What Every Project Participant Needs to Know About Delay Claims
August 05, 2024 —
Andrew G. Vicknair - The Dispute ResolverA “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays.
I. Types of Delays
Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule.
Read the court decisionRead the full story...Reprinted courtesy of
Andrew G. Vicknair, D'Arcy Vicknair, LLCMr. Vicknair may be contacted at
agv@darcyvicknair.com
Developer Transition - Maryland Condominiums
June 21, 2017 —
Nicholas D. Cowie - Maryland Condo Construction Defect Law BlogINTRODUCTION
“Developer transition” is the process by which the governance of a condominium association is transferred from developer to unit owner control. This article provides a brief overview of the legal requirements that govern the developer transition process for Maryland condominiums. This article also as well as a “transition checklist” for transitioning unit owner-controlled boards of directors.
PERIOD OF DEVELOPER CONTROL
A developer initially controls an association because it owns all unsold units in the newly created condominium community. As such, the developer has the controlling votes associated with majority ownership and can appoint its own employees as the initial members of the board of directors and thereby control how the condominium association conducts its affairs. This is referred to as the “period of developer control,” during which the developer makes all decisions on behalf of the association.
The developer also creates an association’s governing documents, allowing it to dictate, subject to applicable law, the procedures and time periods under which control over the association’s board of directors will eventually be transferred to the homeowners.
Read the court decisionRead the full story...Reprinted courtesy of
Nicholas D. Cowie, Cowie & Mott, P.A.Mr. Cowie may be contacted at
ndc@cowiemott.com
HOA Has No Claim to Extend Statute of Limitations in Construction Defect Case
October 28, 2011 —
CDJ STAFFThe California Court of Appeals ruled on September 20, 2011 in the case of Arundel Homeowners Association v. Arundel Green Partners, a construction defect case involving a condominium conversion in San Francisco. Eight years after the Notice of Completion was filed, the homeowners association filed a lawsuit alleging a number of construction defects, including “defective cabinets, waterproofing membranes, wall-cladding, plumbing, electrical wiring, roofing (including slope, drainage and flashings), fire-rated ceilings, and chimney flues.” Three years of settlement negotiations followed.
Negotiations ended in the eleventh year with the homeowners association filing a lawsuit. Arundel Green argued that the suit should be thrown out as California’s ten-year statute of limitations had passed. The court granted judgment to Arundel Green.
The homeowners then filed for a new trial and to amend its complaint, arguing that the statute of limitations should not apply due to the doctrine of equitable estoppel as Arundel Green’s actions had lead them to believe the issues could be solved without a lawsuit. “The HOA claimed that it was not until after the statute of limitations ran that the HOA realized Arundel Green would not keep its promises; and after this realization, the HOA promptly brought its lawsuit.” The trial court denied the homeowners association’s motions, which the homeowners association appealed.
In reviewing the case, the Appeals Court compared Arundel to an earlier California Supreme Court case, Lantzy. (The homeowners also cited Lantzy as the basis of their appeal.) In Lantzy, the California Supreme Court set up a four-part test as to whether estoppel could be applied. The court applied these tests and found, as was the case in Lantzy, that there were no grounds for estoppel.
In Arundel, the court noted that “there are simply no allegations that Arundel Green made any affirmative statement or promise that would lull the HOA into a reasonable belief that its claims would be resolved without filing a lawsuit.” The court also cited Lesko v. Superior Court which included a recommendation that the plaintiffs “send a stipulation?Ķextending time.” This did not happen and the court upheld the dismissal.
Read the court’s decision…
Read the court decisionRead the full story...Reprinted courtesy of
Texas Supreme Court Holds Stipulated Extrinsic Evidence May Be Considered in Determining Duty to Defend
May 10, 2022 —
Tred R. Eyerly - Insurance Law HawaiiResponding to certified questions from the Fifth Circuit, the Texas Supreme Court held that in limited circumstances, extrinsic evidence may be considered in determining the duty to defend. Monroe Guar. Ins. Co. v. Bitco Gen. Ins. Corp., 2022 Tex. LEXIS 148 (Tex. Feb. 11, 2022).
The two insurers each provided CGL coverage to the insured, 5D Drilling & Pump Service, Inc., at different times. BIitco provided two consecutive one-year CGL policies covering October 2013 to October 2015. Monroe's CGL policy covered 5D from October 2015 to October 2016.
5D was sued by David Jones for breach of contract and negligence, seeking damage allegedly resulting from 5D's drilling operations on Jones's property. Jones contracted with 5D in the summer of 2014 to drill a 3600-foot irrigation well on his farmland. The complaint did not detail when 5D's purportedly negligent acts occurred or even when 5D began or stopped the work.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Columbus, Ohio’s Tallest Building to be Inspected for Construction Defects
July 16, 2014 —
Beverley BevenFlorez-CDJ STAFFFox 28 news reported that “[t]he state of Ohio is going to spend more than $166,000 to inspect…the 40-year-old Rhodes Tower” in Columbus.
"They're going to look at the exterior of the building - [at] sealants between the joints, the condition of the panels, the window systems, how they're draining, how they're operating, and how they're sealed," Ned Thiell, of Ohio Facilities Construction Commission, told ABC 6/FOX 28 news.
A study completed last year declared there were “’deficiencies’ on the building’s stone covering” and there were “panels with severe fracture defects” that “will need to be replaced with new stone panels.”
Read the court decisionRead the full story...Reprinted courtesy of
White and Williams Earns Tier 1 Rankings from U.S. News "Best Law Firms" 2020
December 22, 2019 —
White and Williams LLPWhite and Williams has achieved national recognition from U.S. News and World Report as a "Best Law Firm" in the practice areas of Insurance Law and Media Law. Our Boston, New York and Philadelphia offices have also been recognized in their respective metropolitan regions in several practice areas. Firms included in the “Best Law Firms” list are recognized for professional excellence with persistently impressive ratings from clients and peers. Achieving a tiered ranking signals a unique combination of quality law practice and breadth of legal experience.
National Tier 1
Insurance Law
National Tier 3
Media Law
Metropolitan Tier 1
Boston
Product Liability Litigation – Defendants
Delaware
Product Liability Litigation – Defendants
New Jersey
Labor Law – Management
Philadelphia
Commercial Litigation
Insurance Law
Medical Malpractice Law – Defendants
Personal Injury Litigation – Defendants
Personal Injury Litigation – Plaintiffs
Metropolitan Tier 2
Boston
Insurance Law
Delaware
Medical Malpractice Law – Defendants
New Jersey
Employment Law - Management
Litigation - Labor & Employment
Philadelphia
Bet-the-Company Litigation
Legal Malpractice Law – Defendants
Media Law
Real Estate Law
Tax Law
Trusts & Estates Law
Metropolitan Tier 3
New York City
Bankruptcy and Creditor Debtor Rights / Insolvency and Reorganization Law
Philadelphia
Appellate Practice
Construction Law
First Amendment Law
Litigation – Construction
Litigation – Labor & Employment
Patent Law
Read the court decisionRead the full story...Reprinted courtesy of
White and Williams LLP
Beyond the Disneyland Resort: Dining
May 03, 2018 —
Beverley BevenFlorez-CDJ STAFFFor fine dining experiences outside of the Disneyland Resort, try
Summit House Restaurant or the
Anaheim White House Italian Steak House .
A more unusual and upscale restaurant, try
The Hobbit in nearby Orange, California. They offer a seven-course, prix-fixe menu by reservation only. It’s a four-hour dining experience that begins in their Wine Cellar, then guests are taken to their tables in the dining room. Next, is an intermission where guests are encouraged to relax on the patios or visit the kitchen to chat with the chef. Guests then return to their table to finish their entrees and dessert.
If you’d rather spend your time in a unique lounge or bar, try
the Blind Rabbit, which calls itself Orange County’s speak easy. Located in the Anaheim Packing District, the Blind Rabbit’s tables are all reserved after 5pm, and you might want to brush up on their list of rules prior to visiting.
For something casual, try
Hollinghead’s Delicatessen in Orange, where you can purchase hand crafted sandwiches and beers.
Read the court decisionRead the full story...Reprinted courtesy of
What to Know Before Building a Guesthouse
September 17, 2014 —
Cynthia Flash – BloombergThose tiny, often very cute homes that people are adding on their properties seem to be popping up everywhere these days. The tiny buildings can provide extra rental income, offer a less-expensive housing option or provide a home for a relative.
Accessory dwelling units, or ADUs, are second dwelling units created on a lot with an existing house or attached house. They’re often referred to as mother-in-law apartments, granny flats or studio apartments. As a homeowner, what are the legal issues to consider before building an ADU of your own?
Different cities, different rules
First off, different cities have different rules. Before plotting the space for your new tiny house, check with your city’s planning and zoning department to determine what those rules are. You can start online at accessorydwellings.org for a list of regulations by state and city.
Read the court decisionRead the full story...Reprinted courtesy of
Cynthia Flash, Bloomberg
