SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Point Taken: The UK Supreme Court Finally Confirms the General Law of Liquidated Damages (LDs)

April 04, 2022 — Vincent C. Zabielski & Julia Kalinina Belcher - Gravel2Gavel Construction & Real Estate Law Blog
In a long-awaited decision which overturned the Court of Appeal’s ruling in the Triple Point Technology vs PTT Public Company case, the UK Supreme Court confirmed the general law of LDs, which is that—absent clear words to the contrary—they accrue up to the date of termination of a contract regardless of whether the contractor completes the work; after that, general damages are recoverable. This approach was held to reflect “commercial reality and the accepted function of liquidated damages.” Although the contract in question was not a construction contract, the decision is equally relevant in the construction sphere. By way of reminder, Triple Point failed to complete the works under Phase 1 of a contract for the design, installation, maintenance and licencing of software. Despite agreeing a revised project plan, PTT gave notice to terminate. Reprinted courtesy of Vincent C. Zabielski, Pillsbury and Julia Kalinina Belcher, Pillsbury Mr. Zabielski may be contacted at vincent.zabielski@pillsburylaw.com Ms. Belcher may be contacted at julia.belcher@pillsburylaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Potential Extension of the Statutes of Limitation and Repose for Colorado Construction Defect Claims

April 27, 2020 — David M. McLain – Colorado Construction Litigation
On January 27th, Senator Robert Rodriguez introduced SB 20-138 into the Colorado Legislature. The bill has been assigned to the Senate Judiciary Committee and has not yet been scheduled for its first hearing in that committee. In short, Senate Bill 20-138, if enacted, would:

1. Extend Colorado’s statute of repose for construction defects from 6+2 years to 10+2 years;
2. Require tolling of the statute of repose until the claimant discovers not only the physical manifestation of a construction defect, but also its cause; and
3. Permit statutory and equitable tolling of the statute of repose.

Colorado’s statute of repose for construction defect claims are codified at C.R.S. § 13-80-104. In 1986, the Colorado Legislature set the statute of repose period at 6+2 years. For the last 34 years, Colorado’s statute of repose for owners’ claims against construction professionals has been substantially the same, to wit:

(1) (a) Notwithstanding any statutory provision to the contrary, all actions against any architect, contractor, builder or builder vendor, engineer, or inspector performing or furnishing the design, planning, supervision, inspection, construction, or observation of construction of any improvement to real property shall be brought within the time provided in section 13-80-102 after the claim for relief arises, and not thereafter, but in no case shall such an action be brought more than six years after the substantial completion of the improvement to the real property, except as provided in subsection (2) of this section.

(2) In case any such cause of action arises during the fifth or sixth year after substantial completion of the improvement to real property, said action shall be brought within two years after the date upon which said cause of action arises.

Read the court decision
Read the full story...
Reprinted courtesy of David McLain, Higgins, Hopkins, McLain & Roswell
Mr. McLain may be contacted at mclain@hhmrlaw.com

---

Ensuing Loss Provision Does Not Salvage Coverage

December 09, 2011 — Tred R. Eyerly - Insurance Law Hawaii

Water intrusion caused by a construction defect was not covered under the all risk policy’s ensuing loss provision. See Friedberg v. Chubb & Son, Inc., 2011 U.S. Dist. LEXIS 123582 (D. Minn. Oct. 25, 2011).

Extensive water damage was discovered in the insureds’ home when a small hole in the exterior wall was being repaired. Chubb’s adjuster and an expert found water intrusion causing rot, mold, and damage to the home’s wood framing and insulation. Chubb denied coverage because water intruded through the roof and wall, resulting in gradual deterioration. The insureds filed suit.

The policy excluded coverage for construction defects, but insured "ensuing covered loss unless another exclusion applies."

The court agreed there was a prima facie case for coverage because the home suffered a physical loss.

Read the full story…

Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

Read the court decision
Read the full story...
Reprinted courtesy of

---

HHMR Celebrates 20 Years of Service!

October 18, 2021 — David M. McLain – Colorado Construction Litigation
I remember it (almost) like it was yesterday. It was September of 2001, and I was a third-year associate at Long & Jaudon, practicing with the construction litigation group. After a long weekend away, I received word that the firm had just announced that it would cease providing legal services. Long & Jaudon, which formed in 1967, had been a stalwart of Colorado’s defense bar, counting among its number some of the finest and most well-respected defense attorneys in the state. To learn that the firm would be shutting its doors was devastating. I would be out of a job. Soon after L&J’s announcement, Dave Higgins, one of that firm’s senior partners, inquired as to whether I would be interested in starting a new firm focused on supporting Colorado’s construction industry and its insurers. Instead of riding into the sunset of retirement, Dave wanted to leave a legacy. That legacy is Higgins, Hopkins, McLain & Roswell. Shortly after the sprout of the idea, I spent an afternoon at a picnic table in Cheesman Park with Dave Higgins, Steve Hopkins, and Sheri Roswell, sketching out an idea for a new law firm. Twenty years later, HHMR is still here, still serving Colorado’s construction industry and its insurers, and still embodying the principles of service and stewardship upon which the firm was founded. Read the court decision
Read the full story...
Reprinted courtesy of David McLain, Higgins, Hopkins, McLain & Roswell
Mr. McLain may be contacted at mclain@hhmrlaw.com

---

You Don’t Have To Be a Consumer to Assert a FDUTPA Claim

February 22, 2018 — David Adelstein – Florida Construction Legal Updates
A few years ago, the Fourth District Court of Florida rendered an opinion in Caribbean Cruise Line, Inc. v. Better Business Bureau of Palm Beach County, Inc., 169 So.3d 164 (Fla. 4th DCA 2015) regarding Florida’s Deceptive and Unfair Trade Practices Act (referred as to “FDUTPA”) (Florida Statute s. 501.201et seq.). This case held that a party can assert a FDUTPA claim even though the party is NOT a consumer. The party still has to prove there was an injury to consumers in filing such claim, but again, the party can bring the claim even though it is NOT a consumer. Caribbean Cruise Line, 169 So.3d at 169 (“[W]hile the claimant would have to prove that there was an injury or detriment to consumers in order to satisfy all of the elements of a FDUTPA claim, the claimant does not have to be a consumer to bring the claim.”).See also Cemex Construction Materials Florida, LLC v. Armstrong World Industries, Inc., 2018 WL 905752, *15 (M.D.Fla 2018) (relying on Caribbean Cruise Line to find that even though the plaintiff does not need to be a consumer, the plaintiff still must prove an injury to consumers to satisfy elements of a FDUTPA claim). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dadelstein@gmail.com

---

Justin Bieber’s Unpaid Construction Bill Stalls House Sale

March 26, 2014 — Beverley BevenFlorez-CDJ STAFF
The Toronto Sun reported that Justin Bieber’s Calabasas, California house sale to Khloe Kardashian has been stalled due to a an unpaid construction bill. Bieber sold the home for $7.2 million, but allegedly owes $85,000 to a construction company for home repairs. Bieber moved out of his mansion in Calabasas “to Atlanta, Georgia after numerous encounters with the police regarding alleged loud parties, speeding in the gated community and 'egging' a [neighbor’s] house,” according to the Toronto Sun. Bieber has a week to pay the lien, or the house sale does not go through. Read the court decision
Read the full story...
Reprinted courtesy of

---

Aecmaster’s Digital Twin: A New Era for Building Design

May 06, 2024 — Aarni Heiskanen - AEC Business
I sat down with Anssi Auvinen, the CEO and founder of Finnish startup Aecmaster, to discuss the future of design and how the company plans to make it happen. Anssi envisions data-driven design as the next radical change in the AEC sector. Anssi Auvinen started working in the building industry as a 16-year-old construction worker. Since then, he has acquired two master’s degrees: structural engineering and architecture. During his career, Anssi has witnessed how the digitalization of the design sector has progressed, but the results for both designers and building owners could have been more impressive. That inspired him in 2019 to start up Aecmaster, a software and consulting firm that aims to fulfill the promise of digitalization. The company’s software product launched in January 2024. The need for digital twins Anssi states that you can’t say you own a building until you possess its digital assets, the digital twin. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

---

Ohio Rejects the Majority Trend and Finds No Liability Coverage for a Subcontractor’s Faulty Work

December 11, 2018 — Shannon M. Warren - The Subrogation Strategist
In Ohio N. Univ. v. Charles Constr. Servs., 2018 Ohio LEXIS 2375 (No. 2017-0514, October 9, 2018), the Supreme Court of Ohio was recently called upon to determine if a general contractor’s Commercial General Liability (CGL) insurance policy provided coverage for defective work completed by its subcontractor. Rejecting the majority trend, the court held that, because the subcontractor’s faulty work was not an “occurrence” caused by an accident – i.e. a fortuitous event – within the meaning of the contractor’s CGL policy, the insurer did not have to defend or indemnify the contractor with respect to the plaintiff’s claims. Read the court decision
Read the full story...
Reprinted courtesy of Shannon M. Warren, White and Williams LLP
Ms. Warren may be contacted at warrens@whiteandwilliams.com

---