Fairfield Connecticut Building Expert Directory

Courts Take Another Swipe at the Implied Warranty of the Plans and Specifications

December 15, 2016 — John P. Ahlers – Ahlers & Cressman PLLC
Implied warranties are warranties created by law, legislation, or courts. In the construction industry, one of the most prominent implied warranties is that owners who provide plans and specifications to their contractors impliedly warrant the adequacy of their plans and specifications.[i] That implied warranty had its beginning in the 1918 US Supreme Court decision of U.S. v. Spearin[ii] and is, therefore, popularly known as the Spearin Doctrine. Under the Spearin Doctrine, if the contractor completes the work in accordance with the owner’s plans and specifications, but there is a deficiency or failure, the owner, not the contractor, is responsible. When the owner breaches its implied warranty, in most instances, the contractor is entitled to additional compensation for extra work performed, delays experienced, and other additional expense or loss occasioned by the warranty breach. A recent case demonstrates that this implied warranty is not “immunity.” The contractor must still act reasonably and diligently, particularly when the contract provisions so require. In the recent Fifth Circuit case of Dallas/Ft. Worth International Airport v. INet Airport Systems,[iii] the court, despite the implied warranty that existed, did not grant the contractor summary judgment on claims involving admitted plan deficiencies, since factual issues existed regarding the contractor’s cooperation and participation in the solution to the defects. Read the court decision
Read the full story...
Reprinted courtesy of John P. Ahlers, Ahlers & Cressman, PLLC
Mr. Ahlers may be contacted at jahlers@ac-lawyers.com

Getting U.S to Zero Carbon Will Take a $2.5 Trillion Investment by 2030

December 29, 2020 — Will Wade & Eric Roston - Bloomberg
It’s going to take $2.5 trillion in spending over the next decade to get the U.S. on a path to a carbon-free economy, but the transition will help to pay for itself, Princeton University researchers say. Achieving net-zero emissions by 2050 -- a central goal of President-elect Joe Biden’s climate plan -- would require expanding renewable-energy systems, building more efficient homes and putting 50 million electric cars on the road, according to a report released Tuesday. The effort, two years in the making, is the first major assessment since the election detailing how the U.S. can transition to an energy system that satisfies scientific guidance for keeping the climate livable. While the upfront costs are significant, they would be offset by savings associated with switching to cheaper electricity and the creation of as many as 1 million new jobs, according to the researchers, who shared an earlier draft with Biden’s transition team. Read the court decision
Read the full story...
Reprinted courtesy of Will Wade & Eric Roston, Bloomberg

Travelers’ 3rd Circ. Win Curbs Insurers’ Asbestos Exposure

November 21, 2017 — Gregory D. Podolak - Saxe Doernberger & Vita, P.C.
Originally published by CDJ on May 3, 2017 In breaking news this week, LAW360.com posted that the Third Circuit ruled Friday that “a common exclusion found in a Travelers policy bars coverage for claims arising out of asbestos in any form, limiting insurers’ potential exposure to asbestos injury claims by precluding policyholders from arguing that the exclusionary language is ambiguous and doesn’t extend to products containing the carcinogen.” In its detailed analysis of the decision, LAW360 turned to Greg Podolak for his analysis. Gregory D. Podolak, managing partner of Saxe Doernberger & Vita PC’s Southeast office, said the ruling is a cautionary tale that should galvanize policyholders and their insurance brokers to take a closer look at policies to delete or curtail broad “arising out of” language in exclusions. Otherwise, insureds could find themselves without any coverage for claims even remotely related to a certain product, he said. Read the court decision
Read the full story...
Reprinted courtesy of Gregory D. Podolak, Saxe Doernberger & Vita, P.C.
Mr. Podolak may be contacted at gdp@sdvlaw.com

Reference to "Man Made" Movement of Earth Corrects Ambiguity

December 20, 2012 — TRED EYERLY, INSURANCE LAW HAWAII
In Pioneer Tower Owners Assn. v. State Farm Fire & Cas. Co., 12 NY3d 302 (2009), the New York Court of Appeals found an "earth movement" exclusion was ambiguous when applied to an excavation. The court now considered whether a similar exclusion, expressly made applicable to "man made" movement of earth, eliminated the ambiguity when loss was created by excavation. Bentoria Holdings, Inc. v. Travelers Indem. Co., 2012 N.Y. LEXIS 3087 (N.Y. Oct. 25, 2012). Plaintiff's building suffered cracks due to an excavation being conducted on the lot next door. A claim was submitted to Travelers, plaintiff's insurer. Travelers rejected the claim, relying on the earth movement exclusion. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii.
Mr. Eyerly can be contacted at te@hawaiilawyer.com

Filling Out the Contractor’s Final Payment Affidavit

February 03, 2020 — David Adelstein - Florida Construction Legal Updates
When preparing a contractor’s final payment affidavit, I always suggest for a contractor (or anyone in privity of contract with the owner) to identify the undisputed amounts their accounting reflects is owed to ALL subcontractors, etc., regardless of whether that entity preserved their lien rights. If the contractor provided a payment bond, I footnote this simply to support that none of the lower-tiered subcontractors have lien rights or are the traditional “lienor.” (Thus, there is no prejudice to the owner if an entity is inadvertently omitted from the affidavit.) There are times, however, where a contractor does not identify a subcontractor that did not serve a notice to owner and, therefore, has no valid lien rights. Or, a contractor omits a lienor that actually did serve a notice to owner and preserve its lien rights; this happens. There was an older First District Court of Appeals case that harshly (and, quite, unfairly) held that the contractor must identify everyone in the final payment affidavit regardless of whether that entity timely served a notice to owner or their lien is invalid. This case, however, predated, a 1998 statutory change to Florida’s Lien Law. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Governor Inslee’s Recent Vaccination Mandate Applies to Many Construction Contractors and their Workers

September 13, 2021 — Brett M. Hill - Ahlers Cressman & Sleight PLLC
This month Governor Jay Inslee enacted COVID vaccination requirements that apply to certain construction contractors and their workers in Washington state. Inslee’s vaccine proclamation becomes effective October 18, 2021 and requires construction contractors, subcontractors, and their workers to be fully vaccinated to perform work onsite on certain covered projects. The following are types of covered projects where the vaccine mandate applies:

State agencies: All contractors working at projects for Washington state agencies (including WSDOT, DES, DNR, etc.) if the work is required to be performed in person and onsite, regardless of the frequency or whether other workers are present. The vaccine mandate applies to indoor and outdoor settings and there is no exemption even if social distancing requirements can be met.
Education/Higher Education/Child Care: All contractors performing work onsite for K-12, higher education (community colleges, technical colleges, and 4-year universities), child care and other facilities where students or persons receiving services are present. New and unoccupied projects are exempt but it does apply to public and private projects.
Medical facilities: All contractors performing work at a “healthcare setting” where patients receiving care are present. “Healthcare setting” is defined as any public or private setting that is primarily used for the delivery of in-person health care services to people. “Healthcare setting” includes portions of a multi-use facility, but only the areas that are primarily used for the delivery of health care, such as a pharmacy within a grocery store. Additional information is on the state’s Q&A page.

Read the court decision
Read the full story...
Reprinted courtesy of Brett M. Hill, Ahlers Cressman & Sleight PLLC
Mr. Hill may be contacted at brett.hill@acslawyers.com

Equal Access to Justice Act Fee Request Rejected in Flood Case

January 06, 2020 — Tred R. Eyerly - Insurance Law Hawaii
The insured's claim for fees under the Equal Access to Justice Act (EAJA) for seeking coverage under a flood policy was rejected. Hampson v. Wright Nat'l Flood Ins. Co., No. 4:19-cv-10083-KMM (S.D. Fla. Aug. 11, 2019)(Order on Motion to Dismiss). The order is here. The insurer did not compensate plaintiff for flood-related damages under the terms of a Standard Flood Insurance Policy (SFIP). The insurer was a Write-Your-Own (WYO) Program insurance carrier participating in the National Flood Insurance Program (NFIP). By statute, a WYO carrier acts as a "fiscal agent" and "fiduciary" of the United States. The insured's property suffered damage from a hurricane. The insured sued the carrier for breach of contract and attorney's fees under EAJA. The insurer moved to dismiss the claim for fees under EAJA. A party could recover fees and costs under the EAJA as the prevailing party in a case "brought by or against the United States . . . unless the court finds the position of the United States was substantially justified." 28 U.S.C. 2412 (d) (1) (A), (b). The statute defined the "United States" to include "any agency and any official of the United States acting in his or her official capacity." However, attorney's fees were not recoverable under the EAJA in cases for breach of an SFIP brought against a WYO program insurance carrier participating in the NFIP because WYO carriers were not considered "agencies" under the EAJA. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Colorado “occurrence”

January 06, 2012 — CDCoverage.com

In Greystone Construction, Inc. v. National Fire & Marine Insurance Co., No. 09-1412 (10th Cir. November 1, 2011), general contractors Greystone and Branan were each sued by purchases of homes built by each alleging defective construction performed by subcontractors. CGL insurer American Family Mutual Insurance Company defended both Greystone and Brannon while co-insurer National Fire & Marine Insurance Company denied a defense. Greystone, Branan, and American Family sued National Fire for contribution towards defense costs. The federal district trial court entered summary judgment for National Fire.

Read the full story…

Reprinted courtesy of CDCoverage.com

Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES