Seattle Washington Building Expert Directory

Big Bertha Lawsuits—Hitachi Zosen Weighs In

January 31, 2018 — John P. Ahlers – Ahlers Cressman & Sleight PLLC
In a recent article published by Seattle Business Magazine, the Japanese manufacturer of the much-maligned tunnel machine (nicknamed “Bertha”) provided its version of events and its position to the public. The interview took place after executives from Hitachi Zosen were not invited to the ceremony celebrating Bertha’s breakthrough at the end of its two-mile journey underground Seattle. Ultimately, apparently, Seattle Tunnel Partners (“STP”), the general contractor for the project, and Washington State Department of Transportation (“WSDOT”) agreed that Hitachi Zosen executives could attend the event, but they were not allowed to stand with other dignitaries on a specially-built viewing platform. The $3.2 billion Alaska Way Viaduct replacement project is embroiled in a number of legal controversies. Now that the tunnel is finished, Hitachi Zosen has finally decided to tell its side of the story. Hitachi’s problems started on December 5, 2013, three days after the tunnel-boring machine (“TBM”) hit a 120-foot long, eight-inch diameter steel well casing (the project DRB has determined that the pipe was a differing site condition), the TBM overheated and ground to a halt. The project was shut down almost two years while the TBM was being repaired. According to Hitachi Zosen, it always worked hard to get the job done. “We wanted to finish the tunnel and make Seattle happy with the results,” said Hidetoshi Hirata, the general manager for Hitachi Zosen. Read the court decision
Read the full story...
Reprinted courtesy of John P. Ahlers, Ahlers Cressman & Sleight PLLC
Mr. Ahlers may be contacted at john.ahlers@acslawyers.com

Housing Starts in U.S. Surge to Seven-Year High as Weather Warms

May 20, 2015 — Sho Chandra – Bloomberg
New residential construction in the U.S. surged in April to the highest level in more than seven years, indicating the industry has moved beyond a weather-related soft patch to regain strength. Housing starts jumped 20.2 percent to a 1.14 million annualized rate, the most since November 2007, from a 944,000 pace in March, a Commerce Department report showed Tuesday in Washington. The median forecast of 83 economists surveyed by Bloomberg was 1.02 million. More permits, a proxy for future construction, were issued than at any time since June 2008. An improving labor market and mortgage costs close to multiyear lows are reviving residential construction, a sign that the weakness in early 2015 was probably due to harsh winter weather. Builders including PulteGroup Inc. have said the spring selling season is off to a good start, and sentiment data for May showed developers are optimistic about the next six months. Read the court decision
Read the full story...
Reprinted courtesy of Shobhana Chandra, Bloomberg

KF-103 v. American Family Mutual Insurance: Tenth Circuit Upholds the “Complaint Rule”

May 12, 2016 — Adria Robinson – Colorado Construction Litigation
In Colorado, the “complaint rule” requires insurance carriers to provide a defense to its insured when the allegations contained in the complaint allege any set of facts that may fall within an insurance policy. Some insurers have pushed back on this rule arguing that it may cause an insurer to exercise its duty to defend although the underlying facts ultimately do not fall within the policy. In KF 103-CV, LLC v. American Family Mutual Insurance Company, 2015 WL 6517782, the Tenth Circuit of the United States Court of Appeals upheld the complaint rule. In its decision, the Tenth Circuit cited several Colorado state court rulings recognizing the courts’ intent to incentivize insurers to defend policies that may facially fall within the terms of the policy. Where there is uncertainty about coverage, the Tenth Circuit cited a Colorado Supreme Court case stating, “[t]he appropriate course of action for an insurer who believes that it is under no obligation to defend, is to provide a defense to the insured under the reservation of its rights.” Read the court decision
Read the full story...
Reprinted courtesy of Adria Robinson, Higgins, Hopkins, McLain & Roswell, LLC
Ms. Robinson may be contacted at robinson@hhmrlaw.com

Related’s $1 Billion Los Angeles Project Opens After 15-Year Wait

August 22, 2022 — John Gittelsohn - Bloomberg
It’s taken 15 years — longer than the time to finish Manhattan’s Hudson Yards — for Related Cos. to complete the Grand LA, a $1 billion hotel, residential and retail complex designed by star architect Frank Gehry. The Los Angeles hilltop development’s 28-floor Conrad hotel opens July 6, and the first tenants move into a neighboring 45-story apartment tower on July 15. The retail section — a mall-like space between the two towers for restaurants and boutiques — debuts in 2023. Grand LA rises across Grand Avenue from Gehry’s aluminum-clad Walt Disney Concert Hall, home of the Los Angeles Philharmonic. Nearby palaces of culture include the Dorothy Chandler Pavilion, the Ahmanson Theatre, the Broad art museum, Los Angeles Museum of Contemporary Art and the Colburn School, a music and dance academy. Read the court decision
Read the full story...
Reprinted courtesy of John Gittelsohn, Bloomberg

Contractors Can No Longer Make Roof Repairs Following Their Own Inspections

July 02, 2018 — Jason Feld & Alex Chazen - Kahana & Feld LLP
California law mandates that any person who conducts roof inspections for a fee can no longer effectuate the actual repairs to the same property. Effective January 1, 2018, Business & Professions Code Section 7197 (Unfair Business Practices) deems it to be an unfair business practice for a home inspector who charges a homeowner a monetary fee for inspecting the property, to perform or offer to perform additional repairs due to the inherent financial interest and conflict raised by identifying alleged defects necessitating repairs. The new law is a result of California AB 1357, which was signed into law on October 5, 2017. The goal of the new law is to disincentivize a roof inspector from creating a report for the sole purpose of obtaining a bid to perform those documented repairs. The roof contractor can perform repairs identified in their report only after a twelve month “cooling period” which provides the homeowner an opportunity to obtain multiple bids/estimates for repairs based upon the inspector’s report. The new law also discourages home inspectors from providing a list of contractors who provide monetary referral fees back to the home inspector upon receiving repair work from the homeowner based exclusively on the home inspection report. The California Business & Professions Code Section 7195(a)(1) defines a “home inspection” as a “non-invasive, physical examination, performed for a fee in connection with the transfer…of the real property…or essential components of the residential dwelling.” Home inspection includes “any consultation regarding the property that is represented to be a home inspection or any confusingly similar term.” Business & Professions Code section 7195(a)(2) further defines a “home inspection” as including energy efficiency and solar. A “home inspection report” is a written report prepared for a fee issued after an inspection. Business & Professions Code section 7195(c). It is noted that a home inspector does not have to be a licensed architect, professional engineer, or general contractor with a Class “B” license issued by the California Contractors State License Board, but “it is the duty of a home inspector who is not licensed as a general contractor, structural pest control operator, or architect, or registered as a professional engineer to conduct a home inspection with the degree of care that a reasonably prudent home inspector would exercise. Business & Professions Code section 7196. Reprinted courtesy of Jason Feld, Kahana & Feld LLP and Alex Chazen, Kahana & Feld LLP Mr. Feld may be contacted at jfeld@kahanalaw.com Mr. Chazen may be contacted at achazen@kahanafeld.com Read the court decision
Read the full story...
Reprinted courtesy of

Homebuilding Design Goes 3D

June 17, 2015 — Beverley BevenFlorez-CDJ STAFF
The Houston Business Journal reported that some home builders are using new computer visualization technology to create 3D representations of home designs. Autodesk Revit not only helps the buyer visualize the home, but it also catches architectural design mistakes and can help homebuilders quantify all of the building materials necessary for a particular model. Mollie Silver, a senior designer with On Point Custom Homes, uses Autodesk Revit. “It changes the game for our clients, because this gives them a really good idea of what their home will look like in real life,” Silver told the Houston Business Journal. “If you give them floor plans, it just doesn’t give them the same idea.” Read the court decision
Read the full story...
Reprinted courtesy of

Basement Foundation Systems’ Getting an Overhaul

October 22, 2014 — Beverley BevenFlorez-CDJ STAFF
Builder reported that “[a] new game-changing system, recently recognized for its energy-efficient composite approach to basement construction, soon could change how American builders construct foundations.” Epitome composite foundation walls from Composite Panel Systems (CPS) “was awarded the Composites and Advanced Materials Exposition’s Unsurpassed Innovation Award in Orlando, Fla., on Oct. 14.” The system “combines integrated stud cavities for mechanicals, insulation, the top plate, and a vapor barrier in a single step.” It has been approved for use in Wisconsin, and is expected to receive International Building code and International Residential Code compliance later this year. Read the court decision
Read the full story...
Reprinted courtesy of

Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?

January 27, 2020 — Ted R. Gropman & Christine Z. Fan - ConsensusDocs
Construction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date. Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved. There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973). Reprinted courtesy of Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP Mr. Gropman may be contacted at gropmant@pepperlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES