Fairfield Connecticut Building Expert Directory

Coverage Denied for Ensuing Loss After Foundation Damage

February 07, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The insureds attempt to secure coverage for ensuing losses after foundation damage was properly denied by the insurer. Walker v. Nationwide Prop. & Cas. Ins. Co., 2014 U.S. Dist. LEXIS 6683 (W.D. Tex. Jan. 6, 2014). Two provisions excluding coverage under Nationwide's homeowner's policy were key to the court's decision. Exclusion 3 (e) barred coverage for "continuous or repeated seepage or leakage of water or stem over a period of time . . . ." Exclusion 3 (f) (6) precluded coverage for settling, cracking, shrinking, bulging or expansion of pavements, patios, foundations, walls, floors, roof or ceiling. The policy also included a Dwelling Foundation Endorsement which covered settling, cracking, bulging of floor slabs or footings that supported the dwelling caused by seepage or leakage of water or steam. This endorsement stated the limit of liability would not exceed an amount equal to 15% of the limit of coverage for the dwelling. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Construction Litigation Roundup: “Stop - In the Name of the Law!”

August 07, 2023 — Daniel Lund III - Lexology
In a 5-4 decision, the United States Supreme Court settled a split among the federal appellate circuits on whether appeal of a district court refusal to compel arbitration stays the underlying litigation in the district court. Having been denied relief by the district court on its motion to compel arbitration, plaintiff filed an interlocutory appeal to the Ninth Circuit under the Federal Arbitration Act, 9 U. S. C. §16(a), which authorizes an interlocutory appeal from the denial of a motion to compel arbitration. Plaintiff asked the district court to stay its proceedings pending resolution of the interlocutory appeal. The district court refused, and the Ninth Circuit also declined to stay the lower court proceedings pending appeal. Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

A Retrospective As-Built Schedule Analysis Can Be Used to Support Delay

May 23, 2022 — David Adelstein - Florida Construction Legal Updates
Delay claims are part of construction. There should be no surprise why. Time is money. A delay claim should be accompanied by expert opinions that bolster evidence that gets introduced. The party against whom the delay claim is made will also have an expert – a rebuttal expert. Not surprisingly, each of the experts will rely on a different critical path as to relates to the same project. The party claiming delay will rely on a critical path that shows the actions of the other party impacted their critical path and proximately caused the delay. This will be refuted by the opposing expert that will challenge the critical path and the actions claimed had no impact on the critical path (i.e., did not proximately cause the delay). Quintessential finger pointing! This was the situation in CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022), where the government terminated the contractor for convenience and the contractor claimed equitable adjustments for, among other things, delay. The contractor’s expert relied on an as-built critical path analysis by “retrospectively creating updates to insert between the contemporaneous updates.” Id., supra, n.3. The government’s expert did not do a retrospective as-built analysis and relied on only contemporaneous schedule updates. Id. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Climate-Proofing Your Home: Upgrades to Weather a Drought

January 03, 2022 — Todd Woody - Bloomberg
Climate-driven drought is making the once unthinkable foreseeable. Amid water shortages, your faucets could run dry, as has been a possibility in Marin County, California. Violate mandatory water restrictions and you might face steep fines or even a cutoff of service. With the western United States in the grip of an extreme drought, rivers and reservoirs are at record lows and some water utility districts in California have asked residents to curtail consumption by as much as 40%. A 2019 study found regions across the nation could face water shortages in the coming decades in part due to climate change. That puts a premium on making homes more resilient to drought by maximizing efficiency and minimizing waste through technologies that monitor consumption and recycle and capture water that would otherwise be lost. Read the court decision
Read the full story...
Reprinted courtesy of Todd Woody, Bloomberg

Denver Court Rules that Condo Owners Must Follow Arbitration Agreement

November 07, 2012 — CDJ STAFF
Prior to initiating a construction defect lawsuit, the Glass House Residential Association voted to invalidate the arbitration agreement that had been written into its declaration and bylaws by the developer and general contractor. After the association started their construction defect claims, the developer and general contractor argued that the case must go to arbitration, as the arbitration clause contained a provision that it could not be altered without the agreement of the developer and general contractor. The Denver District Court has ruled against that association, determining that the res triction was not in violation of Colorado condominium law. And, as a post from Polsinelli Shughart PC on JDSupra notes, the Colorado Common Interest Ownership Act encourages the use of arbitration procedures to settle disputes. The CCIOA does prohibit “certain restrictions on the homeowners association’s ability to amend the condominium declarations,” however, preserving an arbitration agreement is not one of them. Read the court decision
Read the full story...
Reprinted courtesy of

Statute of Limitations and Bad Faith Claims: Factors to Consider

May 16, 2022 — Anastasiya Collins - Saxe Doernberger & Vita
How much time do our clients have to bring a bad faith action against an insurer? Although we are not frequently asked this question, it is one that we constantly analyze before asserting a bad faith claim. To answer this question, we look to the statute of limitations, which is a law passed by a state legislative body that sets the maximum amount of time for a party to bring a claim based upon a particular cause of action. For policyholders, knowing which statute of limitations applies to their bad faith claim is critical because it indicates whether it is possible to initiate legal proceedings. In addition, it determines the amount in damages available in case of a successful resolution. Statute of Limitations in Breach of Contract vs. Tort Claims One key determinant of a statute of limitations for bad faith is whether the claim is brought as a tort or a breach of contract action. The consequence of framing bad faith as a tort is that a policyholder is not just limited to contract damages. The policyholder can also receive recourse for emotional distress, pain, suffering, punitive damages, attorney’s fees, and other damages that the court may consider appropriate. Unfortunately, however, not every jurisdiction allows plaintiffs to bring bad faith actions as tort claims. While, for example, courts in California, Colorado, and Connecticut allow bad faith claims sounding in tort, courts in jurisdictions such as Tennessee do not. Read the court decision
Read the full story...
Reprinted courtesy of Anastasiya Collins, Saxe Doernberger & Vita
Ms. Collins may be contacted at ACollins@sdvlaw.com

Owners Should Serve Request for Sworn Statement of Account on Lienor

August 10, 2017 — David Adelstein - Florida Construction Legal Updates
When an owner receives a construction lien, an owner should serve the lienor with a Request for Sworn Statement of Account. The Request for Sworn Statement is authorized by Florida Statute s. 713.16(2) and should be in the following form: REQUEST FOR SWORN STATEMENT OF ACCOUNT WARNING: YOUR FAILURE TO FURNISH THE REQUESTED STATEMENT, SIGNED UNDER OATH, WITHIN 30 DAYS OR THE FURNISHING OF A FALSE STATEMENT WILL RESULT IN THE LOSS OF YOUR LIEN. To: (Lienor’s name and address) The undersigned hereby demands a written statement under oath of his or her account showing the nature of the labor or services performed and to be performed, if any, the materials furnished, the materials to be furnished, if known, the amount paid on account to date, the amount due, and the amount to become due, if known, as of the date of the statement for the improvement of real property identified as (property description) . (name of contractor) (name of the lienor’s customer, as set forth in the lienor’s Notice to Owner, if such notice has been served) (signature and address of owner) (date of request for sworn statement of account) From both an owner and lienor’s perspective, the bolded, capitalized language is key. It states that if the lienor fails to respond under oath within 30 days, it will LOSE its lien. That is a very punitive measure for a lienor’s failure to respond, meaning a lienor should absolutely respond, no questions asked. Plus, a lienor’s response to a Request for Sworn Statement of Account is not a burdensome ordeal. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at Dadelstein@gmail.com

Colorado Court of Appeals’ Ruling Highlights Dangers of Excessive Public Works Claims

August 26, 2024 — David M. McLain – Colorado Construction Litigation
In the case of Ralph L. Wadsworth Construction Company, LLC v. Regional Rail Partners (2024 COA 78), the Colorado Court of Appeals reviewed a complex contract dispute related to the design and construction of a transit rail line. The project, commissioned by the Regional Transportation District (“RTD”), involved a collaboration between Regional Rail Partners and Ralph L. Wadsworth Construction Company (“Wadsworth”) to build the North Metro Rail Line between Denver Union Station and Thornton. Key Facts:

Contracts and Payments: Regional Rail Partners contracted with Wadsworth to perform specific construction tasks with a total contract value of $60,210,783. By the time of the trial, Regional Rail had paid almost $58 million of this amount.
Disputes and Delays: The project faced numerous delays and disputes, leading to Wadsworth claiming significant financial damages attributed to these disruptions. In April 2018, Wadsworth’s expert estimated that Regional Rail owed them $12,408,496.60.

Read the court decision
Read the full story...
Reprinted courtesy of David McLain, Higgins, Hopkins, McLain & Roswell, LLC
Mr. McLain may be contacted at mclain@hhmrlaw.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES