Fairfield Connecticut Building Expert Directory

Here's How Much You Can Make by Renting Out Your Home

August 20, 2014 — Suzanne Woolley – Bloomberg
Oklahoma City and San Jose, California, top lists of cities where homeowners deciding to rent rather than sell their homes could see the biggest gains. That's according to real estate information website Zillow Inc., which ran data to see what current homeowners could make if they became mom-and-pop landlords. The Okies in their state's capital city win when it comes to monthly profits: $536, or $6,431 annually. For long-term gains, the top 10 cities are those where homeowners would lose money every year by renting -- until the big payoff when they sell. Zillow translates that gain, looking back, into monthly and yearly profits. So fast-appreciating Californian cities win big, led by San Jose. (Scroll down to see the Top 10 lists; the entire list is here.) The top 10 short-term gainers range geographically from Rochester, N.Y., to Dallas-Fort Worth, Texas. Monthly rental profits there are $349 and $264, respectively, or annual income of $4,182 and $3,166. Read the court decision
Read the full story...
Reprinted courtesy of Suzanne Woolley, Bloomberg
Ms. Woolley may be contacted at swoolley2@bloomberg.net

California Appeals Court Remands Fine in Late Completion Case

November 18, 2011 — CDJ STAFF

The California Court of Appeals in Stanislaus County has reversed the decision of the lower court in Greg Opinski Construction Inc. v. City of Oakdale. The earlier court had awarded the city of judgment of $54,000 for late completion, $3,266 for repair of construction defects and interest, and $97,775 in attorneys’ fees. The late completion of the project was due to actions by the City of Oakdale, however, the court rejected Opinski’s argument that the California Supreme Court decision in Kiewit did not allow this, as his contract with the city established a procedure for claiming extensions.

The appeals court noted that the Kiewit decision has been “criticized as an unwarranted interference in the power of contracting parties to shift the risk of delays caused by one party onto the other party by forcing the second party to give the first notice of any intention to claim an extension of time based on delays caused by first.” They cited Sweet, a professor at Boalt Hall, UC Berkeley’s law school, that Kiewit “gutted” the “provision that conditions the contractor’s right to claim an extension of time for delays beyond his control.”

Further changes in California law in response to the Kiewit decision lead to the current situation which the court characterized as “if the contractor wished to claim it needed an extension of time because of delays caused by the city, the contractor was required to obtain a written change order by mutual consent or submit a claim in writing requesting a formal decision by the engineer.”

Opinski also argued that the lower court misinterpreted the contract. The Appeals court replied that “Opinski is mistaken.” He cited parts of the contract regarding the increase of time, but the court rejected these, noting that “an inability to agree is not the same as an express rejection.”

The court also rejects Opinski’s appeal that “the evidence the project was complete earlier than September 30, 2005, is weightier than the evidence to the contrary,” which they describe as “not a winning appellate argument.” The court points out that the role of an appeals court is not to reweigh the evidence, but to determine “whether the record contains substantial evidence in support of the judgment.”

The court did side with Opinski on one question of the escrow account. They rejected most of his arguments, repeating the line “Opinski is mistaken” several times. They decided that he was mistaken on the timing of the setoff decision and on whether the city was the prevailing party. However, the appeals court did find that Opinski was not liable for interest on the judgment.

The appeals court rejected the awarding of prejudgment interest to the city as the funds from which the judgment was drawn was held in an escrow account. The court noted that the city had access to the funds and could “access the funds when it determined that Opinski had breached the contract.” The appeals court noted that the judgment exhausted the escrow balance and remanded the case to the lower court to determine the amount own to Opinski.

Read the court’s decision…

Read the court decision
Read the full story...
Reprinted courtesy of

Sales of New Homes in U.S. Increased 5.4% in July to 507,000

August 26, 2015 — Shobhana Chandra – Bloomberg
Purchases of new homes in the U.S. rebounded in July, bolstering signs the real-estate market is picking up. Sales climbed 5.4 percent, the biggest gain this year, to a 507,000 annualized pace from a 481,000 rate in the prior month, a Commerce Department report showed Tuesday in Washington. The median forecast of 75 economists surveyed by Bloomberg called for 510,000. Demand had declined 7.7 percent in June. Demand for new properties is likely to keep expanding amid strong employment, low borrowing costs and a lack of available existing homes from which to choose. The improving outlook may spur more residential construction, contributing to the economic expansion in the second half of the year. Read the court decision
Read the full story...
Reprinted courtesy of

California Court of Appeal Clarifies Intent of Faulty Workmanship Exclusions

October 26, 2017 — Tiffany Casanova – Saxe Doernberger & Vita, P.C.
Last month, in Global Modular, Inc. v. Kadena Pacific, Inc., 1 a California Court of Appeal clarified the meaning of the frequently asserted j.(5) and j.(6) exclusions of the standard commercial general liability policy; an issue the court deemed one of “first impression” for the state. The court took a close look at how courts nationwide handle the exclusions and relied on the policy language to come to a policyholder-friendly decision. Read the court decision
Read the full story...
Reprinted courtesy of Tiffany Casanova, Saxe Doernberger & Vita, P.C.
Ms. Casanova may be contacted at tlc@sdvlaw.com

San Francisco International Airport Reaches New Heights in Sustainable Project Delivery

November 21, 2022 — Aileen Cho - Engineering News-Record
Ten years ago, Geoff Neumayr decided he was tired of “doing design and construction by combat.” San Francisco International Airport had completed a master plan for the complex and the front of the airport facilities doing things the traditional way. Reprinted courtesy of Aileen Cho, Engineering News-Record Ms. Cho may be contacted at choa@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

California Statutes Authorizing Public-Private Partnership Contracting

February 01, 2022 — Robert A. James & Shade Oladetimi - Gravel2Gavel Construction & Real Estate Law Blog
Public-private partnerships are often cited as a key pathway to restoring and enhancing the nation’s infrastructure. They can be challenging arrangements to structure. (As a result of the pandemic, they have even suffered the indignity of having their “PPP” acronym coopted by the Paycheck Protection Program. With apologies to Small Business Administration practitioners, we use “PPP” in this article to refer to the infrastructure tool.) One gating condition to setting up a PPP is identifying the authority for a public entity to use a contracting method that does not run afoul of the general requirements that (i) works of improvement be let to the lowest responsive bid by a responsible bidder and (ii) design services be awarded through a qualifications-based selection process. Integrated forms of project delivery that vest in a single concessionaire multiple design, construction, financing, operation, maintenance and entrepreneurial roles must find an exception to any applicable background rules. Reprinted courtesy of Robert A. James, Pillsbury and Shade Oladetimi, Pillsbury Mr. James may be contacted at rob.james@pillsburylaw.com Ms. Oladetimi may be contacted at shade.oladetimi@pillsburylaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Real Estate & Construction News Round-Up (09/21/22) – 3D Printing, Sustainable Design, and the Housing Market Correction

October 17, 2022 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
The first 3D-printed home is under construction, construction contractors could face liability for not securing employee data, the housing market correction continues, and more.

Sustainable home design has become key focus of builders and homeowners, helping reduce carbon emissions and other environmental impacts. (Kristi Waterworth, U.S.News)
Construction contractors could face legal consequences for failing to manage employee data correctly. (Robyn Griggs Lawrence, Construction Dive)
The home price correction continues to spread across the U.S., with an interactive map showcasing local housing markets that have been impacted. (Lance Lambert, Fortune)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

'Perfect Storm' Caused Fractures at San Francisco Transit Hub

January 08, 2019 — Nadine M. Post - Engineering News-Record
The underlying causes of the trouble at San Francisco’s 4.5-block-long Salesforce Transit Center are coming into focus. A combination of low fracture toughness deep inside thick steel plates, cracks present as a consequence of normal steel fabrication and stress levels from loads, which are a function of design, apparently caused brittle fractures in the bottom flanges of the center's twin built-up plate girders that span 80 ft across Fremont Street. Read the court decision
Read the full story...
Reprinted courtesy of Nadine M. Post, ENR
Ms. Post may be contacted at postn@enr.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES