SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Differing Site Conditions: What to Expect from the Court When You Encounter the Unexpected

September 05, 2022 — Margarita Kutsin - Ahlers Cressman & Sleight
[1]Seattle Tunnel Partners (“STP”), a joint venture of Dragados USA and Tutor Perini, entered into a $1.4 billion contract with the Washington State Department of Transportation (“WSDOT”) to replace the Highway 99 viaduct. In December 2013, a tunnel boring machine (“TBM”) bearing the moniker “Bertha,” then the largest TBM ever built, measuring 425 feet long and 57 feet in diameter, struck an underground pipe. Shortly after the impact, Bertha overheated and eventually could no longer make forward progress. A massive repair effort ensued causing a 2.5-year delay in reaching substantial completion. WSDOT sued STP for the delay, seeking liquidated damages of $57 million. In response, STP argued its delay was excusable because it was caused by Bertha’s impact with the pipe, and the steel well casing was a Differing Site Condition (DSC) undisclosed in the contract documents. STP asserted counterclaims against WSDOT, alleging breach of contract and seeking $300 million in damages. Ultimately, a jury found that the steel well casing on the pipe was not a DSC, foreclosing STP’s excusable delay defense and counterclaims, and resulting in a $57 million verdict, plus interest, in favor of WSDOT. Read the court decision
Read the full story...
Reprinted courtesy of Margarita Kutsin, Ahlers Cressman & Sleight
Ms. Kutsin may be contacted at margarita.kutsin@acslawyers.com

---

Hawaii Federal District Court Denies Title Insurer's Motion for Summary Judgment

February 01, 2022 — Tred R. Eyerly - Insurance Law Hawaii
In a rare title insurance dispute before the federal district court in Hawaii, the court denied the insurer's motion for summary judgment while granting the insured's motion for summary judgment. First Am. Title Ins. Co. v. GS Industries, LLC, 2021 U.S. Dist. LEXIS 240601 (D. Haw. Dec. 16, 2021). GS Industries, LLC took ownership of a parcel of real property located fronting Waipa Lane in Honolulu. The property used four buildings and a parking area for 50 cars. GS obtained a title insurance policy from First American. The policy insured GS' fee simple interest in the property in the amount of $3,500,000. The policy insured GS "against loss or damage, not exceeding $3,500,000, sustained or incurred by GS by reason of . . . not right of access to and from the land,." The policy did not identify any issues with access to the property and did not define "access." A portion of Waipa Lane was owned by the City and County of Honolulu. Parcel 86 and Parcel 91 on Waipa Lane were privately owned. (Private Waipa Lane Parcels). Vehicular access to (ingress) and from (egress) the property was via Waipa Lane. Ingress was made via the publicly owned portion of Waipa Lane. Vehicular egress was made via the Private Waipa Lane Parcels. The City of Honolulu maintained the Private Waipa Lane Parcels and considered them to be pubic. None of the owners of Parcels 86 or 91 notified GS of their intent to block the use of Waipa Lane. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Notice and Claims Provisions In Contracts Matter…A Lot

February 27, 2023 — David Adelstein - Florida Construction Legal Updates
Technical contractual provisions in contracts can carry the day. Whether you like it or not, and whether you appreciate the significance of the provisions, they matter. Notice provisions in a contract mean something. Following the claims procedure in a contract means something. The moment you think they don’t mean anything is the moment they will be thrown in your face and used as a basis to deny your position for additional money or time. You may think these provisions are being used as a “gotcha” tactic. They very well might be. But these are provisions included in the contract you agreed to so you know this risk before any basis for additional money or time even arises. The recent bench trial opinion in Metalizing Technical Services, LLC v. Berkshire Hathaway Specialty Ins. Co., 2023 WL 385413 (S.D.Fla. 2023) illustrates the reality of not properly complying with such provisions. The keys when dealing with any notice or claims provision, or really any technical provision in your contract, is to (a) negotiate the risk before you sign the contract, (b) chart the provisions so your team know how to ensure compliance, and (c) make sure you comply with them. Period! Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Contractor’s Unwritten Contractual Claim Denied by Sovereign Immunity; Mandamus Does Not Help

September 22, 2016 — David R. Cook Jr. – AHHC Construction Law Blog
In a very well-reasoned opinion, the Supreme Court of Georgia upheld the denial of a contractor’s unwritten-contract claim against a county based on sovereign immunity. Based on an alleged oral contract, Contractor built a sewer pumping station for the County in exchange for an interest in the station’s pumping capacity. When the County denied Contractor’s demand for an interest, he filed suit. As noted in many prior posts, the Georgia constitution reaffirms sovereign immunity of the state – which the courts interpret to include counties. One common exception in the public works area is the Constitution’s “ex contractu clause,” which waives sovereign immunity for claims based on written contracts. Of course, a precondition to the waiver of sovereign immunity is the existence of a written contract – which Contractor did not have. Applying these rules, the court affirmed the denial of Contractor’s claims based on contract and quasi contract. In the absence of a written contract, there can be no contractual claim against the County. The same rule applies for quasi-contractual claims. Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook, Autry, Hanrahan, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

---

Arizona Supreme Court Holds a Credit Bid at a Trustee’s Sale Should Not be Credited to a Title Insurer Under a Standard Lender’s Title Policy To the Extent the Bid Exceeds the Collateral’s Fair Market Value

March 01, 2017 — Richard H. Herold - Snell & Wilmer Real Estate Litigation Blog
The Arizona Supreme Court recently addressed what impact, if any, a lender’s credit bid at an Arizona trustee’s sale has on an insurer’s liability under Sections 2, 7 and 9 of the standard’s lender’s title policy (“Policy”), holding in Equity Income Partners, LP v. Chicago Title Insurance Company, 241 Ariz. 334, 387 P.3d 1263 (February 7, 2017) as follows: 1. Section 2 of the Policy, entitled “Continuation of Insurance,” not Section 9, entitled “Reduction of Insurance; Reduction or Termination of Liability,” applies when a lender acquires property at a trustee sale by “either a full- or partial-credit bid” since Section 2 directly addresses the existence and amount of coverage in such circumstances. Id. at 1267. Read the court decision
Read the full story...
Reprinted courtesy of Richard H. Herold, Snell & Wilmer
Mr. Herold may be contacted at rherold@swlaw.com

---

Construction Industry Survey Says Optimism Hits All-Time High

March 26, 2014 — Beverley BevenFlorez-CDJ STAFF
The Nashville Business Journal reported that “construction optimism has been growing exponentially since it hit an all-time low in 2009.” Furthermore, “Wells Fargo's 2014 Construction Industry Forecast saw the Optimism Quotient rise to an all-time high of 124 after a survey that was performed in January.” Reasons for the rise, according to Wells Fargo National Sales Manager John Crum, include “more capital available from banks, more public jobs and state and local governments being able to shore up their money supplies,” as quoted by the Nashville Business Journal. Read the court decision
Read the full story...
Reprinted courtesy of

---

Trump, Infrastructure and the Construction Industry

March 01, 2017 — Garret Murai – California Construction Law Blog
It’s been a whirlwind since Donald Trump became President. Some might even say a tornado. Many believed (including myself) that he couldn’t win. I was wrong. Some also believed (again, including myself) that he wouldn’t make good on his campaign promises. So far, he has. While I usually don’t like being wrong, if there’s one thing I couldn’t be happier being wrong about, it’s President Trump’s promises to rebuild the nation’s infrastructure. So, what can the construction industry expect under our first developer-turned-POTUS, Donald Trump, who is arguably the most exciting President for the construction industry since FDR? Where We Are Today The American Society of Engineers, in its oft-cited infrastructure “Report Card,” gave nation’s infrastructure an overall grade of D+, with an estimated investment infusion of $3.6 trillion needed by 2020 just to keep the nation’s infrastructure in “good” (note, not “great”) repair. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

---

Injured Subcontractor Employee Asserts Premise Liability Claim Against General Contractor

March 22, 2021 — David Adelstein - Florida Construction Legal Updates
In an interesting opinion, an injured employee of an electrical subcontractor sued the general contractor of a parking garage project under a premise liability theory after being injured when stepping on an uncovered floor drain at the project site. There is no discussion in the opinion as to workers compensation immunity. Rather, the discussion centers on the injured employee’s premise liability claim as to whether the general contractor “breached its duty to maintain the premises in a reasonably safe condition by leaving the drain uncovered and failing to warn of the danger of the uncovered drain.” Pratus v. Marzucco’s Construction & Coatings, Inc., 46 Fla.L.Weekly D186a (Fla. 2d DCA 2021) The trial court granted summary judgment in favor of the general contractor finding that the drain was open and obvious on the site. The Second District Court of Appeal reversed the summary judgment with a discussion as to premise liability claims, particularly as it pertains to a business invitee, which is what the injured employee of the electrical subcontractor was. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---