Columbus Ohio Building Expert Directory

Oregon Court of Appeals Rules That Negligent Construction (Construction Defect) Claims Are Subject to a Two-Year Statute of Limitations

October 20, 2016 — John P. Ahlers – Ahlers & Cressman PLLC
Statutes of limitations are distinct from statutes of repose. There is a lot of confusion between the two. Generally, a statute of limitations is a law which sets the maximum period of time which one can wait before filing a lawsuit, depending on the type of case or claim. The periods vary by state and by type of claim. Most states also employ a “discovery rule,” which provides that the statute of limitations does not “accrue” until such time as the plaintiff knew or should have reasonably known that the injury or property damage has occurred. Read the court decision
Read the full story...
Reprinted courtesy of John P. Ahlers, Ahlers & Cressman, PLLC
Mr. Ahlers may be contacted at jahlers@ac-lawyers.com

The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier

April 11, 2022 — Robert M. Barrack - Gordon & Rees
In United Concrete Prods. v. NJR Constr., LLC, 207 Conn. App. 551, 263 A.3d 823 (2021), the Connecticut Appellate Court has issued a decision that should be of interest to the Connecticut construction industry and the construction bar. The lawsuit arose out of the late delivery of materials on a construction project, which is a frequent problem on construction projects. In United Concrete Products, the defendant general contractor, NJR Construction, LLC (“NJR”) was retained by the State of Connecticut Department of Transportation (“DOT”) to replace a bridge over the Hockanum River (“Project”). Id. at 555-58 (2021). The Prime Contract provided that NJR with an eight-week time-frame to perform the work, at which time the road would be closed to traffic. Id. The Prime Contract also provided for a bonus of $3,000 for each day the road was opened to traffic prior to the eight week deadline of August 8, 2016, and for liquidated damages of $3,000 for each day the road remained closed beyond the deadline. Id. NJR subsequently entered into a purchase order (“Subcontract”) with the plaintiff, United Concrete Products, Inc. (“United”), whereby United agreed to provide certain concrete components for the Project, including ten pre-stressed concrete beams. Id. The Subcontract required that United deliver the concrete beams by June 7, 2016, but, NJR did not actually schedule the delivery until June 29, 2016. Id. Nevertheless, even with that schedule NJR could have reopened the road by July 19, 2016, which would have allowed it to receive the full $60,000 incentive bonus. However, United did not deliver the concrete beams until July 26, 2016, which caused NJR to lose the incentive bonus, be assessed liquidated damages by the DOT, and to incur additional delay damages. Id. After deducting the amount of $179,500 in damages that it incurred due to United’s late delivery of the beams, NJR paid United the balance of $66,074.75. Id. Read the court decision
Read the full story...
Reprinted courtesy of Robert M. Barrack, Gordon Rees Scully Mansukhani, LLP
Mr. Barrack may be contacted at rbarrack@grsm.com

Does a Contractor (or Subcontractor) Have to Complete its Work to File a Mechanics Lien

January 10, 2018 — Wally Zimolong - Zimolong LLC
Yes. There seems to be common misconception that a contractor, subcontractor, or supplier, has six months from its last day of work on the project to file a mechanics lien. I frequently see mechanics liens whereby the claimant states “Claimants last day of work on the project was X.” However, Section 1502 (49 P.S. Section 1502) of the Pennsylvania Mechanics Lien is clear that a lien must be filed within six month of “the completion of his work.” Under the Lien Law, “completion of the work” is a defined term and means “means performance of the last of the labor or delivery of the last of the materials required by the terms of the claimant’s contract or agreement, whichever last occurs.” Read the court decision
Read the full story...
Reprinted courtesy of Wally Zimolong, Zimolong LLC
Mr. Zimolong may be contacted at wally@zimolonglaw.com

Take Advantage of AI and Data Intelligence in Construction

May 06, 2019 — Nick Carter - Construction Executive
For consumers, AI and data intelligence are daily activities. Purchase recommendations from Amazon simplify holiday shopping. Music options from Spotify helps employees focus during the workday and relax at night. Car-sharing apps remove the stress from post-happy hour transport. It is time for this kind of data-driven ease to hit the construction industry. Building is booming, yet despite the good times, the industry still lags in terms of data intelligence and AI. With them, construction providers can transform document and jobsite information into intelligent insights, reduce errors, keep projects on schedule and predict and prevent costly inefficiencies. Artificial intelligence is the “connective tissue” that construction is missing--if it is used wisely. Why Construction is Ready for AI With its endless stream of owners, architects, engineers, contractors, subcontractors and suppliers, the construction industry manages more critical information on a day-to-day basis than nearly any other business. As a result, there are dozens of potential miscommunications just waiting to happen every day. Reprinted courtesy of Nick Carter, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

Ohio School Board and Contractor Meet to Discuss Alleged Defects

July 30, 2014 — Beverley BevenFlorez-CDJ STAFF
According to Insurance News, The Greeneview School Board will be meeting with contractor Sfaffco Construction Inc. to discuss findings in a 122-page report produced by “Mays Consulting & Evaluation Services Inc. that outlines numerous alleged construction defects in the roofing system.” "It's really the first time we have everybody together to discuss the deficiencies," said Isaac Seevers, the Greeneview Local Schools superintendent told Insurance News. The school board estimates that the alleged problems will take up to $3.5 million to fix. Meanwhile, Staffco has hired their own consultant. "The report from Mays is one sided," Staffco President Jon Stafford said according to Insurance News. "We take issue with some of the findings in there." Read the court decision
Read the full story...
Reprinted courtesy of

Beware of Personal-Liability Clauses – Even When Signing in Your Representative Capacity

January 31, 2018 — David R. Cook Jr. – Autry, Hall & Cook, LLP
When a contract is drafted by a party, the other party expects some level of one-sidedness in favor of the drafter. But there are times when a contract goes too far. There are certain provisions that most persons in the construction industry would find unacceptable, unfair, and beyond the pale – even for a one-sided contract. Such a provision was arguably found in an electrical subcontract at issue in a 2014 opinion by a three-judge panel of the Georgia Court of Appeals. Unfortunately, due to long-standing Georgia law, the panel was forced to apply the provision as written. In the case, a contractor hired a subcontractor to perform the electrical scope of work. When the subcontractor failed to pay a sub-subcontractor, the sub-subcontractor filed suit against the subcontractor, contractor, and the payment-bond surety. The contractor asserted a claim of indemnity against the subcontractor based on the sub-subcontractor’s claim. Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook Jr., Autry, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

Home Prices Expected to Increase All Over the U.S.

July 09, 2014 — Beverley BevenFlorez-CDJ STAFF
According to a survey of the National Association of Realtors (as quoted by the Housing Wire), home prices are expected “to increase in all states and the District of Columbia over the next 12 months, with most of the heavy growth in Florida, Texas, and California, among other states.” The highest expected price growth was “in states with low inventory levels, strong cash sales, and strong growth sectors (e.g., technology, oil).” Read the court decision
Read the full story...
Reprinted courtesy of

Supreme Court Set to Alter Law on Key Project, Workforce Issues

December 02, 2019 — Mary B. Powers & Debra K. Rubin - Engineering News-Record
With its term now under way, the U.S. Supreme Court could change federal laws with industry impact—from where huge pipelines can be built and new regulation of pollution in groundwater to whether LGBTQ workers have anti-bias rights under the 1964 Civil Rights Act. Reprinted courtesy of Mary B. Powers, Engineering News-Record and Debra K. Rubin, Engineering News-Record Mr. Rubin may be contacted at rubind@enr.com Read the court decision
Read the full story...
Reprinted courtesy of

COLUMBUS OHIO BUILDING EXPERT DIRECTORY AND CAPABILITIES