Fairfield Connecticut Building Expert Directory

Significant Issues Test Applies to Fraudulent Claims to Determine Attorney’s Fees

January 13, 2017 — David Adelstein - Florida Construction Legal Updates
Construction lienors need to appreciate on the frontend that recovering statutory attorney’s fees in a construction lien action is NOT automatic—far from it. This is because the prevailing party for purposes of attorney’s fees in a construction lien action is determined by the “significant issues test,” a subjective test with no bright line standards based on who the trial court finds prevailed on the significant issues in the case. If you want to talk about the subjective and convoluted nature of recovering attorney’s fees in a construction lien action under the significant issues test, a recent opinion by the Fourth District Court of Appeal is unfortunately another nail in the coffin. In Newman v. Guerra, 2017 WL 33702 (Fla. 4th DCA 2017), a contractor recorded a construction lien on a residential renovation project and filed a lien foreclosure lawsuit. The homeowner countersued the contractor and asserted a fraudulent lien claim pursuant to Florida Statute s. 713.31. An evidentiary hearing was held on whether the lien was a fraudulent lien and the trial court held that the lien was fraudulent (therefore unenforceable) because it included amounts that were not lienable under the law. The remaining claims including both parties’ breach of contract claims proceeded to trial. There was no attorney’s fees provision in the contract. At the conclusion of the trial, the court found that the contractor was entitled a monetary judgment on its breach of contract claim. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dadelstein@gmail.com

Kahana & Feld P.C. Enhances Client Offerings, Expands Litigation Firm Leadership

March 22, 2017 — Kahana & Feld, P.C.
SANTA ANA, Calif., March 9, 2017 – Celebrating 10 successful years of practice, Managing Partner Amir M. Kahana, Esq. , of Kahana & Feld P.C. (formally Kahana Law), is pleased to announce he has added as name partner Jason Daniel Feld, Esq., expanding client offerings to include insurance defense and bolstering its construction defect and real estate law practice. Feld joins the AV Preeminent firm that for the past decade has become known for its prowess in general business litigation matters, including cases involving employment, construction, real estate and intellectual property law. The firm is home to a group of proven trial attorneys who are among Southern California’s top rated counsel. Feld brings 18 years of experience, with his practice focusing on defending homebuilders, contractors and developers in Arizona, Texas and California. He primarily chooses to represent smaller, family-owned and operated clients, providing the unique opportunity to also assist with overall best practices and risk prevention. In addition, Feld serves on several prominent insurance carrier panels, allowing him to cultivate valuable relationships with the builder and contactor community. A resident of Tustin Ranch, Feld received his juris doctor cum laude from Whittier Law School and a bachelor’s degree from University of Houston. “Jason’s breadth of experience, leadership and work ethic are qualities I have admired throughout the many years of our friendship. He embodies the integrity and admirable character that are at the core of our firm’s fabric,” said Kahana, a resident of Irvine. “I am thrilled to have Jason join forces with our firm as we enter our second decade and are poised for significant growth. Our clients will benefit from our expanded areas of practice, allowing us to provide counsel and litigation support in a variety of areas.” Under Kahana’s leadership, the firm has become known for holding its client relationships in the highest regard while providing premier quality legal services and sound risk assessment at a reasonable cost. With integrity always coming first, the firm’s record of success extends well beyond the office as each associate is proudly involved in his or her community, donating time and resources to a variety of worthy community organizations. “I feel honored to join Amir and this talented and energetic firm,” said Feld. “I feel fortunate to have found a new home with partners and associates who share the same values and commitment to serving the community. I look forward to helping grow the firm in the years ahead.” About Kahana & Feld, P.C. Kahana & Feld, P. C. focuses on general business litigation and insurance defense, with particular emphasis on employment, real estate, construction defect and intellectual property litigation. The AV Preeminent firm is led by attorneys who have been named among Southern California’s Top Rated. The firm was founded with the goal of providing high-quality legal services at fair and reasonable rates. The firm believes that what defines attorneys is not their billing rates, but their record of success, and Kahana & Feld’s track record speaks for itself. For more information, please visit: http://www.kahanafeld.com Read the court decision
Read the full story...
Reprinted courtesy of

Groundbreaking on New Boulder Neighborhood

November 20, 2013 — CDJ STAFF
A new ten-acre neighborhood is springing up in northeast Boulder, Kalmia38. The development is being built by Markel Homes Construction Co. and Coast to Coast Residential Development. The first homes should be ready for residents by the second quarter of 2014, with building continuing on the project for about three years. Read the court decision
Read the full story...
Reprinted courtesy of

Contract’s Definition of “Substantial Completion” Does Not Apply to Third Party for Purposes of SOL, Holds Court of Appeal

June 15, 2020 — Garret Murai - California Construction Law Blog
Those of you in the construction industry know that the two primary statutes of limitation are the 4-year year statute of limitations for patent defects and 10-year statute of limitations for latent defects. Both statutes begin to run on “substantial completion.” In Hensel Phelps Construction Co. v. Superior Court of San Diego, Case No. D076264 (January 22, 2020), the 4th District Court of Appeal examined whether the term “substantial completion,” as used in Civil Code section 941, which applies to residential construction, can be defined by the parties’ contract and applied to third-parties. The Hensel Phelps Case Hensel Phelps Construction Co. entered into a prime construction contract with the owner and developer of a mixed-use project in San Diego. Hensel Phelps was the general contractor on the project. The project included a residential condominium tower which would eventually be managed and maintained by Smart Corner Owners Association. Smart Corners was not a party to the contract. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

U.S. Stocks Fall as Small Shares Tumble Amid Home Sales

September 24, 2014 — Joseph Ciolli and Callie Bost – Bloomberg
U.S. stocks fell, led by a plunge among small companies, as sales of existing homes unexpectedly dropped and China’s finance minister damped stimulus hopes. The Russell 2000 Index of small-cap stocks sank 1.6 percent, the most since July. Yahoo! Inc. (YHOO) dropped 2.3 percent to lead the Dow Jones Internet Composite Index to a one-month low. Alibaba Group Holding Ltd. slid 2.1 percent after surging in its trading debut Sept. 19. The Standard & Poor’s 500 Index dropped 0.7 percent to 1,997.37 at 11:24 a.m. in New York, after closing at a record Sept. 18. The benchmark gauge hasn’t had a four-day slide this year and hasn’t fallen 10 percent in three years. The Dow Jones Industrial Average slid 58.40 points, or 0.3 percent, to 17,221.34. Mr. Ciolli may be contacted at jciolli@bloomberg.net; Ms. Bost may be contacted at cbost2@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Joseph Ciolli and Callie Bost, Bloomberg

Pinterest Nixes Big San Francisco Lease Deal in Covid Scaleback

September 21, 2020 — Sophie Alexander - Bloomberg
Pinterest Inc. canceled a large office lease at a building to be constructed near its San Francisco headquarters, marking one of the most significant moves yet by a big tech company to scale back real estate plans in the city amid the Covid-19 pandemic. “As we analyze how our workplace will change in a post-Covid world, we are specifically rethinking where future employees could be based,” Todd Morgenfeld, Pinterest’s chief financial officer and head of business operations, said in a statement Friday. The social-sharing service is paying an $89.5 million termination fee to terminate its lease for 490,000 square feet (45,500 square meters) of space. It will keep its existing offices in the city. Read the court decision
Read the full story...
Reprinted courtesy of Sophie Alexander, Bloomberg

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

Subcontractors Must be Careful Providing Bonds when General Contractor Does Not

April 05, 2017 — Christopher G. Hill – Construction Law Musings
After I wrote the title to this post, I thought, “Well, that says it all, doesn’t it?” I also considered the fact that for those that read this construction law blog on a regular basis, I am likely stating the obvious. I then thought about the fact that there can be confusion regarding the purpose of bonds versus insurance. Couple this with the fact that Murphy was an optimist, and I thought this would be a good reminder. Bonds and insurance have one fundamental difference between them. When your construction company buys insurance, that insurance is meant to protect your company. When your company provides a payment and/or performance bond, that bond is there not to protect your company but to protect everyone else on the job and the project itself. Where insurance will pay for your company’s qualifying errors so that that money does not come out of the bottom line, a bond contract will have an indemnification agreement whereby anything paid by the surety will then be reimbursed by you and your company dollar for dollar (as opposed to just the premium). Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES