Colorado Court of Appeals to Rule on Arbitrability of an HOA's Construction Defect Claims
November 20, 2013 —
W. Berkeley Mann, Jr. — Higgins, Hopkins, McLain & Roswell, LLCOn October 24, 2013 the Colorado Court of Appeals granted a rare interlocutory appeal in a multi-family residential construction defect case. The Court of Appeals accepted the case ofTriple Crown at Observatory Village Association, Inc. v. Village Homes of Colorado, Inc.(2013 WL 5761028) as an interlocutory appeal after the parties briefed and obtained rulings from the trial court that compelled the case to binding arbitration in lieu of a jury trial on all issues. The appellate decision of October 24, 2013 did not decide the merits of the case, but discussed the issues to be decided in the eventual merits decision. The significance of the issues presented and the interlocutory nature of this appeal both make this case worth watching for further appellate proceedings.
The core issue in this appeal was the applicability of Colorado’s Uniform Arbitration Act (C.R.S. § 13-22-201, et seq.), based on recorded Declarations filed by the developer. The Declarations mandated that the HOA arbitrate any design/construction disputes with the developer. Immediately prior to suit, the Association sought to amend the Declarations in order to avoid the arbitration process for these claims. The interlocutory appellate issues resulted from the trial court’s order compelling the arbitration over the objections of the Association.
The trial court’s decision was based on a reading of the Colorado Revised Non-Profit Corporation Act (“CRNPC,” at C.R.S. § 7-127-107), which was found applicable to the Association.
Read the court decisionRead the full story...Reprinted courtesy of
W. Berkeley Mann, Jr.W. Berkeley Mann, Jr. can be contacted at
mann@hhmrlaw.com
Pacing in Construction Scheduling Disputes
September 14, 2017 —
Luke Mecklenburg - Snell & Wilmer Real Estate Litigation BlogOn a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway.
However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48.
Read the court decisionRead the full story...Reprinted courtesy of
Luke Mecklenburg, Snell & WilmerMr. Mecklenburg may be contacted at
lmecklenburg@swlaw.com
Thinking About a Daubert Motion to Challenge an Expert Opinion?
February 06, 2023 —
David Adelstein - Florida Construction Legal UpdatesWhen you receive an expert opinion, one of the first things you are considering is whether it is worth filing a Daubert motion / challenge. A Daubert motion is a generally a pretrial motion you are using to challenge the admissibility of the expert opinion. Keep in mind this deals with the admissibility, not the credibility, of the expert opinion. A Daubert motion is based on three prongs that must be answered: 1) is the witness qualified to render the expert opinion?; 2) is the expert’s opinion reliable?; and 3) is the expert’s opinion relevant?.
A Daubert motion is premised after Federal Rule of Evidence 702 that provides:
A witness who is qualified as an expert by knowledge, skill, experience, training, or education may testify in the form of an opinion or otherwise if:
- the expert’s scientific, technical, or other specialized knowledge will help the trier of fact to understand the evidence or to determine a fact in issue;
- the testimony is based on sufficient facts or data;
- the testimony is the product of reliable principles and methods; and
- the expert has reliably applied the principles and methods to the facts of the case.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Avoid Delay or Get Ready to Pay: The Risks of “Time-Is-of-The-Essence” Clauses
August 29, 2018 —
Stephen Orlando - Gordon & Rees Construction Law BlogLike death and taxes, construction delays are inevitable. Even the most cautious, diligent contractor may face subcontractor disputes, supply shortages, or inclement weather which slows down a project. Even if the contractor avoids unexpected problems, the sheer complexity of a job may cause a contractor to exceed the deadlines proposed in a contract.
Fortunately, courts recognize the practical reality of construction projects and the unavoidable delays which may arise. Therefore, as a general rule, a contractor is only liable for delayed completion of a project if the delay resulted from the contractor’s unreasonable performance of his or her work. Reasonable performance will typically serve as a defense to a claim of delayed completion. This defense is a vital asset when a contractor surpasses the project’s expected timeframe.
Read the court decisionRead the full story...Reprinted courtesy of
Stephen Orlando, Gordon & Rees Scully Mansukhani
Last Parcel of Rancho del Oro Masterplan Purchased by Cornerstone Communties
August 06, 2014 —
Beverley BevenFlorez-CDJ STAFFAccording to San Diego Source, “A partnership controlled by Ure Kretowicz's Cornerstone Communities has paid a reported $25 million for a 28-acre residential parcel located on the northwest corner of College Avenue and Old Grove Road in the Rancho del Oro masterplan in Oceanside,” California.
Cornerstone plans to create a “338-unit luxury apartment development,” with amenities including “resort-level clubhouse with an Olympic size swimming pool, spa, barbecue area, conferencing center” and more.
Read the court decisionRead the full story...Reprinted courtesy of
Hunton Andrews Kurth’s Insurance Recovery Practice, Partners Larry Bracken and Mike Levine Receive Band 1 Honors from Chambers USA in Georgia
June 14, 2021 —
Walter J. Andrews - Hunton Insurance Recovery BlogThe 2021 Chambers and Partners rankings for Georgia insurance recovery practices and lawyers are out and Hunton Andrews Kurth has received top honors. The rankings include Hunton Andrews Kurth’s Insurance Recovery practice and partners Lawrence J. Bracken II and Michael S. Levine, with all receiving Band 1 honors – the organization’s top-tier ranking. “The top-level ranking of our practice in Georgia, and the work that Larry and Mike bring to our clients in Georgia, specifically, is emblematic of the work our team is doing nationwide,” said Insurance Recovery Practice Head, Walter J. Andrews. “The Firm and I could not be more proud,” he added.
Chambers and Partners is an independent research company operating across more than 200 jurisdictions delivering detailed rankings and insight into the world’s leading lawyers. Its rankings are viewed as one of the most credible and reliable industry benchmarks.
Read the court decisionRead the full story...Reprinted courtesy of
Walter J. Andrews, Hunton Andrews KurthMr. Andrews may be contacted at
wandrews@HuntonAK.com
Real Estate & Construction News Roundup (3/20/24) – Construction Backlog Falls, National Association of Realtors Settle Litigation, and Commercial Real Estate Market’s Effect on City Cuts
April 15, 2024 —
Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law BlogIn our latest roundup, bad loans outweigh loss reserves at top six U.S. banks, the FCC announces a proposed rule aimed at “bulk billing,” office-to-multifamily conversion projects grow in major metro cities, and more!
- The National Association of Realtors has agreed to settle litigation that accused them of artificially inflating real estate commissions – a major decision that could reshape the housing market for buyers, sellers and agents. (Rachel Siegel, The Washington Post)
- An NYU professor considers the positives and negatives of cities cutting services or raising other kinds of taxes to offset the continued faltering of the commercial real estate market. (Alan Rappeport, The New York Times)
- Construction backlog fell in February for every size of contractor except for those with under $30 million in annual revenue, while, over the past year, the largest contractors – those with greater than $50 million in revenue – have experienced the greatest decline in backlog. (Sebastian Obando, Construction Dive).
Read the court decisionRead the full story...Reprinted courtesy of
Pillsbury's Construction & Real Estate Law Team
Dust Obscures Eleventh Circuit’s Ruling on “Direct Physical Loss”
October 12, 2020 —
Walter J. Andrews, Michael S. Levine & Daniel Hentschel - Hunton Insurance Recovery BlogOn August 18, 2020, the United States Court of Appeals for the Eleventh Circuit affirmed a District Court’s 2018 ruling that Sparta Insurance Company need not cover a south Florida restaurant’s lost income and extra expenses resulting from nearby road construction. But, in doing so, the appeals court appears to deviate from even its own understanding of “direct physical loss” under controlling Florida law.
In the underlying coverage action, the insured, Mama Jo’s Inc. operating as Berries in the Grove, sought coverage under its “all risk” commercial property insurance policy for business income loss and incurred extra expenses caused by construction dust and debris that migrated into the restaurant.
Reprinted courtesy of
Walter J. Andrews, Hunton Andrews Kurth,
Michael S. Levine, Hunton Andrews Kurth and
Daniel Hentschel, Hunton Andrews Kurth
Mr. Andrews may be contacted at wandrews@HuntonAK.com
Mr. Levine may be contacted at mlevine@HuntonAK.com
Mr. Hentschel may be contacted at dhentschel@HuntonAK.com
Read the court decisionRead the full story...Reprinted courtesy of