Seattle Washington Building Expert Directory

Takeaways From Schedule-Based Dispute Between General Contractor and Subcontractor

September 09, 2024 — David Adelstein - Florida Construction Legal Updates
A recent opinion out of the Southern District of Florida, Berkley Insurance Co. v. Suffolk Construction Co., Case 1:19-cv-23059-KMW (S.D.Fla. July 22, 2024), provides valuable takeaways on schedule-based disputes between a general contractor and subcontractor on a high-rise project. In a nutshell, the general contractor’s original project schedule was abandoned due to project delays and the project wasn’t being built by any updated project schedule. The subcontractor claimed the general contractor was mismanaging the schedule putting unreasonable manpower and supervision constraints on it, i.e., it was working inefficiently. A bench trial was conducted and the Court found in favor of the subcontractor’s arguments. The Court found the general contractor had unrelated delays and that work activities were no longer methodical but, simply, piecemeal demands. The Court also rejected any inadequate manpower arguments finding the subcontract did not place any manpower requirements on the subcontractor. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

AECOM Out as General Contractor on $1.6B MSG Sphere in Las Vegas

January 18, 2021 — Doug Puppel - Engineering News-Record
Developers of the $1.66-billion MSG Sphere in Las Vegas have removed AECOM as general contractor on the project and will bring construction management in-house for the 875,000-sq-ft entertainment venue, according to a Madison Square Garden Entertainment Corp. statement released Dec. 17. Reprinted courtesy of Doug Puppel, Engineering News-Record ENR may be contacted at ENR.com@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Second Circuit Affirms Win for General Contractor on No Damages for Delay Provision

September 02, 2024 — Bill Wilson - Construction Law Zone
In NASDI, LLC v. Skanska Koch Inc. Kiewit Infrastructure Co. (JV), 2024 WL 1270188 (2d Cir. Mar. 26, 2024), the U.S. Court of Appeals for the Second Circuit affirmed the District Court’s grant of summary judgment dismissing a subcontractor’s delay claim against a general contractor on a public project in New York state. The Court enforced a typical no-damages-for-delay provision to bar the subcontractor’s breach of contract claim. The no-damages-for-delay provision in the subcontract at issue provided:

NO DAMAGE FOR DELAY. Except as otherwise provided …, Subcontractor agrees that it shall have no Claim against Contractor for any loss or damage it may sustain through delay, disruption, suspension, stoppage, interference, interruption, compression, or acceleration of Subcontractor’s Work (‘Delay Damages’) caused or directed by Contractor for any reason, and that all such Claims shall be fully compensated for by Contractor’s granting Subcontractor such time extensions as it is entitled to as a result of any of the foregoing.

Read the court decision
Read the full story...
Reprinted courtesy of Bill Wilson, Robinson & Cole LLP
Mr. Wilson may be contacted at wwilson@rc.com

Narrow House Has Wide Opposition

January 17, 2013 — CDJ STAFF
A small building project on Staten Island is causing some big complaints. While many residents of the area are still dealing with the aftermath of Hurricane Sandy, residents in the Port Richmond neighborhood are concerned about a house that is being built on a lot that at its widest is only seventeen feet. On the other end, the lot is only eleven feet wide. Initially, the Staten Island did not give permission to build on the Orange Avenue lot, but the developer went to the city’s Board of Standards and Appeals who gave permission. The daughter of one neighbor described the foundation as looking “like a swimming pool, not a house.” Her mother’s house has a 40-foot frontage. Another neighbor (37-foot frontage) described the plans to build the narrow house as “pretty stupid.” Work currently stopped on the building over complaints that the site’s fence was incomplete. After the developer repairs the fence, the site needs to be inspected before work continues. Read the court decision
Read the full story...
Reprinted courtesy of

Pennsylvania Court Extends Construction Defect Protections to Subsequent Buyers

December 20, 2012 — CDJ STAFF
The Pennsylvania courts have long held that there is an implied warranty of habitability for the initial purchaser of a home. Now, as some defects may not immediately show up, the court has extended that implied warranty to second and subsequent purchasers. As Marc D. Brookman, David I. Haas, and Christopher Bender of Duane Morris note, “this judicially created doctrine shifts the risk of a latent defect in the construction of a new home from the purchaser to the builder-vendor.” The Pennsylvania Supreme Court concluded that a contractual relationship is not needed for an implied warranty of habitability. The court’s concern was inequalities would result when a home was sold while other homes were protected by being within the statute of repose. Read the court decision
Read the full story...
Reprinted courtesy of

Climate Disasters Are an Affordable Housing Problem

October 01, 2024 — Juan Pablo Garnham & Arjuna Heim - Bloomberg
When Maui was devastated by wildfires in August 2023, some residents were initially fortunate. The neighborhood of Makawao, for example, was spared the worst effects of the fire that engulfed Lahaina, 35 miles to the west. Recently, though, we met a woman in that neighborhood who faces a different kind of threat: Her landlord has now demanded that she pay double her rent or face eviction. As housing advocates in the region, we’ve heard stories like this repeatedly, as residents report an acute fear of displacement and homelessness. A year after the fires killed more than 100 people, displaced 12,000 and disrupted the economy of the island, the disaster lingers for many in Maui and Hawai'i. Rents across the island have increased sharply, offering a cautionary tale for the rest of the US about how climate change, a housing crisis and the lack of adequate public policies can multiply the suffering of a community already in pain. Read the court decision
Read the full story...
Reprinted courtesy of Bloomberg

Difficulty in Defending Rental Supplier’s Claim Under Credit Application

October 11, 2021 — David Adelstein - Florida Construction Legal Updates
In construction, one of the easiest claims to prove from a burden of proof standpoint is that of a supplier, particularly a rental equipment supplier. Oftentimes, these claims are more in the realm of a collection claim because a rental supplier will generally be able to establish that a party opened an account with them, signed a credit application and personal guaranty, and equipment was rented and even delivered to a specific jobsite during set dates. Defending these claims is not so easy. And even if there is a defense as it relates to some amounts, there needs to be an upside challenging those amounts when factoring in the attorney’s fees, costs, and interest on the other amounts and on continuing the dispute. An example of the difficulty in defending these claims from rental suppliers can be found in the recent case of Custom Design Expo, Inc. v. Synergy Rents, Inc., 2021 WL 4125806 (Fla. 2d DCA 2021). Here, a contractor rented equipment (e.g, forklifts) from a supplier. The equipment was rented on an open account and the contractor signed a personal guaranty. The supplier sued the contractor for about $81,000 that remained unpaid. The supplier appeared to waste no time and moved for summary judgment with an affidavit from its credit manager. The credit manager affirmed that the contractor executed a credit application for purposes of renting equipment on an open account, the application contained a personal guaranty, and the credit application formed the basis of a contract. The credit manager authenticated the credit application and affirmed that the contractor owed it about $81,000 in unpaid amounts for rental equipment that was furnished under the credit application. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

How to Build a Water-Smart City

August 23, 2021 — Chris Malloy - Bloomberg
Cities across time have stretched to secure water. The Romans built aqueducts, the Mayans constructed underground storage chambers, and Hohokam farmers dug more than 500 miles of canals in what is now the U.S. Southwest. Today’s cities use portfolios of technologies to conserve supply — everything from 60-story dams and chemicals to centrifugal pumps and special toilets. And yet, the cities of tomorrow will have to do more. A recent United Nations report on drought says climate change is increasing the frequency, severity and duration of droughts, which contribute to food insecurity, poverty and inequality. The report also asserts that “drought has been the single longest-term physical trigger of political change in 5,000 years of recorded human history.” It calls for urgent action and a transformation in governance to manage modern drought risk more effectively. Read the court decision
Read the full story...
Reprinted courtesy of Chris Malloy, Bloomberg

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES