arising out of the fatal incident involving Ruben Dickerson (“decedent”), while employed by independent contractor 24-Hour Tire Service, Inc. Decedent was ultimately crushed on Ahern Rentals, Inc.’s property when a forklift that was improperly placed on uneven ground collapsed as decedent laid under the raised forklift as he performed tire maintenance. Plaintiffs’ suit would normally be barred by the Privette line of decisions which arise out of the foundational principle that an independent contractor’s hirer presumptively delegates to the contractor its tort law duty to provide a safe workplace for the contractor’s employees. (Privette v. Superior Court (1993) 5 Cal.4th 689 (Privette).) The Privette rule is subject to a number of exceptions including the “peculiar risk” exception, the “nondelegable duty” exception and the “affirmative contribution” exception. (See Privette, supra.) Here, Plaintiffs’ claimed that their suit against Ahern arose out of the “affirmative contribution” exception to Privette as defined by Hooker v. Department of Transportation (2002) 27 Cal.4th 198, 202 (Hooker). Hooker allows suits otherwise barred by Privette to go forward if the hirer of the independent contractor “exercised control over safety conditions at the worksite in a way that affirmatively contributed to the employee’s injuries.” Reprinted courtesy of Haight Brown & Bonesteel attorneys Courtney Arbucci, Peter A. Dubrawski and Austin F. Smith Ms. Arbucci may be contacted at carbucci@hbblaw.com Mr. Dubrawski may be contacted at pdubrawski@hbblaw.com Mr. Smith may be contacted at asmith@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Time is Money. Unless You’re an Insurance Company

December 02, 2015 — Garret Murai – California Construction Law Blog
Benjamin Franklin may never have been President but he’s better known than most of them. Not least of all for his pithy quotes on a wide range of subjects:

On personal finance – “A penny saved is a penny earned.”

On education – “Tell me and I forget, teach me and I remember, involve me and I learn.”

On getting real – “In this world nothing can be said to be certain, except death and taxes.”

On guests – “Guests, like fish, begin to smell after three days.”

On lawyers – “A countryman between two lawyers is like a fish between two cats.”

On beer – “In wine there is wisdom, in beer there is freedom, in water there is bacteria.”

But if you were to pick one theme that seems to recur the most in Franklin’s quotes, it would be productivity:

“Time is money.”

“By failing to prepare, you are preparing to fail.”

“Never leave that till tomorrow which you can do today.”

“Early to bed and early to rise, makes a man happy, wealthy and wise.”
But, as the next case, Grebow v. Mercury Insurance Company, Case No. B261172, California Court of Appeals for the Second District (October 21, 2015), illustrates, sometimes the most efficient way of doing things may not necessarily be the most financially prudent way of doing things. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com
Battle of “Other Insurance” Clauses
March 23, 2011 — Tred R. Eyerly
The New York Court of Appeals considered the impact of competing “other insurance” provisions located in both a CGL policy and a D&O policy. See Fieldston Property Owners Assoc., Inc. v. Hermitage Ins. Co., Inv., 2011 N.Y. LEXIS 254 (N.Y. Feb. 24, 2011).

In the underlying case, Fieldston’s officers were charged with making false statements and fraudulent claims with respect to a customer's right to access its property from adjacent streets. Suit was eventually filed against Fieldston and its officers, alleging several causes of action including injurious falsehood. Damages were sought.

Fieldston’s CGL policy was issued by Hermitage. The “other insurance” provision stated, “If other valid and collectible insurance is available to the insured for a loss we cover . . . our obligations are limited,” but also stated it would share with all other insurance as a primary policy.
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com
Read the court decision
Read the full story...
Reprinted courtesy of

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES