Georgia Court Rules that Separate Settlements Are Not the End of the Matter
October 14, 2013 —
CDJ STAFFThe Georgia Court of Appeals recently took up the question of how parties in a construction defect settlement relate to one another in terms of apportioning the settlement. Scott Murphy, writing on the Barnes & Thornburg blog clarifies the issues. The underlying construction defect case involved a newly-constructed hotel with mold and mildew problems. The owners sued the contractor (for negligent construction) and the architect (for negligent design). Separately, the owners settled with the contractor for $2.3 million and the architect for $100,000. Subsequently, the contractor sued the architect, attempting to recover part of the settlement the contractors had made with the owners.
At trial, the architect prevailed, obtaining a summary judgment that under Georgia law, “joint-tortfeasors can no longer assert contribution or non-contractual indemnity claims.” This was reversed by the Court of Appeals, determining that the two were not joint tortfeasors. Mr. Murphy notes that “the court rejected the parties’ attempt to disavow joint and several liability in their respective settlement agreements.” The court ruled that the contractor could proceed with their claims against the argument.
Read the court decisionRead the full story...Reprinted courtesy of
Injury to Employees Endorsement Eliminates Coverage for Insured Employer
February 01, 2021 —
Tred R. Eyerly - Insurance Law HawaiiThe court granted summary judgment to the insurer based upon an endorsement which barred coverage for injuries to employees. Northfield Ins. Co. v. Z&J Mgt. LLC, 2020 N.Y. Misc. LEXIS 10801 (N.Y. Sup. Ct. Dec. 18, 2020).
Ravi Sooklal sued his employer, Z&J Management LLC (Z&J), for injuries at the job site. Northfield, who had issued a CGL policy to Z&L, denied coverage based upon two endorsements. The first was titled "Injury to Employees of Insureds" and the second was "Employers' Liability." Northfield sued for a declaratory judgment and now moved for summary judgment.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Court Rejects Insurer's Argument That Two Triggers Required
May 12, 2016 —
Tred R. Eyerly – Insurance Law HawaiiThe court rejected the insurer's argument that two triggers - one for exposure to asbestos and one for resulting injury - were required under CGL policies. Compass Ins. Co. v. University Mechanical and Engineering Contractors, Inc., 2016 U.S. Dist. LEXIS (N.D. Cal. March 25, 2016).
University Mechanical and Engineering Contractors, Inc. (UMEC) was a California corporation in the business of installing plumbing, piping and HVAC systems. UMEC was defending a number of asbestos cases in California state courts arising from its subcontracting work.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
Spearin Doctrine as an Affirmative Defense
November 30, 2016 —
David Adelstein – Florida Construction Legal UpdatesThe Spearin doctrine, referred to as the implied warranty of constructability doctrine, is oftentimes utilized as an affirmative defense by a contractor being sued for construction defects. Under the Spearin doctrine (recognized in the government contract setting), a contractor is NOT liable for defects in the plans and specifications furnished by the owner if the contractor constructs the project pursuant to the plans and specifications. This is because the owner impliedly warrants the constructability of the plans and specifications it furnishes to the contractor. Hence, the contractor should not be liable for defective construction caused by the owner furnishing defective plans and specifications.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Katz, Barron, Squitero, Faust, Friedberg, English & Allen, P.A.Mr. Adelstein may be contacted at
dma@katzbarron.com
Patti Santelle Honored by Rutgers School of Law with Arthur E. Armitage Sr. Distinguished Alumni Award
March 01, 2021 —
Patricia Santelle - White and WilliamsWhite and Williams is proud to announce that Patti Santelle, Chair Emeritus, will be honored by the Rutgers School of Law-Camden Alumni Association with the 2020 Arthur E. Armitage Sr. Distinguished Alumni Award. The Armitage Award was established in 1983 in memory of Armitage, who, with a group of interested citizens, founded both the South Jersey Law School in 1926 and its companion College of South Jersey in 1927. Past recipients include governors, member of Congress, state and federal judges, and industry leaders.
Patti, a 1985 graduate, is a Co-Chair of the Executive Committee of the newly established Rutgers Law Alumnae Network and a Past Chancellor and long-time member of the Board of the Rutgers-Camden Law Alumni Association. While in law school, she was President of the Student Bar Association, winner of the Hunter Advanced Moot Court Competition and a member of the National Moot Court Team. In 2010, Patti received the Scarlet Oak Meritorious Service Award from Rutgers University for her contributions as an alumni leader and student mentor at the law school. For the past seven years, she served as the Managing Partner and Chair of the Executive Committee at White and Williams, the first woman in the firm’s history and in the City of Philadelphia to serve in that role in a major law firm.
Read the court decisionRead the full story...Reprinted courtesy of
Patricia Santelle, White and WilliamsMs. Santelle may be contacted at
santellep@whiteandwilliams.com
A Lawyer's Perspective on Current Issues Dominating the Construction Industry
March 28, 2022 —
Melanie A. McDonald - Saxe Doernberger & VitaSome of the hot topics dominating the construction industry today include the impacts of COVID-19, government testing and vaccine mandates, cyber security, and the evolving role of general counsel. This article provides a summary review of those topics.
a. The Economic Impact of COVID-19 for Project Owners
Project owners have been placed in a precarious position because courts across the country have almost unanimously ruled that insurance carriers are not liable for COVID-19-related business income losses.1 While project owners have sought alternative ways to mitigate losses resulting from COVID-19, many of these efforts have been negated by the exponential increase in materials costs.2 Thus, it remains unclear what, if any, solutions project owners have at their disposal.
Read the court decisionRead the full story...Reprinted courtesy of
Melanie A. McDonald, Saxe Doernberger & VitaMs. McDonald may be contacted at
MMcDonald@sdvlaw.com
Pacing in Construction Scheduling Disputes
September 14, 2017 —
Luke Mecklenburg - Snell & Wilmer Real Estate Litigation BlogOn a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway.
However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48.
Read the court decisionRead the full story...Reprinted courtesy of
Luke Mecklenburg, Snell & WilmerMr. Mecklenburg may be contacted at
lmecklenburg@swlaw.com
New Addition to the ASCE/SEI 7-22 Standard Protects Buildings from a 500-year Flood Event
June 05, 2023 —
The American Society of Civil EngineersReston, VA — The
American Society of Civil Engineers (ASCE) released a new update to their most widely used standard today,
ASCE/SEI 7-22 Minimum Design Loads and Associated Criteria for Building and Other Structures. As the increasing frequency of severe storms puts strain on communities across the globe, the design standard's
new flood load provisions will protect against 500-year flood events, which is a significant improvement to the 100-year flood hazard referenced in the previous version. The update — which is available in a supplement as a free download — is a significant revision of the design provisions in Chapter 5 to strengthen building resilience against the flood hazard. The ASCE 7 national loading standard is an integral part of building codes in the United States and around the globe.
"For more than 30 years, the ASCE 7 standard has been the authoritative source for the specification of minimum design loads and related criteria in the civil engineering community," said Tom Smith, ASCE Executive Director. "To ensure structures continue to be safe for the public, it is imperative that the standards we rely on are updated to account for emerging risks to the built environment. This Supplement is the most significant change to the standard's flood load provisions since the inception of ASCE 7 and will improve the safety and reliability of structures across the globe."
ABOUT THE AMERICAN SOCIETY OF CIVIL ENGINEERS
Founded in 1852, the American Society of Civil Engineers represents more than 150,000 civil engineers worldwide and is America's oldest national engineering society. ASCE works to raise awareness of the need to maintain and modernize the nation's infrastructure using sustainable and resilient practices, advocates for increasing and optimizing investment in infrastructure, and improve engineering knowledge and competency. For more information, visit www.asce.org or www.infrastructurereportcard.org and follow us on Twitter, @ASCETweets and @ASCEGovRel.
Read the court decisionRead the full story...Reprinted courtesy of