Fairfield Connecticut Building Expert Directory

Broker Not Negligent When Insured Rejects Additional Coverage

January 31, 2018 — Tred R. Eyerly – Insurance Law Hawaii

The broker was not negligent when it proposed additional coverage that was rejected by the insured. Cromer v. Rosenzweig Ins. Agency Inc., 2017 N.Y. App Div. LEXIS 8969 (N.Y. App. Div. Dec. 21, 2017).

Plaintiff was injured while employed as a painter at property owned by Allen Skriloff. Coverage was denied because injuries to employees, contractors and employees of contractors were excluded. Plaintiff sued Skriloff and obtained a jury verdict of $6.1 million. Skirloff assigned to plaintiff all rights and claims held against the insurer and insurance brokers.

Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly, Insurance Law Hawaii

Construction Law: Unexpected, Fascinating, Bizarre

April 25, 2012 — CDJ STAFF

Guy Randles offers an amusing set of odd construction law cases in the Daily Journal of Commerce, which he describes as “the unexpected, the fascinating and even the bizarre.” He noted that in one case “a whistleblower claimed he was terminated for reporting to the owner that the contractor’s painters had not applied the required coating thickness.” The whistleblower was the project manager and “was responsible for ensuring the proper coating thickness.”

A less amusing case was that of an architect who was arrested for manslaughter. Gerard Baker “told investigators that the considered the fireplaces to be merely decorative.” Randles notes that “the mansion’s fireplaces were built of wood framing and lined with combustible drywall.” Further, a “gas fireplace even vented into the house’s interior.” Building officials called the house “a death trap.” According to the LA police chief this may be the only case in which building defects lead to a manslaughter charge.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

Condo Board Goes after Insurer for Construction Defect Settlement

February 07, 2013 — CDJ STAFF
The City Bella on Lyndale homeowners association settled with the high rise's developer and builder for $1.9 million over construction defects. The defects included structural deterioration in the project's pool area, extensive air and water leaks in the windows, and structural problems in the project's underground parking garage. City Bella consists of a 15-story tower and a four-story building on Lyndale Avenue in Minneapolis. They settled the lawsuit in 2011, but the homeowners association is still looking to the insurers to pay up. With legal fees and interest, the total rises to $2.82 million that Travelers could be paying the association. Read the court decision
Read the full story...
Reprinted courtesy of

Conversations with My Younger Self: 5 Things I Wish I Knew Then

July 24, 2023 — Steve Swart - The Dispute Resolver
I remember the morning I became a construction law attorney. It was on my birthday several years ago when a partner called me into his office and asked me to review the A107 contract form for a large firm client. The assignment gave me a new language to speak and contract provisions that I came slowly to understand. I quickly moved into construction litigation and would soon learn that a "fragnet" was not the newest social media app but an important part of a delay claim. I read Spearin's biography and learned how to assess recoverable damages for different claims—costs to repair, replacement and betterment, increased financing/carrying costs, and the like. It took a lot of blood, sweat, and tears to get to where I am now. Echoing Rod Stewart’s sentiment—“I wish that I knew then, what I do now, when I was younger”—here are five tips I’d pass along to the younger me or anyone who is beginning their career as a construction lawyer: Read the court decision
Read the full story...
Reprinted courtesy of Steve Swart, Williams Mullen
Mr. Swart may be contacted at sswart@williamsmullen.com

Toddler Crashes through Window, Falls to his Death

January 24, 2014 — Beverley BevenFlorez-CDJ STAFF
Two-year old Alijah Glenn fell 17 stories to his death after crashing through “a floor-to-ceiling window” at the Crystal Tower apartments in East Cleveland, Ohio, on January 13th, according to The Plain Dealer. Solandra Wallace, East Cleveland’s building and housing manager, told The Plain Dealer that “the city inspects the building whenever a complaint is filed and does not have regular inspections.” The apartment complex “was built in 1966 and would have to adhere to that era's building code standards,” according to the article. The Plain Dealer reports that three complaints have been filed at the Crystal Tower since 2010. A resident complained in 2012 that “her apartment was falling apart, causing water damage and emitting a foul odor,” however, by the time an inspector arrived the ceiling was being fixed. In 2011, an “unspecified roof leak” turned out to be “condensation from a hot pipe.” An elevator was reported inoperable in 2010, however the claim was deemed “invalid” since the elevator worked when inspectors arrived. The Cuyahoga County Medical Examiner ruled Glenn’s death accidental. Read the court decision
Read the full story...
Reprinted courtesy of

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Legal Risks of Green Building

March 22, 2021 — Mark D. Shifton - Construction Executive
All construction projects involve elements of legal risk. Insurance and indemnity claims, delay claims and professional negligence claims are simply accepted risks when involved in construction. Green building projects are no exception to this rule, and often involve unique issues that are not present in typical construction projects. Green building projects commonly employ new or untested construction materials, require construction methods that lack significant track records, and ultimate building performance often fails to meet design expectations. As such, green building projects may give rise to entirely new types of legal risk that should be considered and allocated early in the process. In the past 15 years, the number of buildings for which green certifications have been sought has grown exponentially, and the growth rate of green building and sustainable construction has far outpaced the growth rate of the construction industry as a whole. As green building projects become increasingly common (and often increasingly required by the federal, as well as state and local governments), the unique legal risks presented by green building projects take on an increase importance. Reprinted courtesy of Mark D. Shifton, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Shifton may be contacted at mshifton@gllawgroup.com

SB800 Not the Only Remedy for Construction Defects

October 01, 2013 — CDJ STAFF
“We anticipate an increase in residential construction defect litigation in response to this ruling,” David Frenznic, a construction defect lawyer at Wilke, Fleury, Hoffelt, Gould & Birney LLP told the Central Valley Business Times. Mr. Frenznic was responding to an August ruling by the California Court of Appeals that found that SB800 does not create the only remedy for homeowners with construction defects. “Homeowners who suffer actual damage as a result of construction defects have a choice of remedies,” said Mr. Frenznick. SB800 established a shorter statute of limitations for construction defect claims, however, “the ruling makes clear that common law claims are still governed by the longer statues of limitations.” Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES