Seattle Washington Building Expert Directory

Texas Supreme Court Declines to Waive Sovereign Immunity in Premises Defect Case

April 10, 2023 — Starr M. Forster - Lewis Brisbois
Houston, Texas (March 30, 2023) – The Supreme Court of Texas recently upheld a Thirteenth Court of Appeals’ judgment finding that the plaintiffs in a premises defect case brought against the Texas Department of Transportation (TxDOT) had failed to raise a fact issue regarding the creation of a dangerous condition and, consequently, failed to establish waiver of the defendant’s sovereign immunity. Daniel K. Christ and Nicole D. Salinas v. Tex. DOT, et al., No. 21-0728, 66 Tex. Sup. Ct. J. 306, 2023 Tex. LEXIS 128, at *1 (Feb 10, 2023). Background Plaintiffs Daniel Christ and his wife, Nicole Salinas (the Christs), were riding their motorcycle through a construction zone when they collided with a vehicle that crossed into their lane. TxDOT’s traffic control plan for the related construction project called for the placement of concrete barriers between opposing travel lanes; however, once construction on the project began, TxDOT’s contractor determined there was not enough space for the concrete barriers and revised the traffic control plan to substitute yellow stripes and buttons for the concrete barriers. TxDOT never approved the revised traffic control plan in writing; however, TxDOT’s contractor contended TxDOT orally approved of the change. The Christs sued the driver of the other vehicle, TxDOT, and TxDOT’s contractor. Read the court decision
Read the full story...
Reprinted courtesy of Starr M. Forster, Lewis Brisbois
Ms. Forster may be contacted at Starr.Forster@lewisbrisbois.com

Question of Parties' Intent Prevents Summary Judgment for Insurer

December 02, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The insurer's and insured's intent as to which entities were to be insured prevented the insurer's motion for summary judgment. Chaus v. State Farm Fire & Cas. Co., 2015 U.S. Dist. LEXIS 136311 (E.D. La. Oct. 5, 2015). Water damage from a broken pipe occurred at the insured's building. Blaze Chaus LLC owned the building.The building was occupied by two entities which provided health care services: Dr. Kelly G. Burkenstock, M.D. and Azure Spa, Inc. Dr. Burkenstock was the sole owner of all three entities. The application for commercial insurance was submitted by "Dr. Kelly G. Burkenstock, d/b/a/ Blaze Chaus LLC." The application requested a "Physicians and Surgeons Endorsement" and reflected that the business activities of the applicant as "Internal Medicine Doctor." Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Construction Defects Claims Can Be Limited by Contract Says Washington Court

February 11, 2013 — CDJ STAFF
The firm Lane Powell has issued a construction law update on the recent Washington Supreme Court decision in Washington State Major League Baseball Public Facility District v. The Baseball Club of Seattle, LP. In the underlying construction defect claim, the Public Facility District found defects in the structural steel at Seattle’s Safeco Field. The contractor, Huber, Hunt & Nichols-Kiewit Construction Company claimed that construction claims could not be made, as it was barred by the statue of repose. Washington State has a six-year limitation on its statute of repose, however, the court noted that the contract contained a clause that, as noted by Lane Powell, “any alleged causes of action automatically accrue at substantial contemplation,” instead of within six years of substantial completion. The court concluded that the statue of repose could be rendered inoperative by contract. Further, the court found that these contract clauses pertained to subcontractors as well. Nevertheless, as PFD is a subdivision of the state, the court found that no statue of limitations could be appled. Read the court decision
Read the full story...
Reprinted courtesy of

Mitsui Fudosan Said to Consider Rebuilding Tilted Apartments

October 28, 2015 — Katsuyo Kuwako – Bloomberg
Mitsui Fudosan Co., Japan’s biggest developer, is considering rebuilding an apartment complex in Yokohama after one of the four buildings started to tilt, according to a person familiar with the situation. Kiyotaka Fujibayashi, president and chief executive officer of Mitsui Fudosan Residential Co., on Thursday explained the plans to residents, according to the person, who asked not to be named because the information is private. Another option the company is studying is buying back the apartments from the residents at a price higher than what they had paid, the person said. The project was sold in 2006. Mitsui Fudosan is the latest developer to come under scrutiny for defects at residential projects in the Tokyo area. Mitsubishi Estate Co., Japan’s biggest developer by market value, said last year it would rebuild a residential complex in the upscale Aoyama neighborhood after finding faults. Also last year, Sekisui House Ltd. said it would reconstruct a residential complex that was being built by Taisei Corp. after finding some columns were missing reinforcing metals. Read the court decision
Read the full story...
Reprinted courtesy of Katsuyo Kuwako, Bloomberg

A Court-Side Seat: As SCOTUS Decides Another Regulatory “Takings” Case, a Flurry of Action at EPA

July 19, 2021 — Anthony B. Cavender - Gravel2Gavel
This is a brief account of some of the important environmental and administrative law cases recently decided. THE U.S. SUPREME COURT Pakdel v. City and County of San Francisco On June 28, 2021, the Supreme Court decided this regulatory “takings” case, and, in a Per Curium opinion, reversed the Ninth Circuit’s ruling that that petitioners had to exhaust their state administrative remedies before they could file this lawsuit under 42 USC Section 1983. The City government had already come to a sufficient regulatory conclusion, and the Constitution does not require additional processing. In so ruling, the Ninth Circuit ignored last term’s decision in Knick v. Township of Scott. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

Trump Order Waives Project Environment Rules to Push COVID-19 Recovery

June 15, 2020 — Debra K. Rubin, Mary B. Powers & Jim Parsons - Engineering News-Record
Citing the "national emergency" spurred by the COVID-19 pandemic's economic hit, President Donald Trump has signed an executive order that directs federal agencies to bypass environmental laws to expedite infrastructure projects, including those on federal lands, as a stimulus. Reprinted courtesy of Engineering News-Record attorneys Debra K. Rubin, Mary B. Powers and Jim Parsons Ms. Rubin may be contacted at rubind@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Blackstone Said in $1.7 Billion Deal to Buy Apartments

January 21, 2015 — Hui-yong Yu – Bloomberg
Blackstone Group LP (BX), the biggest owner of U.S. single-family houses, agreed to buy 36 apartment properties across the country for about $1.7 billion as it expands its rental business, according to two people with knowledge of the transaction. The low-rise, garden-style properties are being sold by Praedium Group, a New York-based real estate investment firm, and contain about 11,000 apartments, said the people, who asked not to be identified because the deal is private. About half of the buildings are in California, Washington, D.C., and Boston, with the rest located around the U.S., they said. Read the court decision
Read the full story...
Reprinted courtesy of Hui-yong Yu, Bloomberg
Hui-yong Yu may be contacted at hyu@bloomberg.net

Defining Constructive Acceleration

March 22, 2021 — David Adelstein - Florida Construction Legal Updates
When it comes to the definition of “constructive acceleration,” the case of Fraser Const. Co. v. U.S., 384 F.3d 1354 (Fed.Cir. 2004) is a cited case and contains an instructive definition, quoted below, for proving a constructive acceleration claim. In a nutshell, a constructive acceleration claim is when the contractor incurs added costs for trying to complete the contract on time when it should be provided extensions of time to perform based on excusable delay (i.e., delay not caused by the contractor). These added costs could be bringing in additional supervision to manage the work, adding manpower to perform the work, working overtime, working weekends, adding more shift work, stacking trades, etc. However, just because a contractor claims they have been constructively accelerated does not make it so. The contractor has to actually ask for an extension of time based on an excusable delay and the owner either denied the extension or unreasonably sat on the request for an extension of time; thus, the contractor incurred significant costs to accelerate in order to finish the project on time because it was deprived of a requested time extension for excusable delay. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES