Will European Insurers’ Positive Response to COVID-19 Claims Influence US Insurers?
August 10, 2020 —
Sergio F. Oehninger & Daniel Hentschel - Hunton Insurance Recovery BlogLast month we wrote a piece concerning AXA’s agreement to pay COVID-19 related business interruption claims by a group of restaurants in France after a court ruled that the restaurants’ revenue losses resulting from COVID-19 and related government orders were covered under its insurance policies. AXA reportedly has already agreed to pay over 200 COVID-19 related claims.
Another European insurer recently made headlines for similar reasons. Despite initially denying liability, Swiss insurance company, Helvetia Insurance, announced that most of its policyholders in the hospitality industry have accepted settlements following coverage disputes for COVID-19 related business interruption losses. The settlements reportedly included policyholders from Switzerland, Austria, and Germany.
The positive response from the European insurers appears to have influenced the insurance industry across the continent. For instance, in the U.K., the Financial Conduct Authority announced that it is taking certain insurers to court to seek clarity as to coverage for COVID-19 related losses. In Germany, the government and a group of insurers reached an agreement whereby the government will pay for 70% of business interruption losses for policyholders in the hospitality industry, and the insurers will pay for half of the business interruption losses not covered by the government.
Reprinted courtesy of
Sergio F. Oehninger, Hunton Andrews Kurth and
Daniel Hentschel, Hunton Andrews Kurth
Mr. Oehninger may be contacted at soehninger@HuntonAK.com
Mr. Hentschel may be contacted at dhentschel@HuntonAK.com
Read the court decisionRead the full story...Reprinted courtesy of
Harmon Towers to Be Demolished without Being Finished
October 02, 2013 —
CDJ STAFFEngineering.com looks at why the Harmon Tower in Las Vegas will be coming down at some point in the future. Construction stopped, unfinished in 2008. Taking the building down will cost about $400 million, which the building’s owner feels that the developer should pay.
Inspectors concluded that the building did not meet the earthquake specifications for Las Vegas. The contractor claimed that the fault was due to the design specifications and that the supports were further weakened during destructive testing.
Read the court decisionRead the full story...Reprinted courtesy of
"On Second Thought"
October 28, 2024 —
Daniel Lund III - LexologyRehearing requests are seldom granted by courts, and when they are, there’s usually something uniquely compelling in the request and the granting.
So is the case in a matter involving monies deposited in the registry of the federal court in New Orleans related to work performed on cleanup after Hurricanes Maria and Irma in the U.S. Virgin Islands. The party depositing monies – which represented subcontract sums paid to it by the general contractor – held back several hundred thousand dollars based on withholding provisions in the various contracts in play. The Court was tasked with evaluating not only a pay-when-paid provision in the subcontract of the claiming party, but also incorporation of the terms of a higher tiered contract which allowed for the withholding.
The Court initially granted summary judgment allowing the monies to be withheld. However, on request for rehearing, it was pointed up that while monies could be retained for purposes of covering attorney’s fees and costs related to litigation initiated by the plaintiff subcontractor’s vendors, there was a particular process for that withholding – and an assertion that the process was not followed.
Read the court decisionRead the full story...Reprinted courtesy of
Daniel Lund III, PhelpsMr. Lund may be contacted at
daniel.lund@phelps.com
Updates to the CEQA Guidelines Have Been Finalized
February 06, 2019 —
Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law BlogThe California Natural Resources Agency (CNRA) recently posted final adopted text for amendments to the CEQA Guidelines. The result of over five years of development efforts by the Governor’s Office of Planning & Research and CNRA, the amendments are the most comprehensive update to the CEQA Guidelines since 1998. In “Natural Resources Agency Finalizes Updates to the CEQA Guidelines,” Pillsbury environmental attorneys Norman F. Carlin, Kevin Ashe and Eric Moorman explore the wide range of issues covered in the amendments, including the new Vehicle-Miles-Traveled (VMT) methodology for analyzing transportation impacts; use of regulatory standards as significance thresholds; environmental baselines; and numerous procedural and technical improvements.
Read the court decisionRead the full story...Reprinted courtesy of
Pillsbury's Construction & Real Estate Law Team
Pacing in Construction Scheduling Disputes
September 14, 2017 —
Luke Mecklenburg - Snell & Wilmer Real Estate Litigation BlogOn a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway.
However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48.
Read the court decisionRead the full story...Reprinted courtesy of
Luke Mecklenburg, Snell & WilmerMr. Mecklenburg may be contacted at
lmecklenburg@swlaw.com
The International Codes Development Process is Changing to Continue Building Code Modernization
March 06, 2023 —
The International Code CouncilWashington D.C., March 02, 2023 (GLOBE NEWSWIRE) -- The International Code Council is revising its rigorous code development process. The changes will take effect in 2024-2026 for the development of the 2027 International Codes (I-Codes) and will move the development process to an integrated and continuous three-year cycle.
In the new timeline, year one will include two Committee Action Hearings for Group A Codes; year two will include two Committee Action Hearings for Group B Codes; and year three will be the joint Public Comment Hearings and Online Governmental Consensus Vote for both Group A and B Codes.
The addition of the second Committee Actions Hearings in year one and two will foster a more in-depth vetting of code change proposals, allowing an opportunity for the committee members to review and evaluate the original proposals and consider the submitted responses. This also provides more opportunity for proponents to build consensus for their code change proposal and ensure the best version of their intended improvement to the existing codes.
Additionally, with combined Public Comment Hearings in the third year, voting members are able to vote on all suggested changes to the next edition of the I-Codes at one time. The updated process also provides more opportunity for proposed new referenced standards to be developed and finalized on a consistent timeline regardless of the group (Group A or B) with which they are associated.
About the International Code Council
The International Code Council is the leading global source of model codes and standards and building safety solutions. Code Council codes, standards and solutions are used to ensure safe, affordable and sustainable communities and buildings worldwide.
Read the court decisionRead the full story...Reprinted courtesy of
London Is Falling Down and It's Because of Climate Change
July 16, 2023 —
Priscila Azevedo Rocha - BloombergBritain’s increasingly
extreme weather is shaking the very foundations of its centuries-old history.
The nation has been experiencing prolonged
periods of drought after wet winters since last year. That’s causing the porous rock beneath vast parts of southeast of England, including London, to move more than usual, cracking or tilting many of the city’s historical homes in the plushest neighborhoods. The damage has triggered the highest insurance payout in almost two decades, with experts warning that it could get worse.
The London clay, the type of soil that covers most of these areas, “is quite unique” because it can shrink and swell a lot, according to
Lee Jones, a geological engineer at the British Geological Survey who has studied UK hazards for over 30 years. “The wetter it gets, the more it swells and expands and the drier it gets, the more it shrinks and cracks,” he said, adding that future temperature extremes will exacerbate the impact on buildings and roads.
Read the court decisionRead the full story...Reprinted courtesy of
Priscila Azevedo Rocha, Bloomberg
Remodels Replace Construction in Redding
September 09, 2011 —
CDJ STAFFThe Record Searchlight reports that while new construction is down in Redding, California, residential and commercial remodel permits are up 17 percent. By August 2010, there had been 63 housing and commercial business starts in Redding, while this year has seen only 15.
One such remodel, that of Parkview Market, will cost about $201,000. Safeway is planning on two $80,000 remodels of its grocery stores in Redding. In all, the 150 building permits for remodels are worth a total of $2.8 million.
Read the full story…
Read the court decisionRead the full story...Reprinted courtesy of