Fairfield Connecticut Building Expert Directory

Constructive Changes – A Primer

October 02, 2018 — Jonathan R. Mayo - Smith Currie
A “constructive change” occurs when an owner action or omission not formally acknowledged by the owner to be a change in the contact’s scope of work forces the contractor to perform additional work. Constructive changes are not formal change orders, but informal changes that could have been ordered under a contract’s changes clause if the change had been recognized by the owner. The constructive change doctrine recognizes that being informally required to do extra work is similar to a formal change order and should be governed by similar principles. Thus, if it is found that a constructive change order did occur, the contractor may be entitled to payment for additional costs incurred, and an extension to the contract performance period. Constructive changes most often arise where there is a dispute regarding contract interpretation, defective plans and specifications, acceleration or suspension of work, interference or failure to cooperate with the contractor, misrepresentation or nondisclosure of superior knowledge or technical information, over inspection, or a delay in providing requested information crucial to the contractor’s ability to continue work. Read the court decision
Read the full story...
Reprinted courtesy of Jonathan R. Mayo, Smith Currie
Mr. Mayo may be contacted at jrmayo@smithcurrie.com

Court Finds That Split in Underground Storage Tank is Not a Covered Collapse

July 13, 2017 — Christopher Kendrick & Valerie A. Moore – Haight Brown & Bonesteel LLP
In Tustin Field Gas & Food v. Mid-Century Ins. Co. (No. B268850, filed 7/3/17), a California appeals court ruled that a split in an underground storage tank, caused by the tank sitting on a rock for years, was not a covered “collapse” as a matter of law. Tustin Field owned a gas station in Palm Springs. The installer of the underground storage tanks did not follow the manufacturer’s instructions to bury them in pea gravel or crushed rock. Instead, the installer just dug a hole, placed the tanks into that hole, and then covered them with “native soil” containing rocks, boulders and other debris. The tanks were double-walled, steel with a fiberglass sheath. Sixteen years after installation, testing revealed that the fiberglass sheath on one tank was no longer intact. The tank was excavated and the fiberglass sheath was found to be cracked from the tank sitting on a nine-inch boulder. The insured paid to have the crack repaired and made a claim for the cost of excavating and repairing the tank. Reprinted courtesy of Christopher Kendrick, Haight Brown & Bonesteel LLP and Valerie A. Moore, Haight Brown & Bonesteel LLP Mr. Kendrick may be contacted at ckendrick@hbblaw.com Ms. Moore may be contacted at vmoore@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Woodbridge II and the Nuanced Meaning of “Adverse Use” in Hostile Property Rights Cases in Colorado

November 23, 2020 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
Earlier this year, the Colorado Court of Appeals issued an opinion addressing at length “whether the requirement that the use be ‘adverse’ in the adverse possession context is coextensive with adverse use in the prescriptive easement context.” See Woodbridge Condo. Ass’n, Inc. v. Lo Viento Blanco, LLC, 2020 COA 34 (Woodbridge II), ¶ 2, cert. granted, No. 20SC292, 2020 WL 5405376 (Colo. Sept. 8, 2020). As detailed below, the Woodbridge II court concluded that the meanings of “adverse” in these two contexts are not coextensive—while “hostility” in the adverse possession context requires a claim of exclusive ownership of the property, a party claiming a prescriptive easement is only required to “show a nonpermissive or otherwise unauthorized use of property that interfered with the owner’s property interests.” Thus, the Woodbridge II court reasoned a claimants’ acknowledgement or recognition of an owner’s title alone is insufficient to defeat “adverse use” in the prescriptive easement context. This significant ruling is at odds with a prior division’s broad statement, while considering a prescriptive easement claim, that “[i]n general, when an adverse occupier acknowledges or recognizes the title of the owner during the occupant’s claimed prescriptive period, the occupant interrupts the prescriptive use.” See Trask v. Nozisko, 134 P.3d 544, 553 (Colo. App. 2006). Perhaps for that reason, Woodbridge II is currently pending certiorari review before the Colorado Supreme Court in a case that should provide some much-needed clarity on what constitutes “adverse use” in the context of a prescriptive easement. As we await the Colorado Supreme Court’s decision, I thought it worthwhile to provide a brief analysis of the Woodbridge II court’s deep dive into the nuances of “adverse use” in this field of Colorado law. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

Undercover Sting Nabs Eleven Illegal Contractors in California

January 27, 2014 — Beverley BevenFlorez-CDJ STAFF
A sting operation conducted in Rancho Murieta, California on January 16th by the Statewide Investigative Fraud Team, with assistance from the state Department of Consumer Affairs Division of Investigation netted “11 people accused of illegal, unlicensed home improvement contracting,” reported the Merced Sun-Star. The news source stated that “the statewide drought” provided “a new angle in approaching conservation-minded property owners, according to the Contractors State License Board.” The accusations included “illegal contracting after seeking bids for exterior painting, fencing and landscaping jobs,” according to the Merced Sun-Star. The eleven individuals received notices to appear in Sacramento Superior Court for arraignment March 27th. Read the court decision
Read the full story...
Reprinted courtesy of

Gut Feeling Does Not Disqualify Expert Opinion

July 06, 2011 — CDJ STAFF

The New Jersey Supreme Court issued a ruling in June on the case of Nevins v. Toll in which they reversed an earlier decision and remanded the case to a lower court for retrial. At issue in the case was the testimony of the plaintiff’s expert, J. Anthony Dowling. In depositions, Mr. Dowling said that his estimates for repair were based on a “gut feeling.” Dowling said he had “very little” experience in cost estimates for single-family homes. The defendants sought to bar Dowling’s testimony which was granted by the judge. Without an expert, Ms. Nevin’s case was dismissed.

Describing Dowling’s report as “far from a model of how an expert’s opinion in a construction case should be presented,” the court noted that Dowling is not a professional expert witness. However, the court did note that Dowling is a professional cost estimator. Despite Mr. Dowling using his “gut feeling” to construct his estimate, the New Jersey Supreme Court felt that whether his estimate is convincing is “a question for the jury.”

Read the court’s opinion…

Read the court decision
Read the full story...
Reprinted courtesy of

Even Fraud in the Inducement is Tough in Construction

November 06, 2023 — Christopher G. Hill - Construction Law Musings
I have discussed how hard it is in the Commonwealth of Virginia to make out a claim for fraud when a construction contract is involved. On limited exception is where a claim for “fraud in the inducement” is involved. Essentially, such a claim states that one party was hoodwinked into entering the contract in the first place. Because of the initial fraud (for instance misrepresenting the class or existence of a contractor’s license), the courts may bypass the terms of the contract and allow a claim for fraud to go forward. While you may think that this would lead to many claims making it past a Motion to Dismiss, at least one court here in Virginia makes it clear that such claims will not be taken lightly and must be supported by specific and substantial allegations that would support more than just “advertising” or opinion. In County of Grayson v. Ra-Tech Services Inc., the U. S. District Court for the Western District of Virginia reviewed an amended complaint from the Plaintiff seeking to make out a claim for fraud in the inducement based upon the defendant’s statements in support of a proposal that certain brands of equipment would be used. The Court further considered general allegations that the Defendant never intended to provide those particular brands of equipment. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Arbitration: For Whom the Statute of Limitations Does Not Toll in Pennsylvania

June 03, 2019 — Gus Sara - The Subrogation Strategist
In Morse v. Fisher Asset Management, LLC, 2019 Pa. Super. 78, the Superior Court of Pennsylvania considered whether the plaintiff’s action was stayed when the trial court dismissed the plaintiff’s complaint after sustaining the defendants’ preliminary objections seeking enforcement of an arbitration clause in the contract at issue. The Superior Court—distinguishing between a defendant who files a motion to compel arbitration and a defendant who files preliminary objections based on an arbitration clause—held that, in the latter scenario, if the defendant’s preliminary objections are sustained, the statute of limitations is not tolled. This case establishes that, in Pennsylvania, plaintiffs seeking to defeat a challenge to a lawsuit based on a purported agreement to arbitrate need to pay close attention to the type of motion the defendant files to defeat the plaintiff’s lawsuit. In Morse, the plaintiff entered into a contract with Fisher Asset Management (Fisher) in 2008 for investment-advisor services. The contract included a provision stating that any dispute, claim or controversy arising out of the agreement between the parties shall be determined by arbitration. In June 2009, the plaintiff filed a complaint against Fisher and two of its employees in the Court of Common Pleas of Allegheny County, alleging breach of fiduciary duty, breach of contract, negligence, and other claims. The defendants filed preliminary objections to the complaint seeking dismissal on grounds that the contract between the plaintiff and Fisher required that the dispute be determined by arbitration. The court sustained the preliminary objections and dismissed the complaint. The plaintiff did not appeal the court’s ruling. Read the court decision
Read the full story...
Reprinted courtesy of Gus Sara, White and Williams
Mr. Sara may be contacted at sarag@whiteandwilliams.com

No Subrogation, Contribution Rights for Carrier Defending Construction Defect Claim

December 23, 2023 — Tred R. Eyerly - Insurance Law Hawaii
The Court held that the insurer defending the additional insured general contractor had no right to equitable subrogation or equitable contribution from a separate carrier who also insured the general contractor as an additional insured. Old Republic Gen. Ins. Co. v. Amerisure Ins. Co., 2023 U.S. Dist. LEXIS 170293 (N.D. Ill. Sept. 25, 2023). Tanger Grand Rapids, LLC hired Rockford Construction Company to build the Tanger Outlet Center. Rockford subcontracted with Kamminga & Roodvoeis, Inc. (K&R) to work on the pavement for the outlet mall. Under the subcontract, K&R agreed to maintain primary commercial general liability insurance for itself, with Rockford as an additionial insured. K&R obtained a policy from Amerisure. For additional paving work, Rockford subcontracted with Michigan Paving & Materials, CP. The subcontract also required Michigan Paving to maintain primary coverage, with Rockford as an additional insured. Michigan Paving obtained a policy from Liberty Mutual. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES