Presenting a “Total Time” Delay Claim Is Not Sufficient
September 12, 2022 —
David Adelstein - Florida Construction Legal UpdatesWhen presenting a delay-type of claim on a construction project, a claimant MUST be in a position to properly PROVE the claim. Trying to present a delay claim loosey-goosey is not a recipe for success. In fact, it can be a recipe for an easy loss. This is not what you want. To combat this, make sure you engage a delay expert that understands delay methodologies and how to calculate delay and do NOT present a total time claim. Presenting a delay claim using a total time approach, discussed below, makes it too easy to attack the flaws and credibility of the approach. Per the discussion of the case below, a total time claim with a contractor that used its project manager, versus a delay expert, to support its claim turned the contractor’s claim into a loss.
In French Construction, LLC v. Department of Veteran Affairs, 2022 WL 3134507, CBCA 6490 (CBCA 2022), a contractor submitted a delay claim to the government for almost $400,000. The contractor was hired to construct a two-story corridor to connect hospital buildings. The contractor was required to be complete within 365 days. It was not. The contractor was seeking 419 days of delay from the government. The contractor’s “delay expert” was its project manager who compared the contractor’s as-planned schedule to an as-built schedule he prepared for the claim.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Beyond the Disneyland Resort: Museums
May 03, 2018 —
Beverley BevenFlorez-CDJ STAFFNorth Orange County has a variety of interesting museums from intimate to extravagant to peruse.
Bowers Museum, located in Santa Ana, has several special exhibitions on display around WCC Seminar: Endurance: The Antarctic Legacy Of Sir Ernest Shackleton And Frank Hurley, American Visionary: John F. Kennedy’s Life And Times, Gemstone Carvings: The Masterworks Of Harold Van Pelt, And First Americans: Tribal Art From North America.
Muzeo, a Museum and Cultural Center located in Anaheim, will be showcasing the Trash Artist Challenge Expo & Exhibition from May 12th -27th, and also has on permanent display Anaheim: A Walk through Local History.
Star Wars and Disney fans will want to make their way to the
Hilbert Museum of California Art. In the city of Orange, this museum is located at Chapman University. Two of their many exhibitions include Magical Visions: The Enchanted Worlds Of Eyvind Earle (Disney’s Sleeping Beauty designer) and A New Hope: The Star Wars Art of Robert Bailey.
Learn about American history at the
Richard Nixon Library, located in nearby Yorba Linda.
Read the court decisionRead the full story...Reprinted courtesy of
Drone Use On Construction Projects
June 05, 2023 —
Brent N. Mackay - ConsensusDocsThe use of drones, or small unmanned aircraft systems (“UAS”), has become common throughout the construction industry in all phases of construction, including pre-construction, progress of the work, project closeout, and maintenance. This article examines the federal regulations related to drone use, as well as considerations for construction professionals related to state and local laws, project location, and weather issues.
Federal Regulations
Regardless of the state in which the project is located, companies and persons operating commercial drones must observe regulations promulgated by the Federal Aviation Administration (“FAA”), which has the exclusive authority to regulate aviation safety, airspace navigation, and air traffic control.
Reprinted courtesy of
Brent N. Mackay, Watt, Tieder, Hoffar, & Fitzgerald, LLP (ConsensusDocs)
Mr. Mackay may be contacted at bmackay@watttieder.com
Read the court decisionRead the full story...Reprinted courtesy of
North Dakota Supreme Court Clarifies Breadth of Contractual Liability Coverage
October 30, 2018 —
Michael S. Levine & Latosha M. Ellis - Hunton Insurance Recovery BlogNorth Dakota’s highest court delivered a blow to Mid-Continent Casualty Company in Borsheim Builders Supply, Inc. v. Manger Insurance Co., ruling that a contract between a policyholder and general contractor fit the insured contract exception of contractual liability.
Commercial General Liability (“CGL”) policies generally exclude an insured’s contractual assumption of another party’s liability. The exclusion typically contains an exception for what is known as an “insured contract.” However, many policyholders and insurance claims personnel often miss the significance of the insured contract exception. This was the case in Borsheim.
Read the court decisionRead the full story...Reprinted courtesy of
Michael S. Levine, Hunton Andrews KurthMr. Levine may be contacted at
mlevine@HuntonAK.com
Insurer’s Consent Not Needed for Settlement
October 14, 2013 —
CDJ STAFFThe Texas Supreme Court has concluded in Lennar Corp. v. Markel Am. Ins. Co. that “the costs incurred by a builder to locate and repair damage caused by the builder’s defective product are covered under its general liability insurance policy.” Hunton & Williams have issued a Client Alert discussing the case.
For the background of the case, Lennar built about 800 homes using EIFS. The EIFS trapped water and the homes suffered from rot, structural damage, mold, mildew, and termites. Lennar fixed all the homes so built, avoiding litigation. Lennar “notifed its insurers of the defects and invited its insurers to participate in the proactive remediation program.”
A lower court had agreed with Markel, one of Lennar’s insurers, that the losses were not “caused by property damage,” and that Lennar should not have made “voluntary payments without Markel’s consent.” The Texas Supreme Court granted review, rejecting Markel’s argument and affirming the jury’s finding.
According to Hunton & Williams, the implications of the Texas Lennar decision is that it “confirms that all insurers with policy in effect at the time of property damage are responsible for all sums for which the policyholder is liable.”
Read the court decisionRead the full story...Reprinted courtesy of
Exclusion for Construction of Condominiums Includes Faulty Construction of Retaining Wall
August 04, 2021 —
Tred R. Eyerly - Insurance Law HawaiiThe exclusion for suits arising out of construction of condominiums encompassed the underlying claim for faulty construction of a retaining wall. HT Serv., LLC v. Western Heritage Ins. Co., 2021 U.S. App. LEXIS 16259 (10th Cir. June 1, 2021).
HT Services was a land developer. HT Services designed and constructed a residential community. The AOAO sued HT Services for negligent design and construction of a retaining wall. When its carrier, Western Heritage Insurance Company, denied coverage, HT Services sued. The district court granted summary judgment to Western.
The exclusion eliminated coverage for claims or suits "arising out of, relating to or in any way connected with 'your operations' . . . involving the development [or] construction . . . of . . . condominiums . . . or . . . residential structures." HT Services argued that a retaining wall was not a "residential structure."
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Newmeyer Dillion Secures Victory For Crown Castle In Years-Long Litigation With City Council Of Piedmont Over Small Cell Wireless Telecommunications Sites
December 30, 2019 —
Newmeyer DillionNewmeyer Dillion, a prominent business and real estate law firm, is pleased to announce that, on November 18, 2019, the City Council of the City of Piedmont unanimously voted to approve the installation of 17 small cell wireless telecommunications sites by Newmeyer Dillion client Crown Castle NG West LLC, the leading provider of shared communications infrastructure in the United States. This victory ends a long-running legal dispute over Crown Castle's small cell wireless network, which was vehemently opposed by Piedmont residents and previously rejected by the City Council, prompting Newmeyer Dillion to bring a lawsuit against the city in 2017.
The dispute began in 2016 when Crown Castle filed an application with the City Council of the City of Piedmont to build nine small cell wireless sites designed to provide critical wireless telecommunications coverage in Piedmont. In October 2017, the Council denied the network, rejecting some of the proposed sites or approving others with onerous conditions.
Newmeyer Dillion's Government, Land Use and Environmental practice group filed a lawsuit on behalf of Crown Castle in the United States District Court for the Northern District of California in November 2017, challenging the Council's decision. Drawing from the language established in the Telecommunications Act of 1996, the lawsuit alleged that Piedmont's ordinances established an unreasonably high bar of approval, unlawfully prohibiting telecommunications services in the city.
The city quickly requested a court-supervised settlement, which was approved by the City Council in December 2018 and allowed Crown Castle to reapply to build 17 small cell wireless telecommunications facilities. The unanimous City Council approval came after extensive mediation work between the two parties.
"We are excited that our years-long efforts have culminated in this major win for Crown Castle, allowing them to build out critical telecommunications infrastructure in the City of Piedmont," said Michael Shonafelt, partner at Newmeyer Dillion. "With the growing national need for robust telecommunications networks that can handle voice communication and modern data demands, approvals such as this are significant, not just for the community the network serves, but for the viability of the national telecommunications network as a whole. Our team is proud to be using our multidisciplinary, business-oriented approach to successfully advise clients navigating these issues."
About Newmeyer Dillion
For 35 years, Newmeyer Dillion has delivered creative and outstanding legal solutions and trial results for a wide array of clients. With over 70 attorneys practicing in all aspects of corporate, privacy & data security, employment, real estate, construction, insurance law and trial work, Newmeyer Dillion delivers legal services tailored to meet each client's needs. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949.854.7000 or visit www.newmeyerdillion.com.
Read the court decisionRead the full story...Reprinted courtesy of
Appraisal Award for Damaged Roof Tiles Challenged
December 04, 2023 —
Tred R. Eyerly - Insurance Law HawaiiThe district court denied Travelers' motion for summary judgment and granted the insureds' motion in part regarding replacement of roof tiles damaged in a hail storm. Bertisen v. Travelers Home & Marine Ins. Co., 2023 U.S. Dist. LEXIS 159649 (D. Colo. Sept. 8,2023).
On May 8, 2017, the insureds' home was struck by a hailstorm that damaged their property. A Travelers inspector found damage to metal roof components, a deck, patio furniture and gutters. A partial payment of $6,381.04 was made. A further payment was made for personal property damaged by the storm. Travelers disputed that the hailstorm caused damage to all of the roof tiles.
Travelers' adjustor reinspected the property and observed additional damages caused by hail and another payment of $6,605.22 was issued.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com