Application Of Two Construction Contract Provisions: No-Damages-For-Delay And Liquidated Damages
February 14, 2022 —
David Adelstein - Florida Construction Legal UpdatesA recent Florida opinion between a prime contractor and a Florida public body touches upon two important issues: (1) the application of a no-damage-for-delay provision; and (2) the application of a liquidated damages provision. Both provisions find there way into many construction contracts. Unfortunately, the opinion is sparse on facts. Nevertheless, the application of these provisions is worthy of consideration.
In this opinion, Sarasota County v. Southern Underground Industries, Inc., 2022 WL 162977 (Fla. 2d DCA 2022), a county hired a contractor to install sanitary and water piping underneath a waterway. During construction, a nearby homeowner complained that vibration from the drilling caused damage to his home. As a result, the county stopped the contractor’s work to address a potential safety issue, as it was contractually entitled to do. The contractor hired a structural engineer to inspect the house and the engineer issued a report determining that any alleged damage was cosmetic and that there was sufficient monitoring of the vibrations to prevent future damage. The contractor also had an insurance policy to cover any homeowner claim for damage. However, upon receipt of the engineer’s report, the county did not lift its stop work order. Rather, the stop work order remained in place for an additional 71 days.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Delaware Settlements with Minors and the Uniform Transfer to Minor Act
October 15, 2014 —
Stephen J. Milewski – White and Williams LLPAs a Delaware lawyer, one of the most frequently asked questions I get from insurance clients is: “Do all personal injury settlements with minors need to be approved by the Court?” The answer is and always has been yes. This is true regardless of the amount of the settlement. There have, however, been some recent changes under Delaware law which may help facilitate the process and even reduce the costs associated with settling small tort cases with minors. Traditionally, when settling cases with a minor, a Petition would be filed with the trial court (Superior Court) and then a hearing would be scheduled for the parties to present to the Court the terms of the settlement, explain the plaintiff’s injuries and itemize the fee breakdown. This would be the settlement approval process. After that, the plaintiff would be required to have a guardian appointed over the proceeds, which had to be approved by Chancery Court (Delaware’s Court of Equity). The purpose of this process was to ensure the settlement money going to the minor was managed properly; the net proceeds were generally placed into a bank account not to be used by the guardian or the minor until the minor reached the age of majority. To both the plaintiff, and the insurance carrier paying out the settlement, this process was burdensome and added disproportionate costs to small settlements.
Read the court decisionRead the full story...Reprinted courtesy of
Stephen J. Milewski, White and Williams LLPMr. Milewski may be contacted at
milewskis@whiteandwiliams.com
Build, Baby, Build. But Not Like This, Britain.
March 04, 2024 —
Matthew Brooker - BloombergThe UK needs to do a lot more building. A lack of access to physical and digital connections is holding back the economy, the government says. Besides tackling the housing crisis, the country has to construct more roads, railways, wind farms and reservoirs to open up opportunity and drive productivity. The only problem is that Britain is notoriously inept at delivering infrastructure projects on time and within budget.
The advantage of doing things badly is that at least you get to learn from your mistakes — in theory. Updates this month have offered some illuminating insights into two of the biggest civil-engineering undertakings in the country: High-Speed Rail 2, better known as HS2, and Hinkley Point C, which will be Britain’s first new nuclear power station since 1995. Here are five lessons that can be drawn from the issues encountered by two projects with a combined bill that’s likely to exceed £100 billion ($127 billion):
Don't take budgets too seriously — especially at the start. Fixing an initial budget that was too low may have done much to feed later perceptions that HS2’s costs were spiraling out of control. The original estimate for the expanded train network was set too early and based on “very immature data,” Jon Thompson, appointed executive chair of High Speed 2 Ltd. in February last year, told the House of Commons transport committee. Numbers get more accurate and reliable as work progresses and the quality of information improves. What were viewed as cost blowouts partly reflected this process. The effect was unfortunate, undermining political support for HS2 and providing cover for cutbacks that have reduced the network to a single line between London and Birmingham that fails to fulfill most of its original purpose. To avoid this problem: Stick to a range rather than a single figure, and make sure people understand the uncertainties inherent in early-stage estimates.
Read the court decisionRead the full story...Reprinted courtesy of
Matthew Brooker, Bloomberg
Real Estate & Construction News Round-Up (12/07/22) – Home Sales, EV Charging Infrastructure, and Office Occupancy
December 26, 2022 —
Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law BlogThis week’s round-up explores decreasing home sales, electric vehicle charging stations, office occupancy levels, and more.
- With home sales dropping and more buyers abandoning their plans, forecasters have rarely disagreed as much as they are now regarding where the housing market is going next. (Nicole Friedman, Nick Timiraos, The Wall Street Journal)
- Contractors and construction technology firms are watching as skilled workers look for new jobs in a turbulent economy. (Matthew Thibault, Construction Dive)
- The ability to conveniently charge electric vehicles away from home is a top concern for many owners, indicating the strong need for an extensive and reliable external charging infrastructure. (Robert Charette, IEEE Spectrum)
Read the court decisionRead the full story...Reprinted courtesy of
Pillsbury's Construction & Real Estate Law Team
New Survey Reveals Present-Day Risks of Asbestos Exposure in America - 38% in High-Risk Jobs, 47% Vulnerable through Second-Hand Exposure
April 08, 2024 —
The Law Offices of Justinian C. Lane, Esq. - PLLCAUSTIN, April 04, 2024 (GLOBE NEWSWIRE) -- A recent nationwide survey conducted on the risks of asbestos in America revealed that 38% of respondents have worked in high-risk industries where asbestos was present, while 47% have experienced indirect exposure through family members employed in these high-risk environments. The survey results reflect the fact that, despite the
EPA's recent ban on ongoing uses of chrysotile asbestos, the threat of exposure still looms large in the US, underscoring the urgent need for continued vigilance and action to safeguard public health.
Compounding the concern is the revelation that only 8% of Americans undergo regular testing. These findings, released today, underscore the urgent necessity for Asbestos Cancer Risk Awareness and routine testing. They emphasize the crucial importance of proactive measures to mitigate the pervasive risks associated with asbestos exposure in the United States.
The study was conducted by Researchscape on behalf of
The Law Offices of Justinian C. Lane, Esq. - PLLC, a leading firm advocating for testing and compensation for individuals exposed to asbestos on the job and their families who are at risk due to second-hand exposure.
According to the survey, 86% of respondents have never undergone any testing for asbestos exposure, while a mere 8% are tested regularly. The lack of testing is particularly concerning among the Gen X demographic who could be at risk due to secondhand exposure from a family member who worked with asbestos when it was still prevalent, with 92% reporting no testing, highlighting the potential risks associated with secondhand exposure.
Read the court decisionRead the full story...Reprinted courtesy of
2013 May Be Bay Area’s Best Year for Commercial Building
November 20, 2013 —
CDJ STAFFA tech boom has resulted in something of a commercial building boom for the Bay Area. The region will see about $6 billion in commercial construction projects during 2013. This is better than the totals for 2012, 2011, and 2009. During that period, however, 2010 set a record for the area with $6 billion of construction. Some estimates see 2013 beating that with as much as $6.7 billion in construction by year’s end.
The surge has been attributed to job creation. One Bay-area company, Infoblox, moved into a new office complex, after extensive renovation. The company had 250 employees and now has room to expand to 500 employees.
But 2014 could be even better. Apple is about to begin construction of its new campus, which is expected to cost the company $5 billion.
Read the court decisionRead the full story...Reprinted courtesy of
BHA at the 10th Annual Construction Law Institute, Orlando
January 13, 2017 —
Don MacGregor - Bert L. Howe & Associates, Inc.Bert L. Howe & Associates, Inc. is once again proud to be partnering with the Florida Bar Continuing Legal Education Committee and the Construction Law Committee of the Florida Bar Real Property, Probate and Trust Law Section, as a sponsor and exhibitor at the 10th Annual Construction Law Institute to be held March 16th, 17th & 18th, 2017 at the JW Marriott Orlando Grande Lakes in Orlando.
With offices in Miami serving all of Florida, Bert L. Howe & Associates, Inc. (BHA) offers the experience of over 20 years of service to carriers, defense counsel, and insurance professionals as designated experts in nearly 6,500 cases. BHA’s staff encompasses a broad range of licensed and credentialed experts in the areas of general contracting and specialty trades, as well as architects, and both civil and structural engineers, and has provided services on behalf of developers, general contractors and sub-contractors.
BHA’s experience covers the full range of construction and construction defect litigation, including single and multi-family residential (including high-rise), institutional (schools, hospitals and government buildings), commercial, and industrial claims. BHA specializes in coverage, exposure, premises liability, and delay claim analysis as well.
As the litigation climate in Florida continues to change, and as the number of construction defect and other construction related cases continues to rise, it is becoming more important for contractors and builders here to be aggressive in preparing for claims before they are made, and in defending against those claims once they are filed. Since 1993, Bert L. Howe & Associates has been an industry leader in providing construction consulting services, and has been a trusted partner with builders and insurance carriers, both large and small, across the Western and Southern United States. Here in Florida, we have been providing construction defect and construction-claims related forensic expert services for the past decade with a proven track record of successful results.
For those of you planning on attending the conference, or those who may know someone who will be, we encourage you to stop by the BHA booth and we welcome the opportunity to discuss further the broad range of services provided by BHA.
For your convenience, when registration information is made available, a link to the 10th Annual Construction Law Institute should be available here: http://www.rpptl.org/
Read the court decisionRead the full story...Reprinted courtesy of
Don MacGregor, Bert L. Howe & Associates, Inc.Mr. MacGregor may be contacted at
dmac@berthowe.com
Miller Act Bond Claims Subject to “Pay If Paid”. . . Sometimes
November 04, 2019 —
Christopher G. Hill - Construction Law MusingsThe Federal Miller Act is a great tool that subcontractors and suppliers on Federal projects can use for collection of wrongfully withheld amounts due. However, as a recent federal case from the Eastern District of Virginia points out, the construction contract’s terms affect when a subcontractor or supplier can use this great collection tool and how much it can recover.
In Aarow v Travelers the Court looked at the interaction between a typical termination clause, a “pay when paid” clause, and the Miller Act. The key facts are these. The general contractor on the project at issue, Syska, did not get paid some disputed amounts by the owner and subsequently did not pay Aarow, the plaintiff and a subcontractor on the project. Aarow then refused to continue work and was terminated by Syska who then took over the completion of the work. Aarow sued, seeking damages for the value of its work prior to the termination. Travellers, the surety defended stating that, if Aarow was properly terminated for cause by Syska, then Aarow was not entitled to payment under the contract until such time as the work was completed and accepted by the owner. The termination clauses are set out in the linked opinion.
The Court agreed with Travelers, stating that the pay when paid clause created a situation whereby Aarow could not stop work merely because of a non-payment by Syska attributed to non-payment by the owner. The Court was clear in stating that the Miller Act trumps “pay when paid” in instances where the only cause for non-payment is non-payment by an owner. The Court then reasoned that it is the interaction between the termination and “pay when paid” provisions, and not the “pay when paid” clause itself, that exonerated Travelers because it created the default by Aarow due to its refusal to continue work. In short, Aarow was properly terminated for cause because it left the job without justification and therefore Travelers was not liable.
Read the court decisionRead the full story...Reprinted courtesy of
The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
