The Construction Project is Late—Allocation of Delay
November 17, 2016 —
David Adelstein – Florida Construction Legal UpdatesThe construction project is late. Very late. The owner is upset and notifies the contractor that it is assessing liquidated damages. The contractor, in turn, claims that the project is late because of excusable, compensable delays and, perhaps, excusable, noncompensable delays. This is a common and unfortunate story between an owner and contractor on any late construction project. Now the fun begins regarding the allocation of the delay!
Through previous articles, I discussed that in this scenario the burden really falls on the contractor to establish that the liquidated damages were improperly assessed against it and, thus, it is entitled to additional time and/or extended general conditions as a result of excusable delays. Naturally, this requires the contractor to develop a critical path analysis (time impact analysis) allocating the impacts / delays (and the reasons for the impacts/ delays) to the project completion date. The reason the burden really falls on the contractor is because the owner’s burden is relatively easy – the project was not complete on time pursuant to the contract and any approved changed orders.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Katz, Barron, Squitero, Faust, Friedberg, English & Allen, P.A.Mr. Adelstein may be contacted at
dma@katzbarron.com
The “Program Accessibility” Exception for Public Entities Under the ADA
September 10, 2014 —
Garret Murai – California Construction Law BlogPublic owners, as well as private owners and tenants of commercial and retail properties, are at risk of lawsuits brought under the Americans with Disabilities Act of 1990 (“ADA”) and related state law alleging that their facilities are not accessible by those with disabilities.
A common misperception among private owners and tenants is that facilities constructed before the ADA went into effect in 1992 are exempt or “grandfathered” from the ADA’s requirements. Not so. At least generally. If, however, you are a public entity, there is such an exception. Lucky you.
Under the ADA, public facilities constructed prior to January 26, 1992 need not be “accessible to and usable by individuals with disabilities” so long as a public entity’s “service[s], program[s] and activit[ies], when viewed in [their] entirety, [are] readily accessible to and usable by individuals with disabilities.” Known as “program accessibility,” the exception has left many public entities scratching their heads as to what they can and must do.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Kronick Moskovitz Tiedemann & GirardMr. Murai may be contacted at
gmurai@kmtg.com
Florida Legislative Change Extends Completed Operations Tail for Condominium Projects
December 10, 2024 —
Holly A. Rice - Saxe Doernberger & Vita, P.C.The Florida Legislature recently passed House Bill 1021 which amended Florida Statute § 718.124. The July 1, 2024 amendment changes Florida’s statute of repose (“SOR”) trigger date for condominium projects. Now, the SOR trigger for existing condominium projects will be governed by Florida Statute §718.124, not Florida Statute § 95.11. Most critically, Florida Statute § 718.124 changes the trigger events for when the “clock” starts running and impacts how long the SOR runs. Notably, Florida Statute § 718.124 already governed the trigger event for the statute of limitations (“SOR”) for condominium projects.
One important overarching takeaway for contractors to carefully assess is that the change in the “trigger” event may result in the SOR concluding at a later date than originally planned – affecting time on the risk and, critically, the availability of insurance. The standard approach of using a static 10-year completed operations tail on a condominium construction insurance program may now be insufficient in certain circumstances.
Read the court decisionRead the full story...Reprinted courtesy of
Holly A. Rice, Saxe Doernberger & Vita, P.C.Ms. Rice may be contacted at
HRice@sdvlaw.com
Did New York Zero Tolerance Campaign Improve Jobsite Safety?
December 13, 2021 —
Neil Flynn - Construction ExecutiveConstruction work is one of the most dangerous jobs in America, accounting for 19% of all workplace deaths in 2019. In New York City, that number is almost 50% higher, with construction accidents accounting for a quarter of all workplace deaths. One of the most positive developments in this area, despite the presence of COVID-19, has been the recent implementation of the “Zero Tolerance” campaign by the New York City’s Department of Buildings.
The goal of the DOB’s latest construction safety campaign was to reduce the number of building site injuries and fatalities by implementing a zero-tolerance standard. While it is too premature to measure the program’s efficiency, a
preliminary analysis of the first three months’ results appear to be nothing short of impressive.
Reprinted courtesy of
Neil Flynn, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Mr. Flynn may be contacted at
nf@plattalaw.com
Get Smarter About Electric Construction Equipment
October 24, 2022 —
CONEXPO-CON/AGGMILWAUKEE – Sustainability in the construction industry is being advanced by the public and private sectors. Governments are adopting more clean-air regulations at local and regional levels and companies are adopting sustainability policies and asking partners to help them meet their targets.
Consequently, many manufacturers have already developed – or are in the process of developing – electric-powered construction equipment to meet increasing emissions regulations, provide efficiency improvements, and lower operating costs. All electric, electric/hydraulic, and battery-operated versions rival their diesel and gas counterparts in performance, notes
Joel Honeyman, Vice President of Global Innovation at
Bobcat.
THE CHANGING INDUSTRY
“People say electric machines are not going to perform as well as a diesel machine,” Honeyman observes. “That is simply not true. In many cases they can outperform them.”
“Many people are so used to what they have and are afraid of new technology. Some companies have been running diesel- and gas-powered equipment for 40, 50 years. Hydraulics have been on equipment for 80 years. Adjusting to an electric-powered machine is quite a paradigm shift.”
About the Association of Equipment Manufacturers (AEM)
AEM is the North America-based international trade group representing off-road equipment manufacturers and suppliers with more than 1,000 companies and more than 200 product lines in the agriculture and construction-related industry sectors worldwide. The equipment manufacturing industry in the United States supports 2.8 million jobs and contributes roughly $288 billion to the economy every year.
About CONEXPO-CON/AGG
Held every three years, CONEXPO-CON/AGG is the must-attend event for construction industry professionals. The show features the latest equipment, products, services and technologies for the construction industry, as well as industry-leading education. The next CONEXPO-CON/AGG will be held March 14-18, 2023 in Las Vegas, Nevada. For more information on CONEXPO-CON/AGG, visit https://www.conexpoconagg.com. Learn more about
excavator tech here.
Read the court decisionRead the full story...Reprinted courtesy of
Toolbox Talk Series Recap - Guided Choice Mediation
November 05, 2024 —
Douglas J. Mackin - The Dispute ResolverIn the September 26, 2024 edition of Division 1's Toolbox Talk Series,
Clifford Shapiro presented on Guided Choice Mediation (“GCM”) and how it can lead to better outcomes in construction disputes.
GCM is an approach to mediation that focuses on early and efficient dispute resolution, which prominent mediators created as a public interest project.
Shapiro described his particular variant of GCM based on his experience while acknowledging that other Guided Choice Mediators’ processes may differ from his in various ways. Shapiro’s brand of GCM focuses on ensuring that parties have reasonable expectations and appropriate settlement authority prior to arriving at a mediation. Some of the strategies to help accomplish these noble goals are (i) early mediator engagement, (ii) mediator facilitation of information exchange, (iii) mediator involvement with insurance issues (particularly important in construction defect cases, especially those with multiple defendants), (iii) pre-mediation ex parte meetings, and (iv) mediator participation in risk analysis. These strategies are not typical in the more traditional/historic approach to mediation in which mediation is scheduled based on a scheduling order, mediation statements are sent to the mediator roughly a week before the scheduled mediation (and sometimes not even shared with anyone other than the mediator), and the parties speak with the mediator for the first time on the day of the mediation.
Read the court decisionRead the full story...Reprinted courtesy of
Douglas J. Mackin, Cozen O’ConnorMr. Mackin may be contacted at
dmackin@cozen.com
The Most Expensive Apartment Listings in New York That Are Not in Manhattan
August 26, 2015 —
James Tarmy & Oshrat Carmiel – BloombergApartments for very wealthy New Yorkers have remained mostly within the city’s smallest borough. Until now.
The record price for a Brooklyn home broke the $15 million threshold this summer, and by now it’s widely accepted that New York’s outer boroughs are not much of a bargain, growing further out of reach for the aspiring homeowner. The rush of new construction in gentrifying neighborhoods has pushed up the price of land, and that’s caused construction costs to rise, too. Eventually, to make a profit, developers have to build luxury buildings, according to Jonathan Miller, the president of New York appraiser Miller Samuel.
“We have this perfect storm,” he says. “Everybody gets the same idea at the same time, so materials and labor are at a premium. Throw in the high price of land at each locale, and you’ve got to build a luxury product.”
Reprinted courtesy of
James Tarmy, Bloomberg and
Oshrat Carmiel, Bloomberg Read the court decisionRead the full story...Reprinted courtesy of
Appellate Attorney’s Fees and the Significant Issues Test
June 29, 2017 —
David Adelstein - Florida Construction Legal UpdatesThe significant issues test to determine the prevailing party in construction lien actions (which, by the way, also applies to breach of contract actions) applies to appellate attorney’s fees too! Under this test, the trial court has discretion to determine which party prevailed on the significant issues of the case for purposes of attorney’s fees. The trial court also has discretion to determine that neither party was the prevailing party for purposes of attorney’s fees.
In a recent decision, Bauer v. Ready Windows Sales & Service Corp., 42 Fla. L. Weekly D1417a (Fla. 3d DCA 2017), there were competing motions for appellate attorney’s fees. Both parties believed they should be deemed the prevailing party under Florida Statute s. 713.29 (statute that authorizes prevailing party attorney’s fees under Florida’s Construction Lien Law). The appellate court held that neither party was the prevailing party under the significant issues test: “[W]e conclude that each party lost on their appeal, while each party successfully defended that part of the judgment in their favor on the other party’s cross-appeal. Because both parties prevailed on significant issues, this Court finds that appellate fees are not warranted for either party.”
Bauer, supra. Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Florida Construction Legal UpdatesMr. Adelstein may be contacted at
Dadelstein@gmail.com