New Illinois Supreme Court Trigger Rule for CGL Personal Injury “Offenses” Could Have Costly Consequences for Policyholders
March 09, 2020 —
Michael S. Levine & Kevin V. Small - Hunton Insurance Recovery BlogThe Illinois Supreme Court’s recent decision in Sanders v. Illinois Union Insurance Co., 2019 IL 124565 (2019), announced the standard for triggering general liability coverage for malicious prosecution claims under Illinois law. In its decision, the court construed what appears to be a policy ambiguity against the policyholder in spite of the longstanding rule of contra proferentem, limiting coverage to policies in place at the time of the wrongful prosecution, and not the policies in effect when the final element of the tort of malicious prosecution occurred (i.e. the exoneration of the plaintiff). The net result of the court’s ruling for policyholders susceptible to such claims is that coverage for jury verdicts for malicious prosecution – awarded in today’s dollars – is limited to the coverage procured at the time of the wrongful prosecution, which may (as in this case) be decades old. Such a scenario can have costly consequences for policyholders given that the limits procured decades ago are often inadequate due to the ever-increasing awards by juries as well as inflation. Moreover, it may be difficult to locate the legacy policies and the insurers that issued such policies may no longer be solvent or even exist. A copy of the decision can be found
here.
The Sanders case arose out of the wrongful conviction of Rodell Sanders in 1994 by the City of Chicago Heights (the “City”). Mr. Sanders sought recompense for, among other things, malicious prosecution through a federal civil rights action against the City. In September 2016, Mr. Sanders obtained a consent judgment for $15 Million; however, at the time of the wrongful conviction, seventeen years earlier, the City’s only applicable insurance policy provided just $3 million in coverage. The City contributed another $2 million towards the judgment and, in exchange for Mr. Sanders’s agreement not to seek the $10 million balance from the City, assigned its rights under the policies for the 2012 to 2014 period.
Reprinted courtesy of
Michael S. Levine, Hunton Andrews Kurth and
Kevin V. Small, Hunton Andrews Kurth
Mr. Levine may be contacted at mlevine@HuntonAK.com
Mr. Small may be contacted at ksmall@HuntonAK.com
Read the court decisionRead the full story...Reprinted courtesy of
Idaho Federal Court Rules Against Sacketts After SCOTUS Decided Judicial Review of an EPA Compliance Order was Permissible
May 13, 2019 —
Anthony B. Cavender - Gravel2GavelIn a decision released on March 31, in Sackett v. EPA, the U.S. District Court for Idaho held, without benefit of oral argument, that the Environmental Protection Agency’s (EPA) motion for summary judgment should be granted, and accordingly, the Sacketts had violated the Clean Water Act (CWA) by making improvements to 0.63 acres of land they owned without a required CWA permit when the land qualified as a “wetlands.”
The EPA had determined the Sacketts’ “property is subject to the CWA because it contains wetlands adjacent to Priest Lake, a traditionally ‘navigable water,’ and, additionally, their property is wetland adjacent to a tributary and similarly situated to other wetlands and has a significant nexus to Priest Lake.” The District Court rejected the Sacketts’ arguments that their property was not a “wetlands” subject to the CWA.
Read the court decisionRead the full story...Reprinted courtesy of
Anthony B. Cavender, PillsburyMr. Cavender may be contacted at
anthony.cavender@pillsburylaw.com
Contractor Manslaughter? Safety Shortcuts Are Not Worth It
August 11, 2011 —
Douglas Reiser, Builders Council BlogIt’s been a while since I discussed the importance of safety. But, a recent article on ENR.com compelled this brief article. Don’t shortcut safety — you could be facing serious criminal repercussions.
A New York crane company owner and one of his employees are each facing a second-degree manslaughter charge for the death of two construction workers.  The charges stem from the collapse of a crane in New York City. The district attorney determined that the crane owner cut a few corners to reduce its operation costs, significantly sacrificing safety.
Another example was the 2010 trial of another New York crane operator who was charged with manslaughter. In that case, the criminal charges failed to stick, but an administrative judge found that the contractor used a damaged sling to support the steel collar binding the tower-crane mast to the 18th floor of a high-rise building being constructed. The company also used four slings instead of the eight, as specified by the crane manufacturer; improperly attached the slings and failed to pad or soften them.
Read the full story…
Reprinted courtesy of Douglas Reiser of Reiser Legal LLC. Mr. Reiser can be contacted at info@reiserlegal.com
Read the court decisionRead the full story...Reprinted courtesy of
Colorado Defective Construction is Not Considered "Property Damage"
September 12, 2022 —
Saxe Doernberger & Vita, P.C.In the July 5, 2022, case of Indian Harbor Ins. Co. v. Houston Casualty Co., the United States District Court for Colorado addressed the issue of whether damage to defectively installed balconies is considered “property damage” under Colorado law, requiring payment by a commercial general liability policy.
Facts of the Case
The case stems from a construction project where a subcontractor improperly installed balconies on an apartment complex. The owner of the project secured commercial general liability (CGL) coverage through an OCIP insured by Houston Casualty Company (HHC). The OCIP insured the general contractor and subcontractors. The general contractor also purchased a subcontractor default insurance policy insured by Indian Harbor.
All parties agreed that the subcontractor improperly installed portions of various balconies, including flashing, water-proof sealing, and water-resistant barriers, among other defects with the installation process. The parties also agreed that other portions of the balconies were properly installed. However, in order to repair the defects in the installations, every bit of each balcony had to be torn off and re-constructed.
Read the court decisionRead the full story...Reprinted courtesy of
Saxe Doernberger & Vita, P.C.
Carillion Fallout Affects Major Hospital Project in Liverpool
October 30, 2018 —
Peter Reina - Engineering News-RecordManagers of a 90%-complete, 646-bed hospital in Liverpool will take charge of the project after unravelling a public-private partnership with the contractor Carillion Plc, which collapsed ignominiously in January (ENR 1/22 p. 12). Following cancellation of the contractor’s other large U.K. hospital P3, near Birmingham, project lenders face large losses.
Read the court decisionRead the full story...Reprinted courtesy of
Peter Reina, ENRMr. Reina may be contacted at
reina@btinternet.com
Contractor’s Burden When It Comes to Delay
October 26, 2020 —
David Adelstein - Florida Construction Legal UpdatesWhen a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:
When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.
Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted).
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Small Airport to Grow with Tower
October 25, 2013 —
CDJ STAFFThe city Hammond, Louisiana is finding that their airport just keeps getting busier. Mayson Foster, the mayor of Hammond noted that the city now has “various types of aircraft ranging from blimps, regional jets, smaller private planes, helicopters and other aircraft using the airport.” Spartan Construction Company has made a successful $1.6 million bid to build the tower.
Funding will come from the sale of 17 acres of land near the airport. Air traffic at the Northshore Regional Airport is expected to increase after the tower becomes operational.
Read the court decisionRead the full story...Reprinted courtesy of
Supreme Court Finds Insurance Coverage for Intentional (and Despicable) Act of Contractor’s Employee
July 21, 2018 —
Garret Murai - California Construction Law BlogNot to cast shade on your fun in the sun, but here’s an unusual, albeit sad and creepy, one for you. I’m bummed even writing about this one.
In Liberty Surplus Insurance Corporation v. Ledesma & Meyer Construction Company, Inc., Case No. S236765 (June 4, 2018), the California Supreme Court addressed whether a general contractor’s commercial general liability carrier was obligated to defend and whether the carrier was liable for damages sustained by a young girl who was molested by an employee of the general contractor during construction at a school. At issue was whether the policy’s definition of an “occurrence,” which was defined, like most policies, as “an accident,” was triggered by the “intentional” and clearly not accidental act of the general contractor’s employee.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Wendel, Rosen, Black & Dean LLPMr. Murai may be contacted at
gmurai@wendel.com