Seattle Washington Building Expert Directory

Constructive Suspension (Suspension Outside of an Express Order)

December 13, 2022 — David Adelstein - Florida Construction Legal Updates
In the federal procurement arena, there is a concept known as “constructive suspension.” Constructive suspension, while known in the federal arena, should reasonably apply to all projects when work is stopped outside of an express order to stop the work based on the law below. An unreasonable suspension is an unreasonable suspension and an express order to stop the work does not negate the effects of what really amounts to a suspension. “Constructive suspension occurs when work is stopped absent an express order by the contracting officer and the government is found to be responsible for the work stoppage.” P.R. Burke Corp. v. U.S., 277 F.3d 1346, 1359 (Fed. Cir. 2002). The government delay must be unreasonable to support a constructive acceleration claim. Id. “To demonstrate such a constructive suspension of work, the contractor must show that the delay (1) was for an ‘unreasonable length of time,’ (2) was proximately caused by the government’s actions, and (3) resulted in some injury to the contractor.” Fireman’s Fund Ins. Co. v. U.S., 2001 WL 36415627, *6 (Fed.Cl. 2001) (citation omitted). “Relative to proving that the delay was directly caused by the government, the contractor must concomitantly show that it was not delayed by any concurrent cause that would have independently generated the delay during the same time period even if it does not predominate over the government’s action as the cause of the delay.” Beauchamp Const. Co. v. U.S., 14 Cl.Ct. 430, 437 (Cl.Ct. 1988). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Construction Firm Settles Suit Over 2012 Calif. Wildfire

January 15, 2019 — Associated Press - Engineering News-Record
SACRAMENTO, Calif. (AP) — Officials say a construction company and a logging firm have collectively agreed to pay $9 million for damages resulting from a 2012 wildfire that burned more than 1,600 acres of national forest land in Northern California. The U.S. Attorney's office in Sacramento says Monday that the agreement settles a lawsuit brought by the federal government against Kernen Construction and Bundy & Sons Logging. Read the court decision
Read the full story...
Reprinted courtesy of Engineering News-Record
ENR may be contacted at ENR.com@bnpmedia.com

Judgment Proof: Reducing Litigation Exposure with Litigation Risk Insurance

March 04, 2024 — Latosha M. Ellis & Charlotte Leszinske - Hunton Insurance Recovery Blog
It is not just your imagination: verdicts are getting bigger. So-called “nuclear verdicts” have increased in size and frequency over the past decade, particularly after the COVID-19 pandemic. Litigation risk insurance is a little known, but highly effective, option meant to compliment traditional insurance products and provide additional protection for policyholders nervous about litigation exposure. Unfortunately, it is difficult to predict the exposure presented by any particular case. Between 2020 and 2022, the median verdict increased 95%—from $21.5 million to $41.1 million. In 2022, a jury handed down a verdict worth $7.3 billion for injury to a single plaintiff. Even if an injury or loss is minor, juries have shown that they are willing to penalize corporate defendants with punitive damages that significantly exceed the award of compensatory damages. With such uncertainty and millions (if not billions) at stake, companies can reduce risk with litigation risk insurance. Three key types of litigation risk insurance include: (1) punitive wrap insurance, (2) adverse judgment insurance, and (3) judgment preservation insurance. Reprinted courtesy of Latosha M. Ellis, Hunton Andrews Kurth and Charlotte Leszinske, Hunton Andrews Kurth Ms. Ellis may be contacted at lellis@HuntonAK.com Ms. Leszinske may be contacted at cleszinske@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

Hawaii Supreme Court Construes Designated Premises Endorsement In Insured's Favor

April 01, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The Hawaii Supreme Court held that a Designated Premises Endorsement provided coverage for injury and damage that occurred away from a listed location if the injury or damage arose out of the ownership, maintenance or use of the designated premises. C. Brewer and Co., Ltd. v. Marine Indemn. Ins. Co., 2015 Haw. LEXIS 62 (Haw. March 27, 2015). [Disclosure: our office represents C. Brewer]. The case involves coverage for the former owner (C. Brewer) of land under the Kaloko Reservoir. The Reservoir was fronted by an earthen dam. The Dam burst in March 2006, killing seven people and causing extensive property damage downstream. In 1977, the State of Hawaii and C. Brewer entered an agreement requiring C. Brewer to, among other things, restore and expand the irrigation system that provided water to sugar cane fields in Kilauea, Kauai. C. Brewer formed the Kilauea Irrigation Company (KIC) to satisfy obligations to the State, revitalize the System, and sell System water to local farmers for irrigation. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

DC Circuit Upholds EPA’s Latest RCRA Recycling Rule

September 23, 2019 — Anthony B. Cavender - Gravel2Gavel
On July 2, 2019, the U.S. Court of Appeals for the District of Columbia Circuit decided the case of California Communities Against Toxics, et al. v. EPA. In this decision, the court rejected the latest petition to strike or vacate EPA’s 2018 revisions to the Resource Conservation and Recovery Act (RCRA) hazardous waste recycling rules. In 1985, EPA promulgated a new regulatory definition of “solid waste,” which is the linchpin of the agency’s very stringent hazardous waste management rules. (See the rules located at 40 CFR Sections 260-268.) Unless a material is a “solid waste” as defined by the rules, it cannot also be a hazardous waste. The 1985 rules grappled with the challenges posed by recycling practices, and attempted to distinguish between legitimate recycling which is not subject to hazardous waste regulation, and other more suspect forms of recycling. The rules are complex and replete with nuance. In doing so, EPA was adhering to RCRA’s statutory mandate that it develop appropriate rules to govern the treatment, storage and disposal of hazardous waste, while also promoting “properly conducted recycling and reuse.” The DC Circuit reviewed the 1985 rules in the seminal case of American Mining Congress v EPA, 824 F.2d 1177 (1987), (AMC) and stressed that only those materials that were truly discarded could be regulated as solid waste; for instance, those materials that were destined for immediate recycling or recovery in an ongoing production process were not discarded and hence were not solid waste. Over the years, the court has struggled to clarify the basic holding of AMC in numerous cases while EPA has frequently revised and amended the RCRA rules, and in particular the definition of solid waste, in an attempt to balance the policies mandated by the statute. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

Georgia Super Lawyers Recognized Two Lawyers from Hunton’s Insurance Recovery Group

March 06, 2023 — Hunton Insurance Recovery Blog
Hunton insurance recovery group partner Larry Bracken and associate Rachel Hudgins were each recognized in Georgia Super Lawyers 2023’s most recent publication. Larry Bracken was recognized as a Super Lawyer, and Rachel Hudgins was selected as a Rising Star for Insurance Coverage. Super Lawyers, a subsidiary of Thomson Reuters, is a rating service of outstanding lawyers from more than 70 practice areas who have attained a high-degree of peer recognition and professional achievement. The patented selection process includes independent research, peer nominations and peer evaluations. Ultimately, no more than 5% of lawyers in a state are selected as Super Lawyers, and less than 2.5% are recognized as Rising Stars. Congratulations to Larry and Rachel on this achievement! Read the court decision
Read the full story...
Reprinted courtesy of Hunton Andrews Kurth LLP

Project-Specific Commercial General Liability Insurance

May 13, 2019 — Jeremiah M. Welch - Saxe Doernberger & Vita, P.C.
Many markets which provide insurance for construction projects include an endorsement providing coverage for “repair work” as part of their standard policy. “Repair work” endorsements are largely misunderstood by policyholders and the insurance broker community. They are typically assumed to be coverage enhancements, but many provide no additional coverage and actually risk reduction of coverage otherwise provided as part of the products-completed operations (“PCO”) extensions also found in these project-specific policies. This article is designed to help the reader understand these endorsements so that better decisions can be made at the point of purchase. Intent The common feature of these endorsements is a grant of coverage for bodily injury and property damage resulting from “repair work” for a specified period of time. Most endorsements define “repair work” to mean the repair of completed work performed pursuant to a contract or warranty. Read the court decision
Read the full story...
Reprinted courtesy of Jeremiah M. Welch, Saxe Doernberger & Vita, P.C.
Mr. Welch may be contacted at jmw@sdvlaw.com

A WARNing for Companies

March 13, 2023 — Abby M. Warren & Sapna Jain - Construction Executive
Since last fall, news of layoffs in the technology sector have set off a ripple effect in a variety of other industries. Companies engaging in layoffs must be thoughtful and prepared when it comes to taking such action. While the construction industry generally has one of the highest layoff rates, and human resource personnel may be very knowledgeable with regard to related risks and exposure, there are a number of additional issues to consider when there are mass layoffs or closings. Further, expensive litigation awaits if companies are not meticulous in complying with state and federal laws regarding such large scale reductions in force. Under federal law, the primary legislation governing mass layoffs and closing is the Worker Adjustment and Retraining Notification (“WARN”) Act which generally covers employers with 100 or more employees. This law was enacted to protect employees by requiring companies to provide 60 days’ notice to employees in advance of certain plant closings and mass layoffs. In addition, many states, such as California, Connecticut and New York, have enacted similar state laws, referred to as “mini-WARN” laws, which impose additional requirements, including increasing the length of the required advance notice and broadening the scope of employers to which the law applies. Reprinted courtesy of Abby M. Warren and Sapna Jain, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES