Fairfield Connecticut Building Expert Directory

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

KONE is Shaking Up the Industry with BIM

January 20, 2020 — Aarni Heiskanen - AEC Business
KONE supplies elevators, escalators, autowalks and maintenance and modernization solutions. I sat down with Kenneth Flannigan to discuss how BIM is changing KONE and what it means to the industry. KONE operates in over 60 countries, has around 1.3 million units in service, and moves over one billion people per day. The company’s mission is “to improve the flow of urban life.” Kenneth Flannigan is the BIM Solution Owner for the company. He acknowledges that even though KONE provides equipment and software innovation, in this day and age that’s not enough. “We’re a critical path item. How innovative are we if we’re not working on every single project in a shared 3D environment, like our customers?” Flannigan asks. KONE serves both indirect and paying customers. It works with influencers like architects and with general contractors, builders, and construction managers. It also has a life-cycle relationship with building owners, which is evidenced by the fact that over 30% of the company’s sales come from maintenance. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Alleged Negligent Misrepresentation on Condition of Home is Not an Occurrence Causing Property Damage

December 17, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The court found that even if the insured's negligent misrepresentations constituted an accident, the disclosures did not cause physical damage to the property. Wood v. USAA Cas. Ins. Co., 2024 U.S. Dist. LEXIS 180624 (D. S.C. Sept. 12, 2024). The insured, Clinton Wood, purchased a townhome in January 2014. After the purchase, Wood experienced leaks and significant water intrusion, as did other townhome owners in the same development. Wood and the other owners retained an engineer to evaluate the cause of the water damage. The engineer determined that the water intrusion was caused by defects in the design and construction of the residence. The engineer told Wood that the proposed repairs would not adequately address and resolve the water intrusion and leaks, and that the problems would continue even if repairs were made. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

New York Appeals Court Rekindles the Spark

March 16, 2017 — Lian Skaf - White and Williams LLP
In John Trimble, et al. v. City of Albany, et al., 2016, 144 A.D.3d 1484; 42 N.Y.S. 3d 432 (N.Y. App. Div.), the Supreme Court of New York, Appellate Division, addressed the issue of governmental immunity for municipal fire companies. The court held that the plaintiff, John Trimble (Trimble), had sufficient evidence related to the four-pronged test for establishing a “special relationship” between a municipality and a citizen for liability to attach. In addition, the court held that the defendants were not entitled to summary judgment on the issue of governmental immunity. Specifically, regarding the latter holding, the court stated that, when there is no actual choice made on the part of the government, the government’s actions cannot be considered discretionary and immunity will not apply. In the case at hand, a fire occurred at Trimble’s home on the evening of February 2, 2013. Trimble called 911 and the Department of Fire and Emergency Services for the City of Albany (the Department) responded. After extinguishing the fire, the Department conducted an investigation and cleared the home. The Department’s investigators then told Trimble that the fire was extinguished and it was safe to enter the home. Trimble did so, removing some items so that he could stay with relatives that night. Several hours later, there was a rekindle and the rekindled fire destroyed the home. Read the court decision
Read the full story...
Reprinted courtesy of Lian Skaf, White and Williams LLP
Mr. Skaf may be contacted at skafl@whiteandwilliams.com

Real Estate & Construction News Round-Up (08/24/22) – Local Law 97, Clean Energy, and IRA Tax Credits

September 26, 2022 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
This week’s round-up features the intersection of real estate and energy efficiency, including state efforts surrounding clean energy legislation, Inflation Reduction Act tax credits, hotel & hospitality sectors creating sustainable initiatives to reduce carbon emissions, and more.

In New York City, building owners try to figure out how to pay for upgrades needed to comply with regulations outlined in Local Law 97 that are intended to fight climate change. (Jane Margolies, The New York Times)
Maryland, Massachusetts, and New York approve clean energy legislation, enacting laws to promote electric vehicles as well as wind and solar energy. (ACEEE)
The Inflation Reduction Act (IRA), signed into law by President Biden this week, includes expanded tax credits expected to pivot building owners and property developers to make upgrades geared towards energy efficiency. (Jack Rogers, Globe St.)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

D.C. Decision Finding No “Direct Physical Loss” for COVID-19 Closures Is Not Without Severe Limitations

August 24, 2020 — Michael S. Levine & Michael L. Huggins - Hunton Andrews Kurth
On August 6, 2020, in Rose’s 1 LLC, et al. v. Erie Insurance Exchange, Civ. Case No. 2020 CA 002424 B, a District of Columbia trial court found in favor of an insurer on cross motions for summary judgment on the issue of whether COVID-19 closure orders constitute a “direct physical loss” under a commercial property policy. At its core, the decision ignores key arguments raised in the summary judgment briefing and is narrowly premised on certain dictionary definitions of the terms, “direct,” “physical,” and “loss.” Relying almost entirely on those definitions – each supplied by the insureds in their opening brief – the court set the stage for its ultimate conclusion by finding “direct” to mean “without intervening persons, conditions, or agencies; immediate”; and “physical” to mean “of or pertaining to matter ….” The court then apparently accepted the policy’s circular definition of “loss” as meaning “direct and accidental loss of or damage to covered property.” Importantly, however, despite recognizing the fundamental rule of insurance policy construction that the court “must interpret the contract ‘as a whole, giving reasonable, lawful, and effective meaning to all its terms, and ascertaining the meaning in light of all the circumstances surrounding the parties at the time the contract was made,’” the court apparently ignored the insureds’ argument that the term “property damage” is specifically defined in the policy to include “loss of use” without any specific reference to physical or tangible damage. Reprinted courtesy of Michael S. Levine, Hunton Andrews Kurth and Michael L. Huggins, Hunton Andrews Kurth Mr. Levine may be contacted at mlevine@HuntonAK.com Mr. Huggins may be contacted at mhuggins@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

Google Advances Green Goal With AES Deal for Carbon-Free Power

May 17, 2021 — Mark Chediak - Bloomberg
Google’s moving forward with its goal of becoming carbon-free by the end of the decade after AES Corp. agreed to supply the tech giant with renewable energy to power its data centers in Virginia. AES, an international electricity company and power-plant developer, said the deal will result in the construction of 500 megawatts of solar, wind, small-scale hydroelectric and battery storage projects and supply will begin later this year, according to a statement Tuesday. AES and third-party developers will own the facilities. Read the court decision
Read the full story...
Reprinted courtesy of Mark Chediak, Bloomberg

Virtual Jury Trials of Construction Disputes: The Necessary Union of Both Sides of the Brain

May 17, 2021 — John Dannecker - Construction Executive
Bart Smith is the Senior Project Manager for Simply Best, a general contracting firm. He has been assigned to serve as the liaison with outside counsel in a lawsuit against Holly’s Harleys, a project owner who contracted with Best for the construction of a motorcycle showroom. Best filed suit in federal court for additional project costs it incurred, which it contends were caused by the specification of incompatible materials by Holly’s design firm. The coronavirus pandemic is still raging as the trial date approaches. Courthouse facilities are closed so civil trials are conducted using remote technology, if they occur at all. Bart negotiated the prime contract with Holly’s, and he regrettably allowed Best’s binding arbitration and jury trial waiver clauses in the prime contract to be deleted. Bart worries about how the intricacies of Best’s case can be adequately explained to a jury in a remote trial. His concern approaches panic when Best’s trial counsel explains how the trial will be conducted with none of the parties—their attorneys, the judge, the witnesses or the jury—present in the same location. Reprinted courtesy of John Dannecker, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES