Indirect Benefit Does Not Support Unjust Enrichment Claim Against Prime Contractor
July 05, 2023 —
David Adelstein - Florida Construction Legal UpdatesA recent case out of the Northern District of Florida dealing with a federal project provides an interesting discussion about a sub-subcontractor asserting a claim against the prime contractor for unjust enrichment. The prime contractor argued any benefit to it was indirect which does not support an unjust enrichment claim as the actual direct benefit flowed to the owner of the project – the government. The federal district court agreed and dismissed the sub-subcontractor’s unjust enrichment claim against the prime contractor because an indirect benefit does NOT support an equitable unjust enrichment claim. See U.S.A f/u/b/o Eco Universe Contracting, LLC v. Calvary Construction Group, Inc., 2023 WL 3884642 (N.D.Fla. 2023).
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Congratulations to Partner Vik Nagpal on his Nomination for West Coast Casualty’s Jerrold S. Oliver Award of Excellence!
March 27, 2023 —
Dolores Montoya - Bremer Whyte Brown & O'Meara LLPBremer Whyte Brown & O’Meara, LLP is honored to share that Downtown San Diego and Encinitas Managing Partner Vik Nagpal is nominated for West Coast Casualty’s Jerrold S. Oliver Award of Excellence!
Every year, West Coast Casualty recognizes an individual who is committed, trustworthy, and has contributed to the betterment of the construction defect community. The award is named after the late Judge Jerrold S. Oliver who is considered a “founding father” in the alternate resolution process in construction claims and litigation. Each year, members of the construction community are asked to nominate individuals who invoke the same spirit as Judge Oliver.
Read the court decisionRead the full story...Reprinted courtesy of
Dolores Montoya, Bremer Whyte Brown & O'Meara LLP
Know Whether Your Course of Business Operations Are Covered Or Excluded By Your Insurance
December 27, 2021 —
David Adelstein - Florida Construction Legal UpdatesIt is a good idea to know what your insurance covers and does not cover. This way, if your course of business has you performing a certain (risky) operation, you know whether that operation is covered or excluded under your policy. If you are not sure, discuss with your insurance broker — this is important. There is little value performing an operation that is NOT covered by your insurance policy, as you are now performing a risk that is not covered by insurance. If you know it is not covered by insurance you may elect to change your operations or see if there is insurance to cover the risk. Below is a case study of this occurrence dealing with a commercial automobile liability policy where an insured’s operations using a crane mounted to a super duty truck was not covered under their automobile liability policy.
In People’s Trust Ins. Co. v. Progressive Express Ins. Co., 46 Fla. L. Weekly D262a (Fla. 3d DCA 2021), homeowners hired a company to install a shed. The company hired another company to deliver and install the shed using a crane; the company used a crane mounted to a Ford F-750 super duty truck. This company improperly operated the crane resulting in the shed falling and damaging the homeowner’s roof. The homeowners submitted a claim to their property insurer and their property insurer subrogated to their rights and sued. The company operating the crane’s commercial automobile liability insurer denied coverage, and thus, denied the duty to defend. As a result, a
Coblentz-type agreement was entered into where the company operating the crane consented to a judgment in favor of the property insurer (subrogee) and assigned its rights under its commercial automobile liability policy to the property insurer. The property insurer then sued the automobile liability carrier for coverage. The trial court granted summary judgment in favor of the automobile liability insurer finding there was no coverage and this was affirmed on appeal. Why?
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Late Progress Payments on Local Public Works Projects Are Not a Statutory Breach of Contract
May 10, 2022 —
Ted Senet & Christopher Trembley - Gibbs GidenCalifornia local public agencies and their contractors should take note of a recent appellate decision pertaining to late progress payments on public works projects. In Clark Bros., Inc. v. North Edwards Water Dist., 2022 Cal. App. LEXIS 331, filed on April 22, 2022, the Court of Appeal for the Fourth Appellate District held that a local agency’s late progress payments to a general contractor did not constitute breach of contract under the prompt payment penalty statute, Public Contract Code § 20104.50. Notwithstanding this holding, the contractor recovered damages, interest, fees, and costs in excess of its contract amount.
In 2013, the North Edwards Water District awarded a $6.2 million contract to Clark Bros., Inc. to construct a water treatment facility. The District’s water contained excessive levels of arsenic, and the project was sponsored by the State of California with funds earmarked to provide safe drinking water. The State agreed to disburse funds to the District during construction upon the State’s review and approval of the contractor’s progress payment applications. The contract required completion of the work within one year following the District’s issuance of a notice to proceed to the contractor.
As a result of factors arguably outside the control of the contractor, including unforeseen site conditions and the failure of the District’s equipment supplier to meet delivery deadlines, the project was significantly delayed beyond the deadline for completion. The District nonetheless terminated the contractor, which in turn filed suit against the District and the State. The contractor asserted claims for breach of contract, including breach of contract for the District’s failure to pay the contractor’s progress payment applications within the time specified under Public Contract Code § 20104.50. Subsection (b) of the statute provides:
Any local agency which fails to make any progress payment within 30 days after receipt of an undisputed and properly submitted payment request from a contractor on a construction contract shall pay interest to the contractor equivalent to the legal rate set forth in subdivision (a) of Section 685.010 of the Code of Civil Procedure.
Reprinted courtesy of
Ted Senet, Gibbs Giden and
Christopher Trembley, Gibbs Giden
Mr. Senet may be contacted at tsenet@gibbsgiden.com
Mr. Trembley may be contacted at Ctrembley@gibbsgiden.com
Read the court decisionRead the full story...Reprinted courtesy of
VinFast Breaks Ground in North Carolina on its Promised $4B EV Plant
August 28, 2023 —
Engineering News-RecordCharlotte Observer
North Carolina officials and top VinFast executives met Friday morning in Chatham County to officially start construction on the carmaker’s first manufacturing facility outside its native Vietnam. By 2028, VinFast has committed to employ 7,500 people at the site, about 30 miles southwest of Raleigh . In terms of projected job creation, it is the largest state-backed economic project in North Carolina history.
Reprinted courtesy of
Engineering News-Record
ENR may be contacted at enr@enr.com
Read the full story... Read the court decisionRead the full story...Reprinted courtesy of
Halliburton to Pay $1.1 Billion to Settle Spill Lawsuits
September 03, 2014 —
David Wethe, Margaret Cronin Fisk and Laurel Calkins – BloombergHalliburton Co. agreed to pay $1.1 billion to settle a majority of lawsuits brought over its role in the largest offshore oil spill in U.S. history.
The agreement is subject to court approval and includes legal fees, the Houston-based company said in a statement today. Halliburton was accused by spill victims and BP Plc of doing defective cementing work on the Macondo well before the April 2010 Gulf of Mexico oil spill. Halliburton blamed the incident on decisions by BP, which owned the well.
The settlement comes as the judge overseeing oil-spill cases weighs fault for the disaster. An agreement now averts the company’s risk of a more costly judgment for some spill victims and removes much of the uncertainty that has plagued Halliburton for the past four years as investors waited to see the payout tally. With its biggest piece of liability resolved, Halliburton can refocus its attention on developing new oilfield technology that will help it boost profits worldwide.
Reprinted courtesy of Bloomberg journalists
David Wethe,
Margaret Cronin Fisk and
Laurel Calkins
Mr. Wethe may be contacted at dwethe@bloomberg.net; Ms. Fisk may be contacted at mcfisk@bloomberg.net; and Ms. Calkins may be contacted at lcalkins@bloomberg.net
Read the court decisionRead the full story...Reprinted courtesy of
Injured Construction Worker Settles for Five Hundred Thousand
October 28, 2011 —
CDJ STAFFAn upstate New York man who was injured when an unsecured truss fell off the railings of a scissor lift has settled for $500,000. As the accident happened at the building site for a casino for the Seneca Nation, attorneys for the construction firm had argued that New York labor laws were inapplicable as the injury happened on Seneca Nation land. The state appeals court ruled that as none of the parties involved were Native Americans, it was not internal to the affairs of the Seneca Nation.
Read the full story...
Read the court decisionRead the full story...Reprinted courtesy of
It Pays to Review the ‘Review the Contract Documents’ Clause Before You Sign the Contract
March 11, 2024 —
Alan Winkler - ConsensusDocsIt is fairly common for a construction contract to include a provision requiring the contractor to perform some level of review of the plans and specifications and perhaps other contract documents as part of their responsibilities. Typically, this provision is found in a section of the contract on the contractor’s responsibilities, although it can be anywhere. Owners and contractors are, with reason, focused on three main issues in reviewing contracts: (1) price, costs, and payments, (2) time and scheduling, and (3) scope of the work. Eyes may glaze over the contractor’s responsibilities section. Not only does it seem to be boilerplate, but industry professionals know what a contractor is supposed to do; in a nutshell, build the project.
An old school type of contractor may regard this role as strictly following the plans and specifications, no matter what they provide. That could lead to a situation where construction comes to a complete stop because, for example, two elements are totally incompatible with each other. If that happens, the contractor would then turn to the owner and architect to ask for a corrective plan and instructions on how to proceed. That may also be accompanied by a request for more time and money while the problem is resolved. The ‘review the contract documents’ clause is designed to avoid this. It is intended to address an understanding that everyone makes mistakes, even architects and engineers whose job it is to design a buildable, functional project. The clause also addresses the understanding that a contractor is more than a rote implementer of plans and specifications because its expertise in building necessarily means the contractor has expertise in understanding the documents that define the construction and how things are put together.
Read the court decisionRead the full story...Reprinted courtesy of
Alan Winkler, Peckar & Abramson, P.C.Mr. Winkler may be contacted at
awinkler@pecklaw.com