Fairfield Connecticut Building Expert Directory

Second Circuit Affirms Win for General Contractor on No Damages for Delay Provision

September 02, 2024 — Bill Wilson - Construction Law Zone
In NASDI, LLC v. Skanska Koch Inc. Kiewit Infrastructure Co. (JV), 2024 WL 1270188 (2d Cir. Mar. 26, 2024), the U.S. Court of Appeals for the Second Circuit affirmed the District Court’s grant of summary judgment dismissing a subcontractor’s delay claim against a general contractor on a public project in New York state. The Court enforced a typical no-damages-for-delay provision to bar the subcontractor’s breach of contract claim. The no-damages-for-delay provision in the subcontract at issue provided:

NO DAMAGE FOR DELAY. Except as otherwise provided …, Subcontractor agrees that it shall have no Claim against Contractor for any loss or damage it may sustain through delay, disruption, suspension, stoppage, interference, interruption, compression, or acceleration of Subcontractor’s Work (‘Delay Damages’) caused or directed by Contractor for any reason, and that all such Claims shall be fully compensated for by Contractor’s granting Subcontractor such time extensions as it is entitled to as a result of any of the foregoing.

Read the court decision
Read the full story...
Reprinted courtesy of Bill Wilson, Robinson & Cole LLP
Mr. Wilson may be contacted at wwilson@rc.com

Not So Fast, My Friend: Pacing and Concurrent Delay

April 25, 2022 — William E. Underwood - ConsensusDocs
When critical path activities are delayed by the owner (or another party), contractors will sometimes “pace,” or slow down, other activities to match the owner-caused delay. After all, why should the contractor hurry up and wait? But paced activities can often appear as concurrent delays on a project’s overall schedule. And all too often, contractors fail to contemporaneously document their efforts to pace work. Not only can this create avoidable disputes with owners and other contractors, but it can also create future roadblocks to the recovery of delay damages. This article examines the interplay between pacing and concurrent delay[1] and what contractors should do to minimize risk and preserve their rights to obtain more than a simple time extension for project delays. Pacing versus Concurrent Delay As a basic matter, most contracts allocate responsibility/liability for a schedule delay to the party that caused the delay. For example, if an owner is contractually required to provide equipment for a contractor to install, then the owner likely bears responsibility for any delays caused if the equipment is delivered late. If, however, the contractor was also behind schedule on other activities during this time and the project would have been delayed regardless of the owner’s late deliveries, then the delay is probably concurrent. And the contractor will generally be entitled to only an extension of time, and no other monetary relief. Read the court decision
Read the full story...
Reprinted courtesy of William E. Underwood, Jones Walker LLP (ConsensusDocs)
Mr. Underwood may be contacted at wunderwood@joneswalker.com

Cold Weather Causes Power Blackouts, Disruptions on Jobsites

February 22, 2021 — Autumn Cafiero Giusti - Engineering News-Record
A February cold snap in the central U.S. has created record power demand, resulting in outages from Texas to North Dakota and contractors bracing for delays and damage from weather impacts. Reprinted courtesy of Autumn Cafiero Giusti, Engineering News-Record ENR may be contacted at ENR.com@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Stadium Intended for the 2010 World Cup Still Not Ready

June 18, 2014 — Beverley BevenFlorez-CDJ STAFF
Four years after the HM Pitje Stadium in Pretoria, South Africa was expected to open, the stadium, which was meant to be used during the 2010 World Cup, remains closed. IOL News reported that upgrades began in 2006, “[b]ut since then there have been delays and problems with construction which may see the stands having to be rebuilt.” One of the defects that prevented the stadium from being used for the World Cup was that the slope of the main pavilion was too steep. City of Tshwane spokesman Selby Bokaba told IOL News: “Upgrading of the stadium will take approximately two calendar years, with the completion date reliant on the approval and budget availability.” Read the court decision
Read the full story...
Reprinted courtesy of

GRSM Team Wins Summary Judgment in Million-Dollar HOA Dispute

December 17, 2024 — Robert A. Bragalone & B. Ryan Fellman - Gordon Rees Scully Mansukhani
Gordon Rees Scully Mansukhani Partner Bob Bragalone and Senior Counsel Ryan Fellman won a complete summary judgment on behalf of five board members who had been added to an HOA dispute by the defendant homeowners. The GRSM team resolved the matter within just 60 days of taking over the case, bringing an end to a legal battle that had lasted more than four years. The dispute began when the HOA, as plaintiff, filed suit against the homeowners in Denton County District Court. The HOA alleged that the homeowners had violated the HOA’s Covenants, Conditions, and Restrictions by constructing a non-conforming carport and sought a declaratory judgment to resolve the issue. In response, the homeowners filed a counterclaim and third-party petition, adding the individual HOA board members to the lawsuit. They accused the board members—who were serving in a voluntary capacity—of mishandling the dispute and filed claims against them for intentional infliction of emotional distress, negligence, and gross negligence. Reprinted courtesy of Robert A. Bragalone, Gordon Rees Scully Mansukhani and B. Ryan Fellman, Gordon Rees Scully Mansukhani Mr. Bragalone may be contacted at bbragalone@grsm.com Mr. Fellman may be contacted at rfellman@grsm.com Read the court decision
Read the full story...
Reprinted courtesy of

Traub Lieberman Attorneys Lisa M. Rolle and Justyn Verzillo Win Motion for Summary Judgment

December 23, 2024 — Lisa M. Rolle & Justyn Verzillo - Traub Lieberman
In this subrogation action brought in the Supreme Court of the State of New York, Dutchess County, Traub Lieberman attorneys Lisa M. Rolle and Justyn Verzillo successfully obtained dismissal of a third-party complaint against their client, a fire-system protection company. In the underlying case, a fire sprinkler system within a commercial building leaked water into multiple tenant spaces, causing damage. The tenants’ insurers alleged that they each paid several hundred thousand dollars to cover their insureds’ claims. The insurers then filed complaints against the company which originally installed the sprinkler (the “Installer”), asserting that the company breached its duty of care. The Installer commenced a third-party action against the property owner and two fire-system protection companies—including Traub Lieberman’s client—who had separately conducted annual inspections of the sprinkler system over the years. The property owner and the two fire-system protection companies each asserted cross-claims against each other. Reprinted courtesy of Lisa M. Rolle, Traub Lieberman and Justyn Verzillo, Traub Lieberman Ms. Rolle may be contacted at lrolle@tlsslaw.com Mr. Verzillo may be contacted at jverzillo@tlsslaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Illinois Attorney General Warns of Home Repair Scams

November 27, 2013 — CDJ STAFF
After storms damaged homes in Illinois, Lisa Madigan, the state’s Attorney General, warned consumers “to be cautious and on alert for scammers trying to take advantage of people in need of assistance.” Ms. Madigan noted that home repair scammers go into areas with storm damage convince homeowners to pay more than they should to repair storm damage. Read the court decision
Read the full story...
Reprinted courtesy of

Tokyo's Skyline Set to See 45 New Skyscrapers by 2020 Olympics

April 20, 2017 — Gareth Allan & Katsuyo Kuwako - Bloomberg
Tokyo’s skyline is set to welcome 45 new skyscrapers by the time city hosts the Olympics in 2020, as a surge of buildings planned in the early years of Abenomics near completion. Japan’s capital will see nearly 50 percent more new high-rise space in the next three years than it did in the preceding three, Toyokazu Imazeki, chief analyst at office leasing and consulting firm Sanko Estate Co Ltd., said in an interview. He said the increase was fueled by the fiscal expansion and monetary easing under Abe’s economic program, launched after his election in late 2012. “This marks the timing for completion of buildings planned from about 2013 when developers were expecting the economy to expand,” said Imazeki. The increase in building was supported not only by Abe’s expansionary policies but also Japan’s ultra-low interest rates, he said. Reprinted courtesy of Gareth Allan, Bloomberg and Katsuyo Kuwako, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES