How Does Your Construction Contract Treat Float
November 08, 2017 —
David Adelstein - Florida Construction Legal UpdatesAlthough there are different types of construction schedule float and more technical definitions, the definition that makes sense to me is that float is the amount of time a particular activity can be delayed without that activity delaying the project’s completion date (substantial completion date). In looking at a construction schedule, this determination is made from looking at the difference between the early start date for an activity and the late start date for that activity or the difference between the early finish date for that activity and the late finish date for that activity in your CPM schedule (which should be the same amount of time). This is often referred to as “total float” and is the float that I usually focus on since it may pertain to a delay to the substantial completion date of the project and can trigger either the assessment of liquidated damages and/or the contractor’s extended general conditions, whatever the case may be.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Florida Construction Legal UpdatesMr. Adelstein may be contacted at
Dadelstein@gmail.com
Keep It Simple: Summarize (Voluminous Evidence, That Is...)
October 02, 2023 —
Steve Swart - The Dispute Resolver"The most complex analyses grow beautifully simple as they become public objects.” Philip Rieff, Fellow Teachers (1973), quoted in JOHN BARTLETT, BARTLETT’S FAMILIAR QUOTATIONS 800 (Geoffrey O’Brien gen. ed., 18th ed. 2012)
In a recent ABA Forum on Construction Law Webinar, a panelist with substantial experience as an arbitrator explained that documents are the most important evidence in a construction dispute. Fact-finders, she said, focus on contemporaneous project records more than witness testimony to vet what happened.
But, even a small to mid-sized construction project can generate millions of pages of documents. That is particularly true when disputes involve loss of productivity, delay, acceleration, and disruption. The volume of records related to entitlement and damages (e.g., timesheets, accounting, equipment logs, schedule files, meeting minutes, etc.) can overwhelm and confuse — not to mention bore — the fact finder.
Read the court decisionRead the full story...Reprinted courtesy of
Steve Swart, Williams MullenMr. Swart may be contacted at
sswart@williamsmullen.com
Jury Trials: A COVID Update
July 18, 2022 —
Joshua Lane - Ahlers Cressman & Sleight PLLCJURY TRIALS. Budd v. Kaiser Gypsum Co., Inc., — Wn. App. 2d –, 505 P.3d 120 (Wash. Ct. App. 2022). (1) Courts must ensure that juries are randomly selected to provide a fair and impartial jury. (2) While the Sixth and Fourteenth Amendments prohibit the systematic exclusion of distinctive groups from jury pools, Washington Courts’ COVID-19 policy to excuse people who were ages 60 and older and did not wish to report for duty was not a “systematic” exclusion.
Raymond Budd developed mesothelioma after working with a drywall product called “joint compound” from 1962 to 1972. He sued Kaiser Gypsum Company, Inc. and others for damages, contending that the company’s joint compound caused his illness. A jury returned a verdict in Budd’s favor and awarded him nearly $13.5 million. Kaiser appeals, claiming (1) insufficient randomness in the jury-selection process, (2) erroneous transcription of expert testimony, (3) lack of proximate causation, (4) lack of medical causation, (5) an improper jury instruction on defective design, (6) improper exclusion of sexual battery and marital discord evidence, (7) improper admission of post-exposure evidence, (8) improper exclusion of regulatory provisions, and (9) a failure to link its product to Budd’s disease. The Court of Appeals, Division 1, affirmed the verdict in favor of Budd.
Read the court decisionRead the full story...Reprinted courtesy of
Joshua Lane, Ahlers Cressman & Sleight PLLCMr. Lane may be contacted at
joshua.lane@acslawyers.com
Resilience: Transforming the Energy Sector – Navigating Land Issues in Solar and Storage Projects | Episode 3 (11.14.24)
December 17, 2024 —
Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law BlogIn the latest
episode of the Resilience podcast, colleague
Shellka Arora-Cox and Laura Pagliarulo, CEO and founder of SolaREIT, get down to the nitty-gritty in a discussion of the interplay of solar power capacity, generation and land use.
(Editor’s note: The following transcript has been edited for clarity.)
Welcome to Resilience, the vodcast where we talk about the most pressing challenges and the biggest opportunities in the energy sector. I’m your host, Shellka Arora-Cox, a partner at Pillsbury Winthrop Shaw Pittman. I’m thrilled to have Laura Pagliarulo, the CEO and founder of SolaREIT, with me today.
Read the court decisionRead the full story...Reprinted courtesy of
Pillsbury's Construction & Real Estate Law Team
Dealing with Abandoned Property After Foreclosure
April 10, 2019 —
Bremer Whyte Brown & O'Meara LLPCalifornia landlords must follow very specific steps before disposing of property that is clearly abandoned, left on real estate which has been the subject of court proceedings such as eviction or foreclosure, or otherwise left behind. Following the statutory procedures relating to abandoned property protects landlords from potential liability for an improper “conversion.”
Former tenants/owners and others “reasonably believed” to be owners of the apparently abandoned personal property must be given proper written notice of the right to reclaim the abandoned property. The tenant is presumed to be the owner of any “records” remaining on the property. The California Code of Civil Procedure provides a template for such notice. The notice to be provided to former tenants/owners must be in “substantially” the same form provided in the California Code of Civil Procedure and must contain the following information:
- A description of the abandoned property in a manner reasonably adequate to permit the owner of the property to identify it;
- The location where the tenant can claim the property;
- The time frame that the tenant has to claim the property. The date specified in the notice shall be a date not less than fifteen (15) days after the notice is personally delivered or, if mailed, not less than eighteen (18) days after the notice is deposited in the mail;
- A statement that reasonable storage costs will be charged to the tenant/owner and the tenant/owner must pay those costs before claiming the property; and
Read the court decisionRead the full story...Reprinted courtesy of
Bremer Whyte Brown & O'Meara LLP
Texas Supreme Court Rules on Contractual Liability Exclusion in Construction Cases
January 22, 2014 —
Beverley BevenFlorez-CDJ STAFFThe Texas Supreme Court ruled on Ewing v. Amerisure Ins. Co. on January 17th, a “much-anticipated” decision according to Carl A. Salisbury of Kilpatrick Townsend & Stockton LLP. “Construction projects are always the subject of contracts among owners and contractors” Salisbury stated in his article on Lexology.com. The recent decision demonstrates that “an exclusion in the standard Comprehensive Liability Insurance policy that precludes coverage for ‘liabilities assumed under contract’” does not usually “apply to construction contracts.”
In 2008, Ewing Construction Company built a set of tennis courts in Corpus Christi, according to Salisbury. “Shortly after construction was complete, according to the school district, ‘the courts started flaking, crumbling, and cracking, rendering them unusable for their intended purpose of hosting competitive tennis events.’” After the school district sued Ewing in state court, Ewing “turned the suit over to Amerisure, its CGL insurer, seeking a defense and indemnity. Amerisure denied all coverage, citing the contractual liability exclusion in its policy. This inspired Ewing to sue the carrier in federal district court for the Southern District of Texas.”
After several rulings and appeals, the case eventually reached the Texas Supreme Court: “According to the Ewing court, the contract claims that Ewing failed to perform in a good and workmanlike manner ‘are substantively the same as its claims that Ewing negligently performed under the contract because they contain the same factual allegations and alleged misconduct.’ Failure to perform in a ‘good and workmanlike manner’ is functionally and substantively the same as performing negligently. ‘Accordingly,’ the Ewing court said, ‘we conclude that a general contractor who agrees to perform its construction work in a good and workmanlike manner, without more, does not enlarge its duty to exercise ordinary care in fulfilling its contract, thus it does not ‘assume liability’ for damages arising out of its defective work so as to trigger the Contractual Liability Exclusion.’”
Read the court decisionRead the full story...Reprinted courtesy of
Rachel Reynolds Selected as Prime Member of ADTA
April 05, 2021 —
Rachel Tallon Reynolds - Lewis BrisboisSeattle Partner Rachel Tallon Reynolds was recently selected as a prime member of the Association of Defense Trial Attorneys (ADTA), an exclusive designation bestowed upon only one lawyer per one million population for each city, town, or municipality.
The ADTA is a select group of diverse and experienced civil defense trial attorneys whose mission is to improve their practices through collegial relationships, educational programs, and business referral opportunities, while maintaining the highest standards of professionalism and ethics. ADTA members possess the highest skill level of civil defense trial attorneys.
Moreover, because ADTA invites only one defense trial attorney to be its prime member per one million in population for each city, town, or municipality across the United States, the District of Columbia, Puerto Rico, Canada, France and The United Kingdom of Great Britain, as well as Northern Ireland and the Republic of Ireland, a prime membership represents the high regard in which that defense trial attorney is held by his or her peers in the defense trial bar of their city and state or province.
Read the court decisionRead the full story...Reprinted courtesy of
Rachel Tallon Reynolds, Lewis BrisboisMs. Reynolds may be contacted at
Rachel.Reynolds@lewisbrisbois.com
Contractor to Repair Defective Stucco, Plans on Suing Subcontractor
February 21, 2013 —
CDJ STAFFThe contractor for the Manatee County Judicial Center will be replacing the defective stucco on the building, but they have stated that they intend to go after the subcontractor who initially installed the defective stucco. The contractor, Balfour Beatty LLC, has said they will pay for the repairs, but Steve Holt, an executive of the firm said that “we have initiated a lawsuit against the subcontractor, who we believe was substantially or completely responsible to recover those funds.” Mr. Holt named Commercial Plastering as the subcontractor responsible.
Read the court decisionRead the full story...Reprinted courtesy of