Fairfield Connecticut Building Expert Directory

Time is of the Essence, Even When the Contract Doesn’t Say So

January 11, 2021 — Christopher G. Hill - Construction Law Musings
Welcome to 2021! As often happens here at Construction Law Musings, the year starts with a few posts on notable construction law cases that dropped in the past year or so. Not only does this review hopefully help you keep up, but helps me keep up with the latest developments (one of the reasons why I keep blogging). The first of these cases is Appalachian Power Co. v. Wagman Heavy Civil, Inc. out of the Western District of Virginia federal court. In this case, Wagman Heavy Civil, Inc. (“Wagman”) and the Virginia Department of Transportation (“VDOT”) contracted for the design and construction of a highway interchange project (the “Project”). Wagman and the Appalachian Power Company (“APCO”) entered into a written contract (the “Written Contract”) for APCO to remove and relocate its utility structures (the “Work”) in order to facilitate construction for the Project. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Hamptons Home Up for Foreclosure That May Set Record

May 13, 2014 — Prashant Gopal – Bloomberg
A home in New York’s Hamptons on Further Lane, where comedian Jerry Seinfeld and hedge-fund manager Steven A. Cohen own estates, is up for auction in what will be one of the area’s biggest foreclosure sales. More than $10.5 million is owed on the 1.8-acre (0.7-hectare) property at 80 Further Lane in East Hampton, according to Daniel Murphy, the Riverhead, New York-based attorney who is scheduled to conduct the sale on June 10. Read the court decision
Read the full story...
Reprinted courtesy of Prashant Gopal, Bloomberg
Mr. Gopal may be contacted at pgopal2@bloomberg.net

Can a Contractor be Liable to Second Buyers of Homes for Construction Defects?

November 05, 2014 — Craig Martin - Construction Contractor Advisor
Whether a contractor will be liable to a second purchaser, even though the contractor never contracted with the second purchaser, varies state to state. The Pennsylvania Supreme Court, in Conway v. The Cutler Group, is the latest court to rule that a subsequent purchaser lacks privity and cannot pursue an action against the builder. In that case, the Conways purchased a home from the original owner. After living in the home for about two years, the Conways discovered water leaking around the windows. The Conways sued the builder, alleging breach of the implied warranty of habitability. The builder defended the claim, asserting that it had not contracted with the Conways and thus had not provided any warranties to the Conways. The trial court agreed and dismissed the claim. The first level of appellate court reversed the trial court, holding that the warranty of habitability was intended to level the playing field between the builder and purchaser of a home and it should be extended to subsequent purchasers. The Pennsylvania Supreme Court disagreed and refused to extend any warranties to subsequent purchasers. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Construction Delays: Which Method Should Be Used to Calculate Delay?

July 25, 2021 — David Adelstein - Florida Construction Legal Updates
If you need to prove and allocate construction project delays, you should engage a scheduling consultant qualified with CPM (critical path method) analysis. You should also engage counsel to assist in preserving your rights, as well as presenting and maximing your arguments for delay. There are numerous methodologies used to quantify and allocate delay. You want to discuss the most effective analysis for your case and facts including whether you want/should use a forward-looking prospective analysis or a backward-looking retrospective analysis that factors in as-built data. In doing so, you want to make sure you understand the pros and cons of each methodology including the bases to attack the methodology that will be subject to cross-examination. The five primary CPM methodologies are as follows:

As-Planned Versus As-Built. This methodology compares the as-planned baseline schedule to an as-built schedule reflecting progress to assign delay. An as-built schedule that reflects progress includes actual start dates, finish dates, and durations. The actual dates and durations are compared with the as-planned dates and durations on the baseline schedule to determine delay. Under this methodology, the delay impact is determined retrospectively.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Few Homes Available to Reno Buyers, Plenty of Commercial Properties

January 22, 2013 — CDJ STAFF
Saying that "new home inventory does not exist," Mark Krueger of ArchCrest Commercial Partners tells the Reno Gazette Journal that this had lead to a problem, in that there are no homes for prospective buyers in the Reno and Sparks area. Adding to the problem is that investors are buying up resale homes with the intent of selling them at a profit later, which adds to the scarcity of available homes. While the residential market is suffering from not enough homes to satisfy buyers, there are ample commercial properties. As a result, there are no plans for any additional retail, office, or industrial projects in the Reno area for 2013. Vacancy rates are expected to fall only slightly to 12.3% for industrial properties and 17.7% for retail properties. Read the court decision
Read the full story...
Reprinted courtesy of

Wichita Condo Association Files Construction Defect Lawsuit

November 20, 2013 — CDJ STAFF
Key Construction, the contractor of a downtown Wichita, Kansas mixed-use development has been sued by the condominium association of the development’s condo building. The WaterWalk Place Owners Association claims that the balconies on the building do not drain properly. Additionally, the suit claims that the building has water intrusion problems due to inappropriate or missing sealant at windows, doors, and expansion joints. Key Construction says that they are dealing with the problems and describe the suit as due to “a deadline pushing on” the residents. Wyatt Hock, the attorney for the residents, says that he hopes for a settlement. Read the court decision
Read the full story...
Reprinted courtesy of

Wildfire Insurance Coverage Series, Part 2: Coverage for Smoke-Related Damages

July 03, 2022 — Scott P. DeVries & Yosef Itkin - Hunton Insurance Recovery Blog
For many policyholders, smoke emanating from wildfire causes as much if not more damage than the fire itself. In this post in the Blog’s Wildfire Insurance Coverage Series, we discuss damages caused by smoke emanating from wildfires. Some insurers argue that policies are limited to fire damage to the insured property and do not include smoke damage associated with nearby fires. A treatise frequently cited by insurers states otherwise: “The concept that fire insurance covers non-fire damage which is the proximate result of fire finds application also when the fire occurs on other property and causes harm to the insured property. In such case, the harm to the insured property, even though it is a non-fire harm, has long been recognized to be the result of fire, and, therefore, within the policy coverage.”[1] Reprinted courtesy of Scott P. DeVries, Hunton Andrews Kurth and Yosef Itkin, Hunton Andrews Kurth Mr. DeVries may be contacted at sdevries@HuntonAK.com Mr. Itkin may be contacted at yitkin@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

Deleted Emails Cost Company $3M in Sanctions

January 13, 2017 — Grace V. Hebbel - Saxe Doernberger & Vita, P.C. Blog
Recently, the Federal District Court for the District of Delaware imposed $3 million in punitive sanctions in order to redress harms caused by a company’s bad faith deletion of tens of thousands of emails during the course of litigation. The sanctions were ordered pursuant to Federal Rule of Civil Procedure 37, which was amended effective December 1, 2015 to permit sanctions for the failure to preserve electronically stored information (“ESI”). In GN Netcom, Inc. v. Plantronics, Inc.,1 the plaintiff, GN Netcom, brought an antitrust suit alleging that the defendant company, Plantronics, interfered with distributors to stop GN Netcom from marketing its product. Upon receipt of GN Netcom’s demand letter, Plantronics issued a litigation hold and began providing training sessions to its employees to ensure compliance. Upon filing of GN Netcom’s suit, Plantronics issued an updated litigation hold and continued training sessions. Read the court decision
Read the full story...
Reprinted courtesy of Grace V. Hebbel, Saxe Doernberger & Vita, P.C.
Ms. Hebbel may be contacted at gvh@sdvlaw.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES