Seattle Washington Building Expert Directory

How the Cumulative Impact Theory has been Defined

November 30, 2020 — David Adelstein - Florida Construction Legal Updates
Largely in the federal contract arena, there is a theory referred to as “cumulative impacts” used by a contractor to recover unforeseeable costs associated with a multitude of changes that have an overwhelming ripple effect on its efficiency, particularly efficiency dealing with its original, base contract work. In other words, by dealing with extensive changes, there is an unforeseeable impact imposed on the contractor relative to its unchanged or base contract work. Under this theory, the contractor oftentimes prices its cumulative impact under a total cost approach with an examination on its cost overrun. However, this is not an easy theory to prevail on because there needs to be a focus on the sheer number of changes, causation supporting the impact, and whether there were concurrent impacts or delays that played a role in the ripple effect. See, e.g., Appeals of J.A. Jones Const. Co., ENGBCA No. 6348, 00-2 BCA P 31000 (July 7, 2000) (“However, in the vast majority of cases such claims are routinely denied because there were an insufficient number of changes, contractor-caused concurrent delays, disruptions and inefficiencies and/or a general absence of evidence of causation and impact.”). To best articulate how the cumulative impact theory has been defined, I want to include language directly from courts and board of contract appeals that have dealt with this theory. This way the contractor knows how to best work with their experts with this definition in mind–and, yes, experts will be needed–to persuasively package and establish causation and damages stemming from the multitude of changes. While many of these definitions are worded differently, you will see they have the same focus dealing with the unforeseeable ripple effect of the extensive changes. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

No Coverage Under Property Policy With Other Insurance and Loss Payment Provisions

September 17, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The court determined that the other insurance and loss payment provisions relieved the insurer of coverage obligations. Moroney Body Works, Inc. v. Central Ins. Co., 2015 Mass. App. LEXIS 97 (Aug. 6, 2015). A fire destroyed Moroney's custom-built bookmobile that had just been completed. Moroney had two policies: a commercial property policy issued by Central, and a garage insurance policy issued by Pilgrim Insurance Company. Central denied liability for the bookmobile. Pilgrim covered the cost of repairing the bookmobile. It paid $12,449.82 based on the appraiser's estimate of the repair costs. Moroney thought this amount was inadequate given its own estimate of the repair costs. Moroney sued both insurers. Pilgrim settled by paying Moroney an additional amount which, when added to Pilgrim's earlier payment, resulted in Moroney receiving more than the repair cost. Moroney and Central both moved for summary judgment. The trial court granted Moroney's motion. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Hawaii Federal District Court Remands Coverage Dispute

June 15, 2020 — Tred R. Eyerly - Insurance Law Hawaii
Accepting the insured's amended complaint, the federal district court of Hawaii remanded the coverage action to state court. Hale v. Lloyd's, London, 2020 U.S. Dist. LEXIS 9061 (D. Haw. Jan. 17, 2020). Hale purchased a policy for his home in Hilo, Hawaii, from Defendant Pyramid Insurance Centre. The policy was memorialized by a Lloyd's Certificate issued by Defendant Lloyd's. On September 19, 2017, Hale entered Chapter 7 Bankruptcy. Included in the bankruptcy proceeding was Hale's home and a secured home mortgage loan now owned by Defendant Specialized Loan Servicing, LLC. The Bankruptcy Court issued a discharge order on January 18, 2018. On May 9, 2018, Hale's home was destroyed, being covered with lava from the Kilauea volcano eruption. Hale filed a claim with Lloyd's based upon the loss of his home. The claim was denied. Subsequently, however, Lloyd's issued a check for the full amount of the policy. Both Hale and Specialized Loan were listed as payees on the check. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Home Numbers Remain Small While Homes Get Bigger

June 28, 2013 — CDJ STAFF
Catherine Rampell reports in the New York Times that while the number of single-family homes built in 2012 was still at the very bottom of the range, since the government starting recording this data in 1973, the medium size for these homes is at its largest ever. According to data collected by the Census Bureau, these homes also have more bedrooms and bathrooms than previously. Of all homes built in 2012, forty-one percent had four or more bedrooms and thirty percent had three or more bathrooms. Both of these were the highest percentages in those categories. Meanwhile, the size of newly-built rental units declined in 2012. While still larger than the average rental unit built in 1999 (the earliest date given in the article), there has been little change over the last decade. During the same period, the size of sale units in multi-family buildings did show an increase. Read the court decision
Read the full story...
Reprinted courtesy of

North Carolina Should Protect Undocumented Witnesses to Charlotte Scaffolding Deaths, Unions Say

April 03, 2023 — Engineering News-Record
Charlotte Observer More than two months after a scaffolding collapse in Charlotte killed three men, labor unions are urging state leaders to protect undocumented construction workers who witnessed the collapse so they can safely talk to investigators. Reprinted courtesy of Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Form Contracts are Great, but. . .

November 12, 2019 — Christopher G. Hill - Construction Law Musings
Recently I was discussing the ConsensusDOCs with a colleague and friend and had a revelation. These forms are used often (though somewhat less than their AIA counterparts and less than they should be used). Quick disclaimer: I have been a part of a couple of drafting committees for ConsensusDOCs and am friends with Brian Perlberg, general counsel to the drafting effort. Some of the reason that these forms are so widely used is that they can be applied in a general way to almost any situation. Both sets of forms have documents for small and large jobs. Both have forms for Contractor/Owner and Contractor/Subcontractor. In short, a form document exists for about any scenario. I am writing now to let you know that while forms are great, they are just that. . . forms. Like with any set of forms, they need to be “tweaked” for your particular project. In my opinion they both have great clauses in them, and both have some flexibility built in (ConsensusDOCS more at the moment than the AIA forms). At the very least, construction professionals need to use this flexibility to conform the documents to their particular situation and do so within the documents themselves and not with addenda that “strike” or “modify” particular clauses. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Ninth Circuit Clears the Way for Review of Oregon District Court’s Rulings in Controversial Climate Change Case

February 27, 2019 — Anthony B. Cavender - Gravel2Gavel
On December 26, a divided panel of the U.S. Court of Appeals for the Ninth Circuit accepted an interlocutory appeal of the presiding District Court’s pre-trial rulings in the novel climate change case that is being tried in Oregon. The case is Juliana, et al. v. United States of America. In its ruling, the Ninth Circuit held that the District Court certification of this case for interlocutory appeal satisfied the provisions of 28 U.S.C. § 1292(b). Ninth Circuit precedents authorize such an appeal when a District Court order “involves a controlling question of law as to which there is a substantial ground for difference of opinion”—which aptly characterizes the U.S. Supreme Court’s view of this litigation. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

Tiny Houses Big With U.S. Owners Seeking Economic Freedom

July 16, 2014 — Nina Glinski – Bloomberg
Doug Immel recently completed his custom-built dream home, sparing no expense on details like cherry-wood floors, cathedral ceilings and stained-glass windows -- in just 164 square feet of living space including a loft. The 57-year-old schoolteacher’s tiny house near Providence, Rhode Island, cost $28,000 -- a seventh of the median price of single-family residences in his state. “I wanted to have an edge against career vagaries,” said Immel, a former real estate appraiser. A dwelling with minimal financial burden “gives you a little attitude.” He invests the money he would have spent on a mortgage and related costs in a mutual fund, halving his retirement horizon to 10 years and maybe even as soon as three. “I am infinitely happier.” Dramatic downsizing is gaining interest among Americans, gauging by increased sales of plans and ready-made homes and growing audiences for websites related to the niche. A+E Networks Corp. will air, beginning today, “Tiny House Nation” a series on FYI that “celebrates the exploding movement.” Read the court decision
Read the full story...
Reprinted courtesy of Nina Glinski, Bloomberg
Ms. Glinski may be contacted at nglinski@bloomberg.net

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES