Seattle Washington Building Expert Directory

Court Bars Licensed Contractor From Seeking Compensation for Work Performed by Unlicensed Sub

June 06, 2022 — Garret Murai - California Construction Law Blog
It all started with a tree. A eucalyptus tree to be exact. What followed is one of the more important cases to be decided under Business and Professions Code section 7031 in recent years. Yes, that Section 7031. The statute variously described by the state’s courts as “harsh[ ],” draconian” and “unjust,” but, importantly, nevertheless valid. Under Section 7031, an unlicensed contractor is barred from seeking compensation for work requiring a contractor’s license. This has been called the “shield.” However, in addition to the “shield,” project owners can also employ Section 7031’s “sword,” and seek disgorgement of all monies paid to an unlicensed contractor. Section 7031’s “shield” and “sword” applies even if the project owner knew that the contractor was unlicensed. They also apply even if the unlicensed contractor’s work was flawless. And they also apply even if a contractor was unlicensed during a portion of its work. This is because, as courts have stated, Section 7031 is a consumer protection statute intended to protect the public from unlicensed contractors and applies irrespective of the equities. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Formal Request for Time Extension Not Always Required to Support Constructive Acceleration

April 25, 2022 — David Adelstein - Florida Construction Legal Updates
Does a constructive acceleration claim require the contractor to always request an extension of time which is then denied by the owner? While this is certainly the preference and the contractor should be requesting an extension of time as a matter of course for an excusable delay, the answer is NO! in certain circumstances. This is conveyed in the factually detailed case discussed below where a formal request for an extension of time was not required for the contractor to support its constructive acceleration claim. But first, what is constructive acceleration: Constructive acceleration “occurs when the government demands compliance with an original contract deadline, despite excusable delay by the contractor.” The Federal Circuit in Fraser defined the elements of constructive acceleration as follows: (1) that the contractor encountered a delay that is excusable under the contract; (2) that the contractor made a timely and sufficient request for an extension of the contract schedule; (3) that the government denied the contractor’s request for an extension or failed to act on it within a reasonable time; (4) that the government insisted on completion of the contract within a period shorter than the period to which the contractor would be entitled by taking into account the period of excusable delay, after which the contractor notified the government that it regarded the alleged order to accelerate as a constructive change in the contract; and (5) that the contractor was required to expend extra resources to compensate for the lost time and remain on schedule. Nova Group/Tutor-Saliba v. U.S., 2022 WL 815826, *42 (Fed.Cl. 2022) quoting Fraser Constr. Co. v. U.S., 384 F.3d 1354, 1361 (Fed. Cir. 2004) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Does a Broker Forfeit His or Her Commission for Technical Non-Compliance with Department of Real Estate Statutory Requirements?

September 14, 2020 — Kevin J. Parker - Snell & Wilmer Real Estate Litigation Blog
In a recent Arizona Court of Appeals case, CK Revocable Trust v. My Home Group Real Estate LLC, 2020 WL 4306183 (7/28/2020), the Court of Appeals addressed the distinction between “substantive” and “technical” statutory requirements for real estate broker commission agreements. The Court explained that failure to comply with a substantive requirement would preclude the broker from recovering a commission, but failure to comply with a technical requirement would not. As examples of such substantive requirements, the Court identified the statutory requirement that the broker be licensed at the time the claim for commission arose, and the statutory requirement that the listing agreement be signed by both the broker and the client. Read the court decision
Read the full story...
Reprinted courtesy of Kevin J. Parker, Snell & Wilmer
Mr. Parker may be contacted at kparker@swlaw.com

Is a Text a Writing?

June 10, 2024 — Michael Yelle - Ahlers Cressman & Sleight PLLC
Is a text message a writing? Project communication is constantly evolving, and text messages are an increasingly common way teams share pictures, video, and provide project updates. When texting is part of the communication flow on a project, contractors and owners might text approvals for extra work, notices of changed conditions, or other information that could be a basis for a change order. In a text exchange about a compensable event, the notice, reply, and approval are all saved on the phone. But contracts often contain specific requirements for a contractor or subcontractor to request changes and authorization to proceed may be specifically required in writing. For example, the Associated General Contractors of Washington – 2018 Standard Subcontract says the “Subcontractor shall make no claims for extras unless the same shall be agreed upon in writing by Contractor prior to performance of any such extra work.” (emphasis added). The AGC subcontract doesn’t define “writing,” so the subcontractor and contractor might wonder if a text message exchange about a potentially compensable event was an “agreement in writing.” Read the court decision
Read the full story...
Reprinted courtesy of Michael Yelle, Ahlers Cressman & Sleight PLLC
Mr. Yelle may be contacted at michael.yelle@acslawyers.com

Traub Lieberman Attorneys Recognized as 2021 New York – Metro Super Lawyers®

October 18, 2021 — Traub Lieberman
Traub Lieberman is pleased to announce that six Partners from the Hawthorne, NY Office have been selected to the 2021 New York - Metro Super Lawyers list. 2021 New York – Metro Super Lawyers

Jonathan Harwood – Professional Liability
Lisa Rolle – Construction Litigation
Christopher Russo – Professional Liability
Lisa Shrewsberry – Professional Liability
Stephen Straus – Insurance Coverage
Richard Traub – Insurance Coverage

Read the court decision
Read the full story...
Reprinted courtesy of Traub Lieberman

Massachusetts Appellate Court Confirms Construction Defects are Not Covered Under Commercial General Liability Policies

January 21, 2025 — Bill Wilson - Construction Law Zone
In a case of first impression in Massachusetts, Lessard v. R.C. Havens & Sons, Inc., 104 Mass. App. Ct. 572 (2024), the Appellate Court confirmed that construction defects, without more, do not constitute property damage within the meaning of a commercial general liability policy (CGL). In Lessard, the homeowners filed suit against an insured homebuilder for construction defects in their home. After the homeowners won a jury verdict, the homebuilder’s insurer intervened and sought a declaratory judgment that it owed no duty to indemnify the homebuilder under its CGL policy. The superior court entered a declaratory judgment in favor of the insurer, and the homeowners appealed. Read the court decision
Read the full story...
Reprinted courtesy of Bill Wilson, Robinson & Cole LLP
Mr. Wilson may be contacted at wwilson@rc.com

City Sues over Leaking Sewer System

October 25, 2013 — CDJ STAFF
The city of Storm Lake, Iowa completed a $3.6 million sewer project only year ago, but the system is leaking untreated water into residents properties. The Pilot-Tribune reports that “not all the sewage lines broke,” but the city still needed to check the entire system for damage. The Southwest Shoreline Sanitary District has filed a lawsuit against Lessard Contracting, the firm that built the system. Bob Bergendoff, one of the sanitary district trustees said that “the main thing right now is whether the lines are properly installed.” Steve Anderson, another trustee, said that discussions with Lessard are getting “next to nowhere.” Read the court decision
Read the full story...
Reprinted courtesy of

Client Alert: Court Settles Conflict between CCP and Rules of Court Regarding Demurrer Deadline Following Amended Complaint

August 20, 2014 — R. Bryan Martin and Kristian B. Moriarty - Haight Brown & Bonesteel LLP
In Carlton v. Dr. Pepper Snapple Group, Inc. (No. E056566, filed 8/14/2014), The Court of Appeal, Fourth Appellate District, held a demurrer was timely filed in compliance with California Code of Civil Procedure (“CCP”) section 471.5, despite being filed after the 10-day filing period prescribed in California Rule of Court 3.1320(j). This case appears to settle the conflict that existed between the CCP and the Rules of Court as to the timing of demurrers following amendments to Complaints. Prior to this case, the validity of Rule of Court 3.1320(j)(2) was unclear as it arguably conflicted with CCP Section 471.5, which requires defendants to “answer” an amended complaint within 30 days after service. At the same time, it was not clear that CCP Section 471.5 applied to amendments after a demurrer had been sustained, and it was even more unclear whether the statutory 30-day period to “answer” an amended complaint foreclosed the shorter 10-day period prescribed under Rule of Court 3.1320(j)(2) for a demurrer or motion to strike. On July 15, 2011, Plaintiff filed a Complaint against Dr. Pepper Snapple Group, Inc. (“Dr. Pepper”) and others. On October 24, 2011, Plaintiff filed a First Amended Complaint (“FAC”). Dr. Pepper demurred to the FAC on various grounds. On January 5, 2012, the trial court sustained the demurrer in part, and overruled it in part. The Court granted Plaintiff 30 days to amend the FAC. Reprinted courtesy of R. Bryan Martin, Haight Brown & Bonesteel LLP and Kristian B. Moriarty, Haight Brown & Bonesteel LLP Mr. Martin may be contacted at bmartin@hbblaw.com, Mr. Moriarty may be contacted at kmoriarty@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES