Fairfield Connecticut Building Expert Directory

The Word “Estimate” in a Contract Matters as to a Completion Date

February 12, 2024 — David Adelstein - Florida Construction Legal Updates
Language in a contract matters. The word “estimates” or “estimated” matters particularly when it comes to a date certain such as a substantial completion or completion date. Remember this. Here is an example. In Parque Towers Developers, LLC v. Pilac Management, Ltd., 49 Fla.L.Weekly D190a (Fla. 3d DCA 2024), a trial court held that the developer did not complete the construction of five condominium units by the date in the purchase agreements. The developer appealed because “[t]he agreements contain no date certain for the completion of the units, but rather include a clause that ‘Seller estimates it will substantially complete construction of the Unit, in the manner specified in this Agreement, by December 31, 2017, subject to extensions resulting from ‘Force Majeure (the ‘Outside Date’).’” Parque Towers, supra. Another provision in the purchase agreements stated, “[w]henver this Agreement requires Seller to complete or substantially complete any item of construction, that item will be understood to be complete or substantially complete when so completed or substantially completed in Seller’s opinion. Id. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Formal Request for Time Extension Not Always Required to Support Constructive Acceleration

April 25, 2022 — David Adelstein - Florida Construction Legal Updates
Does a constructive acceleration claim require the contractor to always request an extension of time which is then denied by the owner? While this is certainly the preference and the contractor should be requesting an extension of time as a matter of course for an excusable delay, the answer is NO! in certain circumstances. This is conveyed in the factually detailed case discussed below where a formal request for an extension of time was not required for the contractor to support its constructive acceleration claim. But first, what is constructive acceleration: Constructive acceleration “occurs when the government demands compliance with an original contract deadline, despite excusable delay by the contractor.” The Federal Circuit in Fraser defined the elements of constructive acceleration as follows: (1) that the contractor encountered a delay that is excusable under the contract; (2) that the contractor made a timely and sufficient request for an extension of the contract schedule; (3) that the government denied the contractor’s request for an extension or failed to act on it within a reasonable time; (4) that the government insisted on completion of the contract within a period shorter than the period to which the contractor would be entitled by taking into account the period of excusable delay, after which the contractor notified the government that it regarded the alleged order to accelerate as a constructive change in the contract; and (5) that the contractor was required to expend extra resources to compensate for the lost time and remain on schedule. Nova Group/Tutor-Saliba v. U.S., 2022 WL 815826, *42 (Fed.Cl. 2022) quoting Fraser Constr. Co. v. U.S., 384 F.3d 1354, 1361 (Fed. Cir. 2004) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Federal Court Asks South Dakota Supreme Court to Decide Whether Injunction Costs Are “Damages,” Adopts Restatement’s Position on Providing “Inadequate” Defense

August 13, 2019 — Anthony L. Miscioscia & Timothy A. Carroll - White and Williams LLP
Do costs associated with complying with an injunction constitute covered “damages?” The U.S. District Court for the District of South Dakota recently certified that question to the South Dakota Supreme Court, in Sapienza v. Liberty Mutual Fire Insurance Company, No. 3:18-CV-03015-RAL, 2019 U.S. Dist. LEXIS 84973 (D.S.D. May 17, 2019). If the South Dakota Supreme Court takes on the question, it will become one of the few highest state courts to do so.[1] The Sapienza case is also notable because the court adopted § 12 of the Restatement of the Law of Liability Insurance (Restatement) regarding an insurer’s potential liability for providing an “inadequate” defense. In doing so, the Sapienza court joins a growing list of courts to rely upon or cite to the Restatement. The Sapienza case arose out of an underlying dispute between residential neighbors over the size and location of the Sapienzas’ new house they built in a historic district in Sioux Falls, SD. The newly-built house allegedly prevented the neighbors from using their fireplace, blocked natural light the neighbors previously enjoyed, and decreased the value of the neighbors’ house. The neighbors sought a permanent injunction requiring the Sapienzas to modify or relocate the house. The Sapienzas’ homeowners’ insurer provided them with defense counsel, but the insurer instructed the Sapienzas that it would not cover any costs associated with an injunction as such costs did not constitute covered “damages.” Reprinted courtesy of Timothy Carroll, White and Williams LLP and Anthony Miscioscia, White and Williams LLP Mr. Schulman may be contacted at carrollt@whiteandwilliams.com Mr. Anderson may be contacted at misciosciaa@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

Does the Implied Warranty of Habitability Extend to Subsequent Purchasers? Depends on the State

October 08, 2014 — Beverley BevenFlorez-CDJ STAFF
Attorneys for Traub Liberman Straus & Shrewsberry LLP (in JD Supra Business Advisor), discussed how state courts have come to different conclusions as to “whether a subsequent purchaser of a previously inhabited residence can recover contract damages from a builder or general contractor for breach of the implied warranty of habitability.” Recently, a Pennsylvania “sided with the builder, holding that the implied warranty of habitability was grounded in contract law. Thus, the Court reasoned that an action for breach of the implied warranty of habitability required a showing of contractual privity between the parties. Because there was no contractual privity between the Conways and the builder, the Conways could not pursue an action against the builder based on a breach of the implied warranty of habitability.” However, other state courts have made other conclusions. “Iowa permits an action for breach of the implied warranty of workmanlike construction by subsequent purchasers and does not require a showing of contractual privity. Rhode Island also does not require contractual privity, but limits liability to latent defects discovered within 10 years of construction.” Vermont and Connecticut, however, require contract privity. Read the court decision
Read the full story...
Reprinted courtesy of

Concerns Over Unstable Tappan Zee Bridge Push Back Opening of New NY Bridge's Second Span

October 02, 2018 — The New York Daily News - Engineering News-Record
Sept. 08 --Big bridge, big scissors, big problems. A day after an elaborate ribbon-cutting ceremony, the grand opening of the second span of the new Gov. Mario M. Cuomo bridge was postponed over concerns that the remains of the "destabilized" and "dangerous" Tappan Zee Bridge could collapse. Read the court decision
Read the full story...
Reprinted courtesy of Engineering News-Record
ENR may be contacted at ENR.com@bnpmedia.com

Submitting Claims on Government Projects Can Be Tricky

March 19, 2015 — Craig Martin – Construction Contractor Advisor
The Federal Circuit Court of Appeals opinion in K-Con Building Systems, Inc. v. United States illustrates the difficulties a contractor may face when pursuing a claim before a Contracting Officer. After nearly 10 years of litigation, the court found that the contractor’s claim to the Contracting Officer did not contain enough detail to allow the claim to proceed. That’s a lot of time and resources wasted on a claim that was dead from the start. K-Con was awarded a $582,000 job to design and build a Coast Guard support building in Michigan. K-Con was unable to complete the project by the finish date and the Coast Guard assessed liquidated damages of $109,554. K-Con contested the assessment of liquidated damages by submitting a one paragraph letter asserting that it was not the sole cause of the alleged delays; that the government was at fault for the delay; and the liquidated damages were an impermissible penalty. The Contracting Officer ultimately denied K-Con’s claim and K-Con appealed to the Court of Claims. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Local Government’s Claims on Developer Bonds Dismissed for Failure to Pursue Administrative Remedies

March 22, 2017 — David R. Cook - Autry, Hanrahan, Hall & Cook, LLP
The Georgia Court of Appeals recently affirmed a trial court’s dismissal of a county’s claim on developer bonds based on its failure to exhaust administrative remedies. Douglas County v. Hamilton State Bank, — Ga. App. –, A16A1708 (Mar. 16, 2017). Specifically, because the bank was under FDIC receivership, the County was required to pursue administrative remedies under the Financial Institutions Reform, Recovery, and Enforcement Act of 1989 (the “Act”). Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook, Autry, Hanrahan, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

Subcontractor Strength Will Drive Industry’s Ability to Meet Demand, Overcome Challenges

October 10, 2022 — Anwar Ghauche - Construction Executive
Owners, developers and general contractors get a lot of notoriety for construction projects, especially in these infrastructure-focused times. However, the subcontractor is truly the one under the microscope, as this group requires the most care and attention to ensure the owners and operators are able to meet accelerating demand and public expectations. The challenges in the current environment are many. Inflation and supply chain disruptions are highly detrimental to specialty trades in the mechanical, electrical, plumbing, drywall and other areas. Reports show that the construction industry, in particular, has seen an increase of over 20% in the cost of supplies and building materials in the last year alone and, in some cases, over 90% since the start of the pandemic. While these costs are passed along to the owner, the subcontractor still retains significant cash flow risk. This truth is amplified in a volatile market. As if the cost was not enough, equipment and material shortages coupled with rising interest rates only compound the problem—and tenfold for small businesses. Subcontractors are likely to feel the greatest pressure from supply-related issues. Inflation combined with supply chain shortages require subcontractors to prepare earlier for projects and, when possible, purchase materials upfront. However, the consequence of this preliminary preparation equates to further strains on cash flow. In an effort to remain aligned on schedules and budgets, subcontractors frequently buy all of a project’s materials as soon as a contract is signed—if not before. Reprinted courtesy of Anwar Ghauche, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES