Fairfield Connecticut Building Expert Directory

Skilled Labor Shortage Implications for Construction Companies

July 15, 2019 — Tony James & Keith Maciejewski - Construction Executive
The construction industry is facing one of the most significant labor shortages it has ever seen. This labor shortage has far-reaching implications for worker safety and construction quality—both of which could adversely impact a company’s bottom line if investments are not made to address the issue. What’s causing the labor gap? There are two underlying trends driving this phenomenon:

More experienced workers have either not returned to the industry after the Great Recession or are now retiring as they’ve concluded their careers.
The construction industry has long struggled to attract new, younger workers to the industry, and this problem has only worsened as the broader economy boomed. As a result, construction firms must compete with other industries, such as health care, technology and engineering, for young talent.

Reprinted courtesy of Tony James & Keith Maciejewski, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

Duty To Defend Construction Defect Case Affirmed, Duty to Indemnify Reversed In Part

May 07, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The Eleventh Circuit affirmed the district court's finding of a duty to defend, but reversed, in part, the insurer's duty to indemnify. Carithers v. Mid-Continent Cas. Co., 2015 U.S. App. LEXIS 5540 (11th Cir. April 7, 2015). After discovering a number of defects in their home, the Carithers sued their homebuilder, Cronk Duch Miller & Associates. Cronk Duch's insurer, Mid-Continent Casualty Company, refused to defend.The parties entered into a consent judgment for $90,000 in favor of the Carithers. Cronk Duch then assigned to the Carithers the right to collect the judgment from Mid-Continent. The Carithers then sued Mid-Continent. Florida law applied. Mid-Continent has issued four policies to Cronk Duch from March 2005 to October 2008. The parties filed cross-motions for summary judgment on the duty to defend issue. The underlying complaint alleged that the defects could not have been discovered until 2010, after the last policy period. The district court rejected Mid-Continent's argument that property damage occurred when it was discovered or when it reasonably could have been discovered. Therefore, summary judgment on the duty to defend was granted to the Carithers. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Court of Appeals Finds Arbitration Provision Incorporated by Reference Unenforceable

September 20, 2021 — Garret Murai - California Construction Law Blog
Subcontractors have gotten accustomed to incorporation clauses in their contracts. While an incorporation clause can incorporate any document, most typically, it’s the prime contract between the general contractor and the project owner. Subcontractors will sometimes even accept these documents sight unseen which can be a recipe for disaster. But not in the next case. In Remedial Construction Services, LP v. AECOM, Inc., Case No. B303797 (June 15, 2021), the 2nd District Court of Appeal examined whether a subcontractor was bound to an arbitration provision contained in a prime contract that was incorporated by reference into the subcontractor’s contract. In this case, it was the prime contractor who was in for a surprise. The Remedial Construction Case In 2015, Shell Oil Products US, LLC entered into a prime contract with AECOM Technical Services, Inc. for the demolition, remediation and restoration of the Gaviota oil terminal in Goleta, California. AECOM in turn entered into a subcontract with Remedial Construction Services, LP to perform portions of the work. When AECOM refused to pay Remedial for delay costs asserted by Remedial, Remedial filed suit. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Estimate Tops $5.5B for Cost of Rebuilding After Maui Fires

August 21, 2023 — James Leggate - Engineering News-Record
Rebuilding after wildfires on the island of Maui in Hawaii could cost more than $5.5 billion, according to a preliminary assessment prepared by the University of Hawaii Pacific Disaster Center and local officials. Reprinted courtesy of James Leggate, Engineering News-Record Mr. Leggate may be contacted at leggatej@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Consolidated Case With Covered and Uncovered Allegations Triggers Duty to Defend

May 20, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The Illinois Court of Appeals held that the insurer had a duty to defend a consolidated case that included one complaint alleging intentional acts and another complaint alleging negligence. Farmers Auto. Ins. Ass'n v. Neumann, 2015 Il. App. 140026 (Ill. Ct. App. March 24, 2015, reh'g denied March 24, 2015). Neumann allegedly hit Bitner with his automobile as Bitner, a police offier, was directing traffic. Bitner sued Neumann, alleging intentional assault and intentional battery. Farmers rejected Neumann's tender because the policy did not cover intentional acts. Farmers filed for a declaratory judgment. In his answer, Neumann included an affidavit stating that he did not intend to strike or cause bodily harm to Bitner. The trial court granted the motion to strike the affidavit. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Precedent-Setting ‘Green’ Apartments in Kansas City

September 17, 2015 — Beverley BevenFlorez-CDJ STAFF
According to the Kansas City Star, the Missouri riverfront apartment development, Second and Delaware, is being constructed with “greener-than-green technology” and features the following: “Sixteen-inch-thick concrete walls. Rooftop gardens. A 90 percent reduction in energy use compared to current building codes.” The two buildings “will comprise the largest U.S. multifamily apartment project using Passive House Institute-certified construction, a system that’s more energy-efficient than the highest LEED (Leadership in Energy and Environmental Design) building standard.” Read the court decision
Read the full story...
Reprinted courtesy of

Implied Warranty Claims–Not Just a Seller’s Risk: Builders Beware!

May 10, 2021 — Carin Ramirez - Colorado Construction Litigation
One of the thorns in the side of every construction defect defense litigator is the implied warranty claim. The “implied warranty” is a promise that Colorado law is “implied” into every contract for a sale of a new home that the home was built in a workmanlike manner and is suitable for habitation. Defense attorneys dislike the implied warranty claim because it is akin to a strict liability standard. All that is required to provide the claim is that an aspect of construction is found to be defective — i.e., inconsistent with the building code or manufacturer’s installation instructions — regardless of whether the work was performed to the standard of care. The implied warranty claim is therefore easier to prove than a negligence claim, where a claimant must prove that a construction professional’s work fell below a standard of reasonable care. Additionally, it is not a defense to an implied warranty claim that the homeowners or the HOA are, themselves, partially liable for the defects where damage is due in part to insufficient or deferred maintenance, as it is for negligence claims. The only redeeming aspect to the implied warranty claim was that, until recently, it was believed that it could only be asserted by a first purchaser against the seller of an improvement, because the implied warranty arises out of the sale contract. Recently, the Colorado Court of Appeals opinion in Brooktree Village Homeowners Association v. Brooktree Village, LLC, 19CA1635, decided on November 19, 2020, extended the reach of the implied warranty — though just how far remains to be seen. Specifically, a division of the Court of Appeals held that an HOA can assert implied warranty claims on behalf of its members for defects in common areas, even where there is no direct contractual relationship between the parties to base the warranty upon. Read the court decision
Read the full story...
Reprinted courtesy of Carin Ramirez, Higgins, Hopkins, McLain & Roswell, LLC
Ms. Ramirez may be contacted at ramirez@hhmrlaw.com

Is Performance Bond Liable for Delay Damages?

October 20, 2016 — David Adelstein – Florida Construction Legal Updates
There is an argument that a performance bond is not liable for delay damages UNLESS the bond specifically allows for the recovery of such damages. Keep this in mind when requiring a performance bond so that the bond covers the associated risks (and damages) you contemplate when requiring the bond. This argument is supported by the Florida Supreme Court’s 1992 decision in American Home Assur. Co. v. Larkin General Hosp., Ltd., 593 So.2d 195, 198 (Fla. 1992):

The language in the performance bond, construed together with the purpose of the bond, clearly explains that the performance bond merely guaranteed the completion of the construction contract and nothing more. Upon default, the terms of the performance bond required American [performance bond surety] to step in and either complete construction or pay Larkin [obligee] the reasonable costs of completion. Because the terms of the performance bond control the liability of the surety, American’s liability will not be extended beyond the terms of the performance bond. Therefore, American cannot be held liable for delay damages.

However, the Eleventh Circuit in National Fire Ins. Co. of Hartford v. Fortune Const. Co., 320 F.3d 1260(11th Cir. 2003), also analyzing an issue relating to the recoverability of delay-type damages against a performance bond, did not narrowly interpret the Florida Supreme Court’s decision in Larkin General Hospital. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Katz, Barron, Squitero, Faust, Friedberg, English & Allen, P.A.
Mr. Adelstein may be contacted at dma@katzbarron.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES