Graham & Who May Trigger The Need To Protest
December 23, 2023 —
Hugo Fraga - Ahlers Cressman & Sleight PLLCOn May 30, 2023, the Washington Court of Appeals, Division I, issued a decision that appears to expand a contractor’s obligation with respect to WSDOT notice and claim procedures. In
Graham Contracting, Ltd. v. City of Federal Way, No. 83494-1-I, 2023 WL 3721171 (Wash. Ct. App. May 30, 2023) (Unpublished), the Court held that under the 2016 WSDOT Standard Specifications for Road, Bridge, and Municipal Construction (“Standard Specifications”), a Contractor must protest the actions of not only the “Engineer” but also the actions of any person or organization acting on behalf of the Owner.
This case arises out of a public construction contract in which Graham Contracting Ltd (“Graham”) built a multi-million dollar roadway improvement for the City of Federal Way along a stretch of Pacific Highway. The appeal was from the trial court’s granting of the City’s motion for summary judgment to dismiss claims by Graham for extra time and money due to delays and impacts to Graham’s construction of the Project.
Read the court decisionRead the full story...Reprinted courtesy of
Hugo Fraga, Ahlers Cressman & Sleight PLLCMr. Fraga may be contacted at
hugo.fraga@acslawyers.com
Project Completion Determines Mechanics Lien Recording Deadline
April 08, 2024 —
William L. Porter - Porter Law GroupThe California mechanics lien is one of the most powerful collection remedies available to contractors, subcontractors and suppliers who are unpaid for work performed and materials supplied in relation to a California private works construction project. The mechanics lien allows the claimant to actually sell the property where the work was carried out in order to obtain payment, entirely of course, against the wishes of the property owner. There are a number of important steps to follow and timelines to be met in order to pursue this remedy.
First, Understand Your Preliminary Notice Deadline
Working within deadlines is absolutely crucial to preserving mechanics lien rights under California law. The deadlines differ, depending on whether you are a “direct” contractor, also known as “original” or “prime” contractor (one who contracts directly with the property owner) or a subcontractor or material supplier. The process begins with the serving of a “preliminary notice” no later than 20 days after the party serving the preliminary notice begins supplying labor or materials to the project. Direct contractors are only required to serve the preliminary notice on the construction lender (Civil Code section 8200-8216), whereas subcontractors and material suppliers must serve not only the construction lender, but also the owner and direct contractor (see Civil Code section 8200(e)).
Read the court decisionRead the full story...Reprinted courtesy of
William L. Porter, Porter Law GroupMr. Porter may be contacted at
bporter@porterlaw.com
Florida Condos Bet on Americans Making 50% Down Payments
October 29, 2014 —
John Gittelsohn – BloombergJorge Perez crashed along with the real estate market, then regained his crown as Florida’s “Condo King” by building new projects with 50 percent deposits from foreign buyers. Now, for his next development, he’s looking to wealthy Americans.
In December, he’ll begin marketing the Auberge Beach Residences and Spa Fort Lauderdale, a $500 million oceanfront project 35 miles (56 kilometers) north of Miami. He expects as many as two-thirds of the buyers to come from the U.S. or Canada. All future owners must pay hefty deposits to finance construction by Perez’s Related Group, Fortune International Group and Fairwinds Group in a partnership that the companies plan to announce tomorrow.
“The U.S. buyers have made up an increasing share of luxury beachfront condominiums and, like our foreign buyers, they have shown little resistance to larger deposits,” Perez said in an e-mail. “Most feel that if they can’t put a 50 percent down payment, they probably should not be buying.”
Read the court decisionRead the full story...Reprinted courtesy of
John Gittelsohn, BloombergMr. Gittelsohn may be contacted at
johngitt@bloomberg.net
Connecticut Court Holds Unresolved Coverage Issues Makes Appraisal Premature
July 18, 2018 —
Michael S. Levine, Lorelie S. Masters & Geoffrey B. Fehling – Hunton Insurance Recovery Law BlogA Connecticut court recently denied a motion to compel appraisal of a claim for coverage of a commercial property damage claim, holding that, where the insurance policy at issue provides for appraisal of disputes related to the value or quantum or a loss suffered—not the rights and liabilities of the parties under the policy—appraisal is premature. The decision relied on law that equates insurance appraisal to arbitration and follows a number of decisions holding that parties cannot expand the scope of appraisal clauses to resolve questions of coverage or liability where, as in this case, those issues are not supported by the applicable policy language.
Reprinted courtesy of Hunton Andrews Kurth attorneys
Michael S. Levine,
Lorelie S. Masters and
Geoffrey B. Fehling
Mr. Levine may be contacted at mlevine@HuntonAK.com
Ms. Masters may be contacted at lmasters@HuntonAK.com
Mr. Fehling may be contacted at gfehling@HuntonAK.com
Read the court decisionRead the full story...Reprinted courtesy of
Newmeyer Dillion Announces Partner John Van Vlear Named to Board Of Groundwater Resources Association Of California
January 13, 2020 —
Newmeyer DillionProminent Orange County-based law firm Newmeyer Dillion is pleased to announce that partner
John Van Vlear has been elected to the Board of Directors for the Groundwater Resources Association of California (GRA). He will serve a three year term effective immediately.
"It was an honor to be nominated and I'm excited to help further GRA's goal of remaining the preeminent professional organization in the West addressing timely and important groundwater issues," says Van Vlear. He has been a member of the GRA for five years and has spoken both at a Southern California branch event and the 2nd Annual Western Groundwater Congress in Sacramento. Serving on the GRA Board will be Van Vlear's fourth different lifetime non-profit Board volunteer effort. He joins a diverse group of members to complete the Board, including a hydrologist with the US Geological Survey, environmental and engineering consultants, an equipment manufacturer, and water agencies' managers.
Van Vlear's practice focuses on all aspects of "contaminated sites" environmental legal work. Applying technical acumen, he focuses on investigation, strategic analysis, and remediation for site acquisitions/sales, development, regulatory interface, and related litigation in federal and state courts. He represents clients before a wide range of environmental agencies and has a portfolio of projects that include: commercial, industrial, raw land, and residential, as well as specialty facilities such as affordable housing, oil fields, and landfills throughout California and across the country. These matters have involved a complex blend of soil, groundwater, and vapor contamination. Van Vlear is a frequent speaker on environmental, real estate and contamination topics, as well as being a professional author and novelist, an expert witness, and arbitrator on environmental issues. He has been interviewed on TV twice professionally and has testified before the California Senate subcommittee on Environmental Quality.
Established in 1992, the GRA is a 1,000 member state-wide professional organization dedicated to resource management that protects and improves groundwater supply and quality through education and technical leadership. The GRA hosts programs and webinars focusing on important issues to water management community at both the state-wide and regional branch levels.
About Newmeyer Dillion
For 35 years, Newmeyer Dillion has delivered creative and outstanding legal solutions and trial results that achieve client objectives in diverse industries. With over 70 attorneys working as a cohesive team to represent clients in all aspects of business, employment, real estate, environmental/land use, privacy & data security and insurance law, Newmeyer Dillion delivers holistic and integrated legal services tailored to propel each client's success and bottom line. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California and Nevada, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949.854.7000 or visit www.newmeyerdillion.com.
Read the court decisionRead the full story...Reprinted courtesy of
Denver Parking Garage Roof Collapses Crushing Vehicles
February 12, 2014 —
Beverley BevenFlorez-CDJ STAFFOn Monday night, a parking garage ceiling collapsed at the Park Mayfair Condos in Denver, Colorado, according to KKTV News. Residents claim that “between five and ten vehicles were completely destroyed after the ceiling of the underground garage caved in.” No one was injured from the incident. Structural engineers have not commented “yet on how the collapse occurred, but residents told sister station KCNC that the ceiling fell after a cement beam holding up one side of the roof collapsed.”
According to KWGN News, FOX31 interviewed a “passerby” who alleged that he lived in the condominium five years ago, but moved out “because inspectors repeatedly sent notices to fix problems with the garage, but, to his knowledge, no action was taken by the condo complex.”
Read the full story at KKTV News...
Read the full story at KWGN News... Read the court decisionRead the full story...Reprinted courtesy of
When Can Customers Sue for Delays?
September 18, 2023 —
Scott L. Baker - Los Angeles Litigation BlogConstruction projects are subject to many internal and external factors. Due to this, delays are not an uncommon occurrence. Whether delays are the result of bad weather conditions or supply chain issues, contractors and their clients cannot control every aspect of the project.
Delay issues are very
common construction disputes. Therefore, new and experienced contractors alike need to know when their clients may have a reason for a delay claim.
2 particular types of delays that pose a risk
Common obstacles that contractors faced during the height of the COVID-19 global pandemic involved supply chain issues. The lack of materials put various projects on hold across California and the country. This widespread issue was out of contractors’ and clients’ control, meaning they were excusable delays.
Read the court decisionRead the full story...Reprinted courtesy of
Scott L. Baker, Baker & AssociatesMr. Baker may be contacted at
slb@bakerslaw.com
Structural Failure of Precast-Concrete Span Sets Back Sydney Metro Job
February 23, 2017 —
Chris Webb - Engineering News-RecordA key component of Australia’s biggest public transport infrastructure project—Sydney’s $6.3-billion Metro North West—is the subject of a
critical and detailed technical report describing how an elevated viaduct span failed at a stitch joint between two precast segments during construction last September. Project officials say the affected span, which did not suffer a progressive collapse, has since been removed and its replacement fast-tracked to avoid further delays. Little additional detail was provided.
Read the court decisionRead the full story...Reprinted courtesy of
Chris Webb, ENRENR may be contacted at
ENR.com@bnpmedia.com