Fairfield Connecticut Building Expert Directory

A Retrospective As-Built Schedule Analysis Can Be Used to Support Delay

May 23, 2022 — David Adelstein - Florida Construction Legal Updates
Delay claims are part of construction. There should be no surprise why. Time is money. A delay claim should be accompanied by expert opinions that bolster evidence that gets introduced. The party against whom the delay claim is made will also have an expert – a rebuttal expert. Not surprisingly, each of the experts will rely on a different critical path as to relates to the same project. The party claiming delay will rely on a critical path that shows the actions of the other party impacted their critical path and proximately caused the delay. This will be refuted by the opposing expert that will challenge the critical path and the actions claimed had no impact on the critical path (i.e., did not proximately cause the delay). Quintessential finger pointing! This was the situation in CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022), where the government terminated the contractor for convenience and the contractor claimed equitable adjustments for, among other things, delay. The contractor’s expert relied on an as-built critical path analysis by “retrospectively creating updates to insert between the contemporaneous updates.” Id., supra, n.3. The government’s expert did not do a retrospective as-built analysis and relied on only contemporaneous schedule updates. Id. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

How a Maryland County Created the Gold Standard for Building Emissions Reduction

May 24, 2021 — Pam McFarland - Engineering News-Record
Montgomery County, Md. is generating significant buzz among U.S. municipalities aiming to reduce greenhouse gas emissions from buildings. Reprinted courtesy of Pam McFarland, Engineering News-Record ENR may be contacted at ENR.com@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

COVID-19 Case Remanded for Failure to Meet Amount in Controversy

September 14, 2020 — Tred R. Eyerly - Insurance Law Hawaii
The federal district court remanded to state court a loss of rent claim because the amount in controversy requirement was not met. Geragos & Geragos Fine Arts Bldg., LLC v. Travelers Indemn. Co., 2020 U.S Dist. LEXIS 127427 (C.D. Cal. July 20, 2020). Geragos suffered loss of rental income due to the COVID-19 tenant relief measures implemented in Los Angeles. The tenant relief orders would remain in effect for the duration of the emergency period, the end date of which was not presently set. Geragos submitted a claim for loss of rental income to Travelers. When the claim was denied, Geragos sued in state court. Travelers removed to federal district court. Geragos moved to remand the case back to state court for lack of subject matter jurisdiction. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Housing to Top Capital Spending in Next U.S. Growth Leg: Economy

September 24, 2014 — Shobhana Chandra – Bloomberg
Bruce Hottle’s $10,000 computer systems upgrade in February at his Pennsylvania concrete plant may be his last investment for another two years. More than 1,100 miles south in suburban Miami, Maggie Cruz-Ledon and her husband have set a 2015 deadline to buy a house, upping their budget in the process. Hottle’s and Cruz-Ledon’s plans represent a sneak peek into the next leg of the expansion. Housing and business capital spending, two areas closely tied to swings in the world’s largest economy, are poised to diverge as home construction gives growth more of a boost in the long run while investment in new plants and equipment shows less promise, according to economists at Goldman Sachs Group Inc. and Morgan Stanley. Read the court decision
Read the full story...
Reprinted courtesy of Shobhana Chandra, Bloomberg
Ms. Chandra may be contacted schandra1@bloomberg.net

Cold Stress Safety and Protection

February 27, 2023 — The Hartford Staff - The Hartford Insights
The best time to think about cold stress safety isn’t when it’s about to snow – it’s actually when it’s still warm out. “Construction firms and other businesses may start to think about protecting workers against the cold when frigid temperatures and the winter are right around the corner. But we’ve found that oftentimes, that may be too late to start thinking about cold stress prevention,” said Chris O’Hala, director of construction Risk Engineering at The Hartford. “Thinking about cold protection months ahead can prevent serious injuries, illnesses or even death.” O’Hala added that possible solutions for cold-related risks, like planning for temporary heat or building temporary enclosures, “require very specific planning, equipment and materials.” Read the court decision
Read the full story...
Reprinted courtesy of The Hartford Staff, The Hartford Insights

Federal Court Opinion Has Huge Impact on the Construction Industry

July 06, 2020 — Wally Zimolong - Supplemental Conditions
The United States District Court for the Eastern District of Pennsylvania in Philadelphia recently issued an opinion that should get the attention of any contractor or subcontractor performing work on a federal funded construction project. In U.S. ex rel IBEW Local 98 v. The Fairfield Company, the federal court held that a contractor on a SEPTA project could be held liable under the False Claims Act for failing to pay its workers under the Davis Bacon Act. The court found that liability was appropriate under the FCA even through the contractor did not knowingly violate the Davis Bacon Act. The court awarded the plaintiff over $1,000,000 in damages and an additional over $1,000,000 in attorneys fees. An Extremely Brief Primer on the FCA A full discussion of the FCA is beyond the realm of this blog post and you could write a book on FCA cases. But in a nutshell, the FCA prohibits a contractor from knowingly submitting a claim for payment to the federal government (or an entity receiving funding from the federal government, like SEPTA) that is false. Importantly, knowingly does not equal actual knowledge of the falsity of the claim. Rather, “reckless disregard of the truth or falsity” of the submission is sufficient. As explained below, this standard played an important role in the court’s decision and should give contractors performing work on federally funded projects pause. Read the court decision
Read the full story...
Reprinted courtesy of Wally Zimolong, Zimolong LLC
Mr. Zimolong may be contacted at wally@zimolonglaw.com

10 Haight Lawyers Recognized in Best Lawyers in America© 2022 and The Best Lawyers: Ones to Watch 2022

September 20, 2021 — Haight Brown & Bonesteel LLP
Three Haight Brown & Bonesteel LLP attorneys were selected for Best Lawyers in America© 2022.

Bruce Cleeland – Product Liability Litigation – Defendants
Peter Dubrawski – Product Liability Litigation – Defendants
Denis Moriarty – Insurance law

Seven Haight Brown & Bonesteel LLP attorneys were selected for Best Lawyers®: Ones to Watch 2022.

Courtney Arbucci – Personal Injury Litigation – Defendants; Product Liability Litigation – Defendants
Frances Brower – Product Liability Litigation – Defendants
Kyle DiNicola – Transportation Law
Arezoo Jamshidi – Appellate Practice
Jonna Lothyan – Appellate Practice
Kristian Moriarty – Transportation Law
Bethsaida Obra-White – Construction Law; Insurance Law; Personal Injury Litigation – Defendants

Read the court decision
Read the full story...
Reprinted courtesy of Haight Brown & Bonesteel LLP

Truck Hits Warning Beam That Falls, Kills Motorist at Las Vegas Bridge Project

July 11, 2022 — Doug Puppel - Engineering News-Record
A truck carrying an oversized load in northwest Las Vegas on Friday struck a steel beam near a bridge construction site, sending the beam crashing onto a following vehicle and killing its driver, according to the Nevada Dept. of Transportation. Reprinted courtesy of Doug Puppel, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES