CAMBRIDGE MASSACHUSETTS BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Excess-Escape Other Insurance Provision Unenforceable to Avoid Defense Cost Contribution Despite Placement in Policy’s Coverage Grant

April 20, 2016 — Christopher Kendrick & Valerie A. Moore - Haight Brown & Bonesteel, LLP
In Certain Underwriters at Lloyds, London v. Arch Specialty Ins. Co. (No. C072500; filed 4/11/16), a California appeals court found an “other insurance” provision unenforceable to excuse defense contribution between successive primary insurers, regardless of the fact that the limiting language was contained in the policy’s coverage grant. Certain Underwriters and Arch each insured Framecon over successive policy periods. Framecon was sued by a developer in a series of construction defect actions, and tendered to both insurers. Underwriters agreed to defend under a reservation of rights but Arch declined, citing the wording of its insuring agreement, which stated: Reprinted courtesy of Christopher Kendrick, Haight Brown & Bonesteel LLP and Valerie A. Moore, Haight Brown & Bonesteel LLP Mr. Kendrick may be contacted at ckendrick@hbblaw.com Ms. Moore may be contacted at vmoore@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Haight Welcomes Robert S. Rucci

August 26, 2015 — Robert S. Rucci – Haight Brown & Bonesteel LLP
Haight Brown & Bonesteel LLP welcomes new partner Robert S. Rucci. Mr. Rucci joins Haight’s San Diego office in the Construction Law, General Liability and Risk Management & Insurance Law Practice Groups. For 25 years, Mr. Rucci has specialized in defending design professionals, businesses and their employees in addition to representing clients against declaratory relief, breach of contract and bad faith litigation. During his career, he has tried 60 cases to defense verdict and successfully resolved countless matters via mediation, arbitration and settlement conference. His extensive litigation experience is invaluable to our clients. Haight Brown & Bonesteel LLP 402 West Broadway Suite 1850 San Diego, CA 92101 www.hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of Robert S. Rucci, Haight Brown & Bonesteel LLP
Mr. Rucci may be contacted at rrucci@hbblaw.com

---

Construction Defects #10 On DBJ’s Top News Stories of 2015

December 10, 2015 — Beverley BevenFlorez-CDJ STAFF
The Denver Business Journal’s top 15 news stories of 2015 covers the “Battle Over Construction Defects.” Some developers and other groups have blamed the lack of condominium development in Denver and other Colorado cities on the state’s defect laws. After a construction-defects reform bill failed to pass the Colorado Legislature, several cities passed construction defect-related ordinances, according to the Denver Business Journal: “In November the Denver City Council voted 12-1 to approve an ordinance aimed at making it harder to file class-action lawsuits over construction defects within the city.” Read the court decision
Read the full story...
Reprinted courtesy of

---

How Pennsylvania’s Supreme Court Decision Affects Coverage of Faulty Workmanship Claims

March 31, 2014 — Beverley BevenFlorez-CDJ STAFF
Darin J. McMullen of the firm Anderson Kill explained how a recent opinion by the Pennsylvania Supreme Court allows “Pennsylvania policyholders” to “more confidently challenge insurance companies’ denials of faulty workmanship claims.” The decision in Indalex Inc. v. National Union Fire Ins. Co. of Pittsburgh, PA, 2013 Pa. Super 311 (Dec. 3, 2013) “reverses a nearly decade-long trend of Pennsylvania decisions narrowing the scope of insurance coverage for construction and defect-related claims under commercial general liability insurance policies,” according to McMullen. “Equally important, the Indalex ruling dealt a blow to the insurance industry’s continual efforts to win overbroad expansion of the rulings in Kvaerner Metals Div. of Kvaerner U.S., Inc. v. Commercial Union Ins. Co., Millers Capital Ins. Co. v. Gambone Bros. Dev. Co., and Erie Ins. Exchange v. Abbott Furnace Co., which found that claims of faulty workmanship in some circumstances may not constitute coverage-triggering ‘occurrences.’” Read the court decision
Read the full story...
Reprinted courtesy of

---

Pending Sales of U.S. Existing Homes Rise Most in Four Years

July 01, 2014 — Jeanna Smialek – Bloomberg
The number of contracts to purchase previously owned U.S. homes jumped in May by the most in more than four years, a sign the residential-real estate market is rebounding after a slow start to the year. The pending home sales index climbed 6.1 percent, the biggest advance since April 2010, after a revised 0.5 percent increase in April, the National Association of Realtors said today in Washington. The gain exceeded the most optimistic estimate in a Bloomberg survey of economists, whose median forecast called for a 1.5 percent gain. Housing demand is benefiting from cheaper borrowing costs, a stronger employment outlook and easier access to credit for some households. At the same time, higher prices and limited income gains are keeping the improvement in the residential real estate from becoming more broad-based. Read the court decision
Read the full story...
Reprinted courtesy of Jeanna Smialek, Bloomberg
Ms. Smialek may be contacted at jsmialek1@bloomberg.net

---

Delays Caused When Government (Owner) Pushes Contractor’s Work Into Rainy / Adverse Weather Season

January 13, 2020 — David Adelstein - Florida Construction Legal Updates
There are a number of horizontal construction projects where a contractor’s sequence of work and schedule is predicated on avoiding the rainy season (or certain force majeure events). The reason is that the rainy season will result in delays due to the inability to work (and work efficiently) during the adverse weather (including flooding caused by the weather). If the work is pushed into the rainy season, is such delay compensable if the government (or owner) delayed the project that pushed work out into the rainy season? It very well can be. For example, in Meridian Engineering Co. v. U.S., 2019 WL 4594233 (Fed. Cl. 2019), a contractor was hired by the Army Corps of Engineers to construct a flood control project for a channel in Arizona. Due to delays, including those caused by the government, the project was pushed into the monsoon season, which caused additional delays largely due to flooding caused by the heavy rain. One issue was whether such delays were compensable to the contractor – the government raised the argument that the contractor assumed the risk of potential flooding from the rainy season. The Court found this argument unconvincing:

[The contractor’s] initial construction schedule planned for a completion of the channel invert work, a necessary step in protecting the site from flooding, to be completed by late June 2008…[M]any issues arose in the project’s early stages that led to cumulative substantial delay, including those caused by the government’s failure….The government cannot now claim that [the contractor] assumed the risk of flooding from monsoon season when the government was largely responsible for [the contractor’s] inability to complete the project prior to the beginning of the monsoon season. Simply put, the government cannot escape liability for flood damages when the government is responsible for causing the contractor to be working during the flood-prone season. Meridian Engineering, 2019 WL at *7 (internal citations omitted)

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Sun, Sand and Stir-Fry? Miami Woos Chinese for Property: Cities

February 18, 2015 — Blake Schmidt and Bill Faries – Bloomberg
(Bloomberg) -- Miami has a Little Havana and Little Haiti, a neighborhood known as Westonzuela and even the Venetian Islands. What it doesn’t have is a Chinatown. Shan-Jie Li wants to do something about it. The developer from the city of Linyi in China’s wintry northeast aims to make Florida’s most-populous metropolitan area, with its clean beaches and tropical climate, a destination for Chinese property investors. “We are focused on bringing to Miami the new wave of Chinese who are wealthy and educated,” Li said in a phone interview via a translator. “The environment in Miami makes for a very suitable lifestyle. Playing golf and going to the beach are huge attractions.” Reprinted courtesy of Blake Schmidt, Bloomberg and Bill Faries, Bloomberg Mr. Schmidt may be contacted at bschmidt16@bloomberg.net; Mr. Faries may be contacted at wfaries@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of

---

Residential Mortgage Lenders and Servicers Beware of Changes to Rule 3002.1

December 08, 2016 — James C. Vandermark & Amy E. Vulio – White and Williams LLP
This December, residential mortgage lenders and servicers will be required to comply with new requirements for providing notices of payment changes (PCNs) and post-petition fees, expenses, and charges (PPFNs) to mortgage borrowers in Chapter 13 bankruptcies. While the new Federal Bankruptcy Rule 3002.1 will provide much needed clarity, it will also significantly increase the number of PCNs and PPFNs that lenders will need to file. Reprinted courtesy of James C. Vandermark, White and Williams LLP and Amy E. Vulio, White and Williams LLP Mr. Vandermark may be contacted at vandermarkj@whiteandwilliams.com Ms. Vulpio may be contacted at vulpioa@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

---