Difficult Task for Court to Analyze Delay and Disorder on Construction Project
August 23, 2021 —
David Adelstein - Florida Construction Legal UpdatesOne of my favorites quotes from a case, and I am sure others in the construction industry feel the same way or can relate, is from the District of Columbia Court of Appeals in Blake Construction Co., Inc. v. C.J. Coakley Co., Inc., 431 A.2d 569, 575 (D.C. 1981):
We note parenthetically and at the outset that, except in the middle of a battlefield, nowhere must men coordinate the movement of other men and all materials in the midst of such chaos and with such limited certainty of present facts and future occurrences as in a huge construction project such as the building of this 100 million dollar hospital. Even the most painstaking planning frequently turns out to be mere conjecture and accommodation to changes must necessarily be of the rough, quick and ad hoc sort, analogous to ever-changing commands on the battlefield. Further, it is a difficult task for a court to be able to examine testimony and evidence in the quiet of a courtroom several years later concerning such confusion and then extract from them a determination of precisely when the disorder and constant readjustment, which is to be expected by any subcontractor on a job site, become so extreme, so debilitating and so unreasonable as to constitute a breach of contract between a contractor and a subcontractor.
Do you agree with this sentiment? The reality is that retrospectively analyzing delay on a complicated construction project with numerous moving parts on a day-by-day, hour-by-hour, basis is no easy feat. It is not easy for the parties and certainly not easy for courts to unravel. With every party claiming delay based on a retrospective analysis there will be another party with either a different delay analysis or providing credible cross examination as to flaws with the delay analysis. The same bodes true with loss of productivity / inefficiency claims and the particular case-specific facts are important, preferably with evidence such as photos, videos, notifications, daily reports, manpower reports, etc., supporting the facts. But the facts are complicated, and the delay analysis is complicated, and it is a difficult task for a trier of fact to unravel these facts.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Facebook Posts “Not Relevant” Rules Florida Appeals Court
February 07, 2014 —
Beverley BevenFlorez-CDJ STAFFA Cape Coral, Florida resident is suing the city and construction companies over alleged negligence “for failing to use reasonable care in keeping the construction site safe for pedestrians,” according to News-Press. The lawsuit was filed after a three-year old boy “jumped out of a wagon pulled by his aunt and darted across the construction zone before being” hit and dragged by a vehicle. The boy “suffers neurological problems from the crash.” The defendants wanted to use Facebook posts made by the Plaintiff about the city, contractors, and subcontractors, as evidence. However, the 2nd District Court of Appeals ruled that the Facebook posts were irrelevant to the case.
Todd Robert Falzone, the Plaintiff attorney, said that “it’s becoming more common for defense lawyers to try and introduce social media into any case, but the law is new and there isn’t a lot of guidance for lawyers or judges,” according to News-Press. The defendants’ attorneys did not return News-Press’s calls asking for comments.
Read the court decisionRead the full story...Reprinted courtesy of
Fifth Circuit Finds Duty to Defend Construction Defect Case
March 14, 2022 —
Tred R. Eyerly - Insurance Law HawaiiReversing the judgment of the district court, the Fifth Circuit found the insurer owed a defense in a construction defect case. Siplast, Inc. v. Emplrs Mut. Cas. Co., 2022 U.S. App. LEXIS 795 (5th Cir. Jan. 11, 2022).
The Archdiocese of New York sued various parties for a roofing project at a high school in the Bronx. Siplast, the roofing manufacturer, was included as a defendant. The underlying lawsuit arose from the Archdiocese purchase of a roof membrane system from Siplast. Siplast guaranteed that the roof membrane system would remain "in a watertight condition for a period of 20 years . . . or Siplast will repair the Roof Membrane System at its own expense."
After installation of the roof, school officials noticed water damage in the ceiling tiles throughout the school after a rain storm. Siplast attempted to repair the damage, but was unsuccessful. Siplast later informed the Archdiocese that the guarantee would not be honored regarding any permanent improvements of the roof. The Archdiocese filed suit against Siplast and the installing contractor. The cause of action against Siplast was for breach of the guarantee.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Recovering Unabsorbed Home Office Overhead Due to Delay
May 30, 2022 —
David Adelstein - Florida Construction Legal UpdatesIn the
preceding article, I discussed the use of a retrospective as-built delay analysis in a case before the Civilian Board of Contract Appeals (CBCA). This case also discussed a damages component in certain delay claims known as unabsorbed home office overhead—a challenging damages component to recover because this deals with indirect costs as opposed to direct costs.
Unabsorbed home office overhead is a damages component when the contractor is on standby, but this is NOT as easy as just claiming standby thereby you are automatically entitled to unabsorbed home office overhead. There are requirements that MUST be met.
To obtain an equitable adjustment for unabsorbed home office overhead as compensation for being on standby, [the contractor] must initially show “[1] a government-caused delay of uncertain duration,” that “[2] the delay extended the original time for performance” or precluded the contractor from finishing earlier than scheduled, and that “[3] the contractor [was] on standby and unable to take on other work during the delay period.
CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022) quoting Nicon, Inc. v. U.S., 331 F.3d 878, 883 (Fed. Cir. 2003).
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Top 10 Construction Contract Provisions – Changes and Claims
November 03, 2016 —
James R. Lynch – Ahlers & Cressman PLLCThis is the seventh post in our “Top 10 Construction Contract Provisions” series. Prior posts discussed
Price and Payment,
Liquidated Damages,
Consequential Damages – Part I and
Part II,
Indemnity,
Scope of Work, and
Flow-Down Provisions.
Today’s topic, Changes and Claims, is a contender for the top spot on our list, for both day-to-day impact on the job and importance in disputes. In fact, these provisions[i] are so variable and are involved in so many reported construction law decisions, that this post will not attempt to survey all their various forms, uses, or potential legal ramifications, but instead focuses on bottom line “best practices”—questions to consider as a general contractor, subcontractor, or owner when drafting, negotiating, or managing the Changes and Claims provisions of a contract. There is no “ideal” here, and the changes and claims procedures should be suited to the project, owner, contractor(s), likely issues, and other project-specific considerations. Key considerations include the following:
1. How prescriptive is the Change Order process? At one end of the spectrum, a Change Order provision may include requirements for written direction and request by the owner and formal response by the contractor, with pricing and specific supporting data or documentation, in addition to strict timelines for response, execution, and performance, precise methods to determine the resulting contract adjustment, limits on the type or extent of adjustment, or terms defining the effect of a signed Change Order, e.g. to what extent related claims or impacts might be extinguished. At the other end of the spectrum, the Change Order provision might simply recognize that the owner may direct changes, and the parties intend to document the directions and resulting compensation in a Change Order, with no further elaboration. There is no universal ideal on this spectrum. A highly defined and prescriptive process may be appropriate for a complex, high value, multi-stakeholder project on which significant changes are likely. The same process would be an inefficient waste of resources on a small and simple project where significant changes are unlikely and the parties would be unlikely to comply with more formal procedures.
Read the court decisionRead the full story...Reprinted courtesy of
James R. Lynch, Ahlers & Cressman PLLCMr. Lynch may be contacted at
jlynch@ac-lawyers.com
California Supreme Court Declines Request to Expand Exceptions to Privette Doctrine for Known Hazards
January 17, 2022 —
Garret Murai - California Construction Law BlogFirst things first. Happy New Year! Hope you had a good one.
To start things off in the new year we’ve got an employment-related case for you – Gonzalez v. Mathis, 12 Cal.5th 29 (2021) – a California Supreme Court case involving the Privette Doctrine. For those not familiar with the Privette Doctrine, the Privette Doctrine is named after the case Privette v. Superior Court, 5 Cal.4th 689 (1993), which held that project owners and higher-tiered contractors are not liable for workplace injuries sustained by employees of lower-tiered contractors. Since then, courts have carved out a few exceptions to the Privette Doctrine including the “retained control exception” (also known as the Hooker exception – that’s the name of the case not the occupation of the injured worker) whereby a “hirer,” that is, the higher-tiered party who hired the lower-tiered party whose employee is injured, can be held liable if the hirer: (1) retains control over any part of the lower-tiered party’s work; and (2) negligently exercises that control in a manner that affirmatively contributes to the worker’s injury.
Another exception is the “concealed hazard exception” (also known as the Kinsman exception) whereby a hirer can be held liable if: (1) the hirer knew, or should have known, of a concealed hazard on the property that the lower-tiered contractor did not know of and could not have reasonably discovered; and (2) the hirer railed to warn the lower-tiered contractor of that hazard.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Nomos LLPMr. Murai may be contacted at
gmurai@nomosllp.com
Project Delivery Methods: A Bird’s-Eye View
November 01, 2021 —
Levi W. Barrett, Nathan A. Cohen & Stewart Shurtleff - ConsensusDocsFor centuries the ability to construct sophisticated structures has been the yardstick for measuring civilizations. Naturally, as our knowledge and capacity to build has evolved and developed over the ages, the methods of project delivery have similarly progressed.
From Design-Bid-Build to CM-at-Risk and Design-Build to Integrated Project Delivery, each method developed to fit a very specific need—but each carries its own set of inherent risks and rewards. In this article we explore key aspects and differences among the various delivery methods that are commonly used in today’s construction industry, and provide guidance related to the obligations and risk profiles of the parties involved. Ideally, contractors and construction managers may refer to the advice provided herein when determining whether a proposed delivery method properly fits the requirements of the project under consideration.
Reprinted courtesy of
Levi W. Barrett, Peckar & Abramson, P.C.,
Nathan A. Cohen, Peckar & Abramson, P.C. and
Stewart Shurtleff, Peckar & Abramson, P.C.
Mr. Barrett may be contacted at lbarrett@pecklaw.com
Mr. Cohen may be contacted at ncohen@pecklaw.com
Mr. Shurtleff may be contacted at sshurtleff@pecklaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Construction Litigation Roundup: “This Is Sufficient for Your Purposes …”
April 08, 2024 —
Daniel Lund III - Lexology… but just barely.
Federal courts are “notice” pleading courts. One source writes: “Notice pleading refers to pleading standards that merely notify the opposing party and court of the general issues in the case. In contrast to fact pleading standards, notice pleading standards do not require pleadings to include hyper-detailed facts in support of each claim.”
Some state courts – including Louisiana – are fact pleading courts. Ordinarily, no one practicing in Louisiana state courts would describe the fact pleading requirements for initiating a lawsuit as mandating “hyper-detailing” of the facts, but … why risk it?
In a construction mechanics lien case – the jurisprudence for which requires that courts strictly construe the related law because liens empower lien holders with rights which are “in derogation” of common property ownership rights – the defendant was successful in having the trial court dismiss a lien suit for failing to affirmatively set forth in the complaint (a “petition” in Louisiana) the date of substantial completion. The lien claimant appealed.
Read the court decisionRead the full story...Reprinted courtesy of
Daniel Lund III, PhelpsMr. Lund may be contacted at
daniel.lund@phelps.com
