CAMBRIDGE MASSACHUSETTS BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?

January 27, 2020 — Ted R. Gropman & Christine Z. Fan - ConsensusDocs
Construction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date. Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved. There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973). Reprinted courtesy of Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP Mr. Gropman may be contacted at gropmant@pepperlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Non-compliance With Endorsement Means No Indemnity Coverage

January 15, 2019 — Tred R. Eyerly - Insurance Law Hawaii
The insured's failure to verify that subcontractors had CGL policies and to provide a contract stating that the subcontractors would indemnify the insured as required by the policy's endorsement meant there was no coverage for the insured. Cincinnati Spec. Underwriters Ins. Co. v. Milionis Constr., Inc., 2018 U.S. Dist. LEXIS 199658 (E.D. Wash. Nov. 26, 2018). The homeowners filed suit against Milionis, the general contractor for construction of a home. The underlying suit alleged that Milionis breached the parties' agreement by leaving the home unfinished. Cincinnati defended Milionis under a reservation of rights. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Limitations: There is a Point of No Return

September 06, 2023 — Amy Anderson - ConsensusDocs
After nearly any event that causes inefficiency, delay, or extra cost on a project, there are some things you should always do: review the contract and document the inefficiency, delay, or cost. However, how you document the particular issue likely changes depending on what is in your contract, your position on the project, and the outcome you hope to reach. In reviewing the inefficiency, delay, or cost, one thing to always consider is how long you have to actually recoup damages you may incur if they were caused by another party on the project. In every jurisdiction (state or federal), there is likely to be some outer limit to when you can bring litigation or arbitration against an opposing party to recover damages another party causes to you. This is generally called a statute of limitations or statute of repose, although it goes by other names depending on your state. The length of time will be specific to the locality. For example, in Texas, you have four years to bring a breach of contract claim but only two years to bring a negligence claim. Whether you fall under the two year or four year period may be highly fact intensive, depending on your claims. Do you have a contract directly with the party that is at fault? Is the claim based on your contract or some tort outside of the contract? Read the court decision
Read the full story...
Reprinted courtesy of Amy Anderson, Jones Walker LLP (ConsensusDocs)
Ms. Anderson may be contacted at aanderson@joneswalker.com

---

Update Regarding McMillin Albany LLC v. Super Ct.

April 28, 2016 — Richard H. Glucksman and David A. Napper – Chapman Glucksman Dean Roeb & Barger In Focus
The construction industry continues to await the California Supreme Court's highly anticipated decision regarding McMillin Albany LLC v. Super Ct. 2015 F069370 (Cal.App.5 Dist.). The Supreme Court will attempt to resolve the conflict presented by the Fourth Appellate District Court's holding in Liberty Mut. Ins. Co. v. Brookfield Crystal Cove LLC (2013) 219 Cal.App.4th 98 and rejection of the same by the Fifth Appellate District Court in McMillin Albany. The issue is whether the Right to Repair Act (SB800) is the exclusive remedy for all defect claims arising out of new residential construction sold on or after January 1, 2013. CGDRB has been closely monitoring the progress of the case and understands that the real parties in interest have submitted their opening brief on the merits. The Court granted Petitioners a further and final extension to file the answer brief on the merits. The answer deadline is Monday April 25, 2016. Stay tuned. Reprinted courtesy of Richard H. Glucksman, Chapman Glucksman Dean Roeb & Barger and David A. Napper, Chapman Glucksman Dean Roeb & Barger Mr. Glucksman may be contacted at rglucksman@cgdrblaw.com Mr. Napper may be contacted at dnapper@cgdrblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Hundreds of Coronavirus Coverage Cases Await Determination on Consolidation

September 21, 2020 — Tred R. Eyerly - Insurance Law Hawaii
On July 30, 2020, the Judicial Panel on Multi-District Litigation (JPML) heard oral argument on the potential consolidation of all federal cases involving business interruption coverage relating to coronavirus and shut-down orders. A decision will be rendered in the near future. Meanwhile, many cases are on hold, waiting for a determination on consolidation. One such case is Pigment Inc. v. Hartford Fin. Servs. Group, 2020 U.S. Dist. LEXIS 133230 (S.D. Cal. July 27, 2020), where the court granted a stay pending a decision by the JPML. The case is a class action based on denial of coverage under business interruption insurance. Plaintiff's case alleged a bad faith denial that risked the permanent closure of its business due to unexpected temporary shutdowns from the COVID-19 pandemic. Plaintiff sought a stay pending the decision of the JPML. The court considered the possible damage which could result from granting a stay, the hardship which a party could suffer in being required to go forward, and the orderly course of justice measured by the simplifying or complicating of issues, proof, and questions of law which could be expected to result from a stay. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

U.S. Judge Says Wal-Mart Must Face Mexican-Bribe Claims

October 01, 2014 — Jef Feeley – Bloomberg
Wal-Mart Stores Inc. (WMT) was ordered by a federal judge in Arkansas to face a pension fund’s claims the retailer defrauded shareholders by concealing corruption tied to bribes allegedly paid by officials of its Mexican unit. U.S. District Judge Susan Hickey in Fayetteville rejected Wal-Mart’s bid to throw out the Michigan-based fund’s lawsuit accusing it of making misleading statements to regulators about claims it paid bribes to facilitate Mexican real-estate deals. The world’s largest retailer has said it’s spent $439 million since 2012 in connection with investigations into allegations that employees paid bribes in Mexico, China, India and Brazil. Both U.S. and Mexican prosecutors have said they are probing whether executives of Wal-Mart’s Mexican unit were paying off local officials to clear the way for construction of new stores and warehouses. Read the court decision
Read the full story...
Reprinted courtesy of Jef Feeley, Bloomberg
Mr. Feeley may be contacted at jfeeley@bloomberg.net

---

Preventing Costly Litigation Through Your Construction Contract

August 17, 2011 — Douglas Reiser, Builders Council Blog

It’s Tuesday, which means it ’s the middle of your work week. Tuesday is a great time to take an hour to look over your contracts, while the crews are pushing through their scheduled work. Today’s food for thought: How do you use your contract to reduce your litigation burden?



Your contract should do many things. It should discuss the scope of work, scheduling of work, quality of work, coverage for liabilities and conditions and timeliness for payment. But often overlooked is how your contract can lend to dispute resolution.



Commonly, you will see a simple provision that covers governing law, venue for disputes and the awarding of attorneys’ fees. But you can do better. Remember, a contract is enforced to the maximum extent possible in Washington state.

Read the full story…



Reprinted courtesy of Douglas Reiser of Reiser Legal LLC. Mr. Reiser can be contacted at info@reiserlegal.com

Read the court decision
Read the full story...
Reprinted courtesy of

---

The Prompt Payment Rollercoaster

February 23, 2016 — Garret Murai – California Construction Law Blog
This past year we wrote about a case involving California’s prompt payment laws and the current state of confusion with the prompt payment statutes which are scattered throughout the state Code and which are inconsistent in the use of their terminology and, thus importantly, application. In United Riggers & Erectors, Inc. v. Coast Iron & Steel Co., California Court of Appeals for the Second District, Case No. B258860 (December 18, 2015), the Court of Appeals for the Second District addressed whether under one of the prompt payment statutes, Civil Code section 8814, a general contractor may withhold retention without being subject to prompt payment penalties if there is a dispute of any kind between the general contractor and the subcontractor, or only when the dispute relates to the retention itself. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

---