Seattle Washington Building Expert Directory

Is an Initial Decision Maker, Project Neutral, or Dispute Resolution Board Right for You?

July 14, 2016 — David Adelstein – Florida Construction Legal Updates
Recently, I participated in a roundtable hosted by JAMS with experienced South Florida construction lawyers and retired circuit court judges to discuss the pros and cons of utilizing an initial decision maker (“IDM” and also referred to as a project neutral) or a dispute resolution board (“DRB”) to resolve disputes on construction projects. The IDM and DRB are designed to resolve disputes, specifically claims (whether for time, money, or both), during construction to keep the project progressing forward without being bogged down by the inevitable claim. There are numerous avenues to resolve disputes without resorting to filing a lawsuit or a demand for arbitration. The thought is that dispute resolution will be facilitated by techniques designed to assist the parties with the resolution of claims during construction. While direct discussions between the parties, meetings with the executives for business decision purposes, mediations, etc., are certainly helpful, sometimes these avenues are simply not enough to truly resolve a complex claim on a construction project that occurs during construction. Read the court decision
Read the full story...
Reprinted courtesy of David M. Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Hotel Claims Construction Defect Could Have Caused Collapse

December 30, 2013 — CDJ STAFF
The owners of the Crowne Plaza New Orleans Airport, in Kenner, Louisiana, have filed a lawsuit claiming that a defective beam installed during renovations put the building at risk of collapse, reports The Louisiana Record. The hotel was sold to its current owners, 2929 Williams Blvd, LLC, in 2006, and the renovations began after Hurricane Katrina in 2007. The renovations converted an indoor pool area into a ballroom. The renovations were finished in 2008, but hotel staff noticed the walls and ceiling of the ballroom were sagging by September 2011. A structural engineer determined that a main beam had failed, risking collapse of the entire building. The hotel owners set upon repairing the structure and now seek reimbursement. 2929 Williams Blvd., LLC is suing Trimark Constructors LLC, Kyle Associates LLC, and Avengo Baily & Associates, Inc. for an unspecified amount of damages. Read the court decision
Read the full story...
Reprinted courtesy of

Discussion of History of Construction Defect Litigation in California

September 10, 2014 — William M. Kaufman – Construction Lawyers Blog
California literally wrote the book on construction defect litigation. Construction defects began to surface after World War II due to cheap track homes being constructed haphazardly on a large scale. Throughout the 1960s, developers began utilizing the services of subcontractors to build massive developments. Rather than having their own employees perform the work, developers began relying more heavily on the specialty subcontractors to perform quality control functions. In 1969, the California Supreme Court expanded liability for developers with respect to residential housing through the concept of strict liability for mass produced homes. Strict liability defendants in construction defect cases may include builders of mass-produced homes, building site developers, component part manufacturers, and material suppliers. Courts have noted that there is little distinction between the “mass production and sale of homes and the mass production and sale of automobiles, and the pertinent overriding policy considerations are the same.” Kriegler v. Eichler Homes, Inc. (1969) 269 Cal. App. 2d 224, 227 (1969). Accordingly, developers of mass-produced tract homes may be held strictly liable whether or not there is privity of contract. Ibid. Courts have held, however, that there is no strict liability against contractors or sub-contractors. See Ranchwood Communities v. Jim Beat Construction (1996) 57 Cal.Rptr.2d 386; La Jolla Village Homeowners’ Assn., Inc. v. Superior Court (1989) 261 Cal.Rptr. 146. Within ten years, attorneys in California were using strict liability theories to seek compensation for homeowners. The initial strict liability lawsuits in California in the 70s and 80s generally applied to condominium projects. The Construction defect “industry” began to take off in the 1980s due to the housing boom and the enforcement of strict liability claims by the courts. Reprinted courtesy of William M. Kaufman, Lockhart Park LP Mr. Kaufman may be contacted at wkaufman@lockhartpark.com, and you may visit the firm's website at www.lockhartpark.com Read the court decision
Read the full story...
Reprinted courtesy of

Traub Lieberman Attorneys Recognized as 2022 Illinois Super Lawyers® and Rising Stars

February 21, 2022 — Traub Lieberman
Traub Lieberman is pleased to announce that two Partners from the Chicago, IL office have been selected to the 2022 Illinois Super Lawyers list. In addition, three Partners have been named to the 2022 Super Lawyers Rising Stars list. 2022 Illinois Super Lawyers

Brian Bassett – Insurance Coverage
Dana Rice – Insurance Coverage

2022 Super Lawyers Rising Stars

Brandt Allen – Insurance Coverage
Jessica Kull – Civil Litigation: Defense
Jeremy Macklin – Insurance Coverage

Read the court decision
Read the full story...
Reprinted courtesy of Traub Lieberman

New Hampshire’s Statute of Repose for Improvements to Real Property Does Not Apply to Product Manufacturers

April 22, 2019 — Gus Sara - The Subrogation Strategist
In United Services Automobile Association v. Broan-Nutone, LLC, No. 218 2017 CV 01113, [1] the Superior Court of Rockingham County, New Hampshire recently considered whether the eight-year statute of repose for improvements to real property applied to the manufacturer of a ceiling ventilation fan that was installed in the property during its original construction. The court held that New Hampshire’s statute of repose did not apply to the manufacturer because it was not involved in incorporating its product into the property. In 2012, Chad St. Francis purchased a home in Northwood, New Hampshire. The home was originally constructed in 2008, at which time a Broan-Nutone ceiling ventilation fan was installed in the first-floor bathroom. In 2016, a fire occurred at the home. United Services Automobile Association (USAA) provided property casualty insurance for the home and paid Mr. St. Francis for the damage. In 2017, USAA filed a subrogation lawsuit against Broan-Nutone, alleging that its ceiling fan caused the fire due to a design defect within the product. Broan-Nutone filed a motion for summary judgment on grounds that USAA’s action was barred by New Hampshire’s statute of repose for improvements to real property. Read the court decision
Read the full story...
Reprinted courtesy of Gus Sara, White and Williams LLP
Mr. Sara may be contacted at sarag@whiteandwilliams.com

PA Superior Court Provides Clarification on Definition of CGL “Occurrence” When Property Damage Is Caused by Faulty Building Conditions

September 30, 2019 — Anthony L. Miscioscia & Konrad R. Krebs - White and Williams LLP
The standard for an “occurrence” under a commercial general liability (CGL) insurance policy has been addressed on several occasions by Pennsylvania courts when an insured has allegedly performed faulty workmanship on a construction project. Specifically, in Pennsylvania, a claim for damages arising from an insured’s performance of faulty workmanship pursuant to a construction contract, where the only damage is to property supplied by the insured or worked on by the insured, does not constitute an “occurrence” under the standard commercial general liability insurance policy definition. But what about the circumstance when the insured has failed to perform contractual duties where the claim is for property damage to property not supplied by the insured or unrelated to the service the insured contracted to provide? The Pennsylvania Superior Court recently addressed this question in Pennsylvania Manufacturers Indemnity Co. v. Pottstown Industrial Complex LP, No. 3489 EDA 2018, 2019 Pa. Super. 223, 2019 Pa. Super. LEXIS 729* (Pa. Super. 2019). Pottstown Industrial Complex arose out of an underlying dispute between a landlord and a commercial tenant who had leased space to store its product inventory. The tenant alleged that the landlord was responsible under the lease for keeping the roof “in serviceable condition in repair.” Notwithstanding this responsibility, the tenant alleged that the landlord failed to properly maintain and repair the roof, resulting in leaks and flooding during four separate rainstorms, destroying over $700,000 in inventory. The tenant specifically alleged that the floods were caused by poor caulking of the roof, gaps and separations in the roofing membrane, undersized drain openings, and accumulated debris and clogged drains. The insurer filed a declaratory judgment action, seeking a determination that there was no coverage under a commercial general liability policy issued to the landlord. Following a motion for judgment on the pleadings, the trial court entered an order in favor of the insurer, holding that allegations of inadequate roof repairs were claims for faulty workmanship and were not covered under Kvaerner Metals Division of Kvaerner U.S., Inc. v. Commercial Union Insurance Co., 908 A.2d 888 (Pa. 2006) and Millers Capital Insurance Co. v. Gambone Brothers Development Co., 941 A.2d 706 (Pa. Super. 2007). Reprinted courtesy of Anthony Miscioscia, White and Williams LLP and Konrad Krebs, White and Williams LLP Mr. Miscioscia may be contacted at misciosciaa@whiteandwilliams.com Mr. Krebs may be contacted at krebsk@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

Safety Officials Investigating Death From Fall

September 09, 2011 — CDJ STAFF

California safety officials are looking into the circumstances surrounding the death of a construction worker who fell from a roof in Tiburon, California. Another worker found Gabriel Vasquez unconscious at the site. Vasquez was later pronounced dead. The State Division of Occupational Safety and Health are trying to determine how Vasquez fell.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES