Torrey Pines Court Receives Funding for Renovation
August 06, 2014 —
Beverley BevenFlorez-CDJ STAFFSan Diego Source reported that “CIT Real Estate Finance provided…$60 million…to refinance existing debt and fund the renovations at Torrey Pines Court,” a five-building Class A office campus located in La Jolla, California. The 206,128 square foot complex, which resides on 9.24 acres, is adjacent to the Torrey Pines Golf Course. CIT has funded the project in partnership with Rockwood Capital and The Muller Company.
"We are excited to begin renovations that will complete our repositioning of Torrey Pines Court with state-of-the-art office space and amenities,” David Streicher, Partner at Rockwood Capital, stated according to a press release in the Wall Street Journal. “We expect that the renovations, coupled with the project's picturesque setting, will solidify Torrey Pines Court's position as the preferred office destination in the submarket. We thank CIT for working with us to create a sound financing package that will take this project to the next level."
Read the full story, San Diego Source...
Read the full story, Wall Street Journal... Read the court decisionRead the full story...Reprinted courtesy of
Edward Beitz and William Taylor Recognized by US News – Best Lawyers as a "Lawyer of the Year"
August 31, 2020 —
Edward Beitz & William Taylor - White and WilliamsWhite and Williams is proud to announce that Edward Beitz and William Taylor have been recognized by U.S. News – Best Lawyers® as a “Lawyer of the Year” in their respective practices in Philadelphia. Ed was named in the area of Medical Malpractice and Bill was named in Construction Law. "Lawyer of the Year" recognitions are awarded to individual lawyers with extremely high overall peer-feedback for a specific practice area and geographic location.
Ed is a member of the Healthcare Group and focuses his practice on medical malpractice defense, defending doctors, nurses, physician assistants and hospitals at the trial and appellate court levels, as well as general liability matters. He has successfully defended numerous medical malpractice cases at trial involving complex issues of the human anatomy, such as cardiac surgery, neurosurgery, orthopedic surgery, nursing care, obstetrical complications, nerve injury and vascular injury. Ed has authored briefs on appellate issues in healthcare and coverage matters to the Superior Court of Pennsylvania, the New Jersey Appellate Division and the Third Circuit Court of Appeals.
Reprinted courtesy of
Edward Beitz, White and Williams and
William Taylor, White and Williams
Mr. Beitz may be contacted at beitze@whiteandwilliams.com
Mr. Taylor may be contacted at taylorw@whiteandwilliams.com
Read the court decisionRead the full story...Reprinted courtesy of
Pacing in Construction Scheduling Disputes
September 14, 2017 —
Luke Mecklenburg - Snell & Wilmer Real Estate Litigation BlogOn a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway.
However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48.
Read the court decisionRead the full story...Reprinted courtesy of
Luke Mecklenburg, Snell & WilmerMr. Mecklenburg may be contacted at
lmecklenburg@swlaw.com
The EEOC Targets Construction Industry For Heightened Enforcement
May 15, 2023 —
Meghan Douris & Andrew Scroggins - The Construction SeytSeyfarth Synopsis: On January 10, 2023, the Equal Employment Opportunity Commission (EEOC) released for public comment its
draft 2023-2027 Strategic Enforcement Plan (“SEP”)—a document that will guide the Commission’s enforcement priorities for the next five years. The EEOC’s prior Strategic Plan described how it would pursue its enforcement goals. (See our earlier blog on the Strategic Plan
here). The Strategic Enforcement Plan, on the other hand, describes what the EEOC’s enforcement priorities will be. Earlier actions by the EEOC suggested that it might be turning its attention to the construction industry. In the SEP, the EEOC makes its intentions explicit, putting the construction industry—and especially those receiving federal funding—squarely in its sights.
History of the SEP
The EEOC’s
first SEP covered Fiscal Years 2013-2016 (the EEOC’s fiscal years begin on October 1) and identified six broad subject-matter priorities. The EEOC’s
second SEP set the course for enforcement priorities for FY2017-2022. The
latest proposed SEP, published in the Federal Register for comment for the first time, provides notable additional details that put the employer community on notice of the Commission’s intentions for FY2023-2027.[
1]
Reprinted courtesy of
Meghan Douris, Seyfarth and
Andrew Scroggins, Seyfarth
Ms. Douris may be contacted at mdouris@seyfarth.com
Mr. Scroggins may be contacted ascroggins@seyfarth.com
Read the court decisionRead the full story...Reprinted courtesy of
Solar Energy Isn’t Always Green
August 27, 2014 —
Beverley BevenFlorez-CDJ STAFFIEEE Spectrum reported that photovoltaics, used in Solar Energy, “varies substantially by technology and geography” and some emit chemical pollution. However, IEE Spectrum stated that “the industry could readily eliminate many of the damaging side effects that do exist.”
One challenge is that “nearly half the world’s photovoltaics are manufactured in China” who, according to IEEE Spectrum, “typically [does] the worst job of protecting the environment and their workers.”
It is also difficult for consumers to make choices based upon photovoltaic manufacturer practices, since solar energy doesn’t have a formal ecolabel like Energy Star, IEEE Spectrum reported.
Read the court decisionRead the full story...Reprinted courtesy of
Tropical Storms Pile Up Back-to-Back-to-Back Out West
September 17, 2014 —
Brian K. Sullivan – BloombergTropical Storm Polo, the 16th storm of an unusually active eastern Pacific hurricane season, is on a path eerily like that of Odile, which blasted the Baja California peninsula earlier this week.
Odile went ashore late Sept. 14 with top winds of 125 miles (201 kilometers) per hour, the strongest storm to hit the region since 1967. As its winds swept the resort city of Cabo San Lucas, it was a Category 3 storm on the five-step Saffir-Simpson scale and a major hurricane.
At its peak, hours before landfall, Odile’s winds reached 135 mph, Category 4-force. Photos from Mexico’s Baja California Sur show houses destroyed, hotels piled with debris and gaping holes in the local airport. At least 30,000 tourists were stranded.
Read the court decisionRead the full story...Reprinted courtesy of
Brian K. Sullivan, BloombergMr. Sullivan may be contacted at
bsullivan10@bloomberg.net
The “Program Accessibility” Exception for Public Entities Under the ADA
September 10, 2014 —
Garret Murai – California Construction Law BlogPublic owners, as well as private owners and tenants of commercial and retail properties, are at risk of lawsuits brought under the Americans with Disabilities Act of 1990 (“ADA”) and related state law alleging that their facilities are not accessible by those with disabilities.
A common misperception among private owners and tenants is that facilities constructed before the ADA went into effect in 1992 are exempt or “grandfathered” from the ADA’s requirements. Not so. At least generally. If, however, you are a public entity, there is such an exception. Lucky you.
Under the ADA, public facilities constructed prior to January 26, 1992 need not be “accessible to and usable by individuals with disabilities” so long as a public entity’s “service[s], program[s] and activit[ies], when viewed in [their] entirety, [are] readily accessible to and usable by individuals with disabilities.” Known as “program accessibility,” the exception has left many public entities scratching their heads as to what they can and must do.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Kronick Moskovitz Tiedemann & GirardMr. Murai may be contacted at
gmurai@kmtg.com
Developers Can Tap into DOE’s $400 Million for Remote and Rural Clean Energy Projects
December 10, 2024 —
Robert A. James, Elina Teplinsky, Alicia M. McKnight, Sidney L. Fowler & Clarence H. Tolliver - Gravel2Gavel BlogOn October 3, 2024, the Department of Energy Office of Clean Energy Demonstrations announced a Notice of Funding Opportunity (NOFO) to fund up to $400 million for clean energy projects in rural and remote areas via its Energy Improvements in Rural or Remote Areas program. The NOFO will provide awards ranging from $2 million – $50 million, with plans to fund 20 to 50 projects. Awards will require a non-federal cost share, range across four topic areas, and target projects in rural and remote communities with populations of 10,000 people or fewer.
Eligibility
Applications are open to a wide range of entities, including for-profit and nonprofit organizations, state and local governmental entities, Indian Tribes and Tribal organizations, institutions of higher education, rural electric cooperatives, incorporated and unincorporated consortia, farming associations and cooperatives, and labor unions. Generally applicants must be U.S. entities, but foreign entities may be allowed to participate in limited circumstances. Applicants must identify at least one area in the U.S. or U.S. territories with a population of up to 10,000 people which will benefit from the proposal.
Reprinted courtesy of
Robert A. James, Pillsbury,
Elina Teplinsky, Pillsbury,
Alicia M. McKnight, Pillsbury,
Sidney L. Fowler, Pillsbury and
Clarence H. Tolliver, Pillsbury
Mr. James may be contacted at rob.james@pillsburylaw.com
Ms. Teplinsky may be contacted at elina.teplinsky@pillsburylaw.com
Ms. McKnight may be contacted at alicia.mcknight@pillsburylaw.com
Mr. Fowler may be contacted at sidney.fowler@pillsburylaw.com
Mr. Tolliver may be contacted at clarence.tolliver@pillsburylaw.com
Read the court decisionRead the full story...Reprinted courtesy of