Fairfield Connecticut Building Expert Directory

#10 CDJ Topic: Carithers v. Mid-Continent Casualty Company

December 30, 2015 — Beverley BevenFlorez-CDJ STAFF
Craig Martin of Lamson Dugan and Murray, LLP on his Construction Contractor Advisor blog used the Carithers case to demonstrate how “[w]hen you are involved in construction litigation, you have battles on several fronts, including those against subcontractors, owners, insurers and the court. Shoring up your defenses on each of these fronts is imperative, or you may lose the battle or, worse yet, the war.” Martin discusses the various “battle fronts” including the “Claim Against Contractor,” “Where Are You Litigating,” “Claim Against Insurance Company,” and “Damages.” Read the full story... In the article, “Duty to Defend Construction Defect Case Affirmed, Duty to Indemnify Reversed In Part,” attorney Tred R. Eyerly also covered the Carithers case. Eyerly explained, “Determining whether there was coverage for the damages awarded required the court to decide which trigger applied. Examining the policy language, the court determined that property damage occurred when the damage happened, not when the damage was discovered or discoverable. Therefore, the district court did not err in applying the injury in fact trigger.” Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Just When You Thought General Contractors Were Necessary Parties. . .

December 31, 2014 — Christopher G. Hill – Construction Law Musings
Did you think that a subcontractor had to name a general contractor in a mechanic’s lien suit? I did. Did you think that nothing about this changed in the case where a Virginia mechanic’s lien was “bonded off” pursuant to Va. Code Section 43-71? I did. Well, a recent Virginia Supreme Court case, Synchronized Construction Services Inc. v. Prav Lodging LLC, seems to at least create some doubt as to whether the a general contractor is a “necessary” party to a lawsuit by a subcontractor in the case where a bond is posted for release of a mechanic’s lien. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, Law Office of Christopher G. Hill, PC
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Repairs to Water Infrastructure Underway After Hurricane Helene

October 07, 2024 — Derek Lacey - Engineering News-Record
As transportation officials in Tennessee and North Carolina brace for long rebuilds of heavily damaged interstates in remote and rugged areas of the Appalachian Mountains, local agencies are also at work restoring water and sewer services to residents nearly one week after Hurricane Helene made landfall. Reprinted courtesy of Derek Lacey, Engineering News-Record Mr. Lacey may be contacted at laceyd@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

West Coast Casualty’s Quarter Century of Service

May 03, 2018 — Beverley BevenFlorez-CDJ STAFF
West Coast Casualty's Construction Defect Seminar has been promoting charitable work for the past twenty-five years. Each year, they promote different charities, and provide multiple ways for individuals and companies to contribute. Whether it’s Buy a Banner, Tennis Shoe Thursday, or Flip Flop Friday, industry members are given opportunities to support worthwhile causes. This year, West Coast Casualty is supporting Hawaii’s Children’s Cancer Foundation , St. Jude Children’s Research Hospital, and Shriners Hospital for Children. WCC also supports charitable organizations through every award that they present each year. Donations are made in the winner’s name: For Jerrold S. Oliver Award of Excellence awardees, Habitat for Humanity as well as a local California and Nevada charity; For Legend of an Era Award, the designated charity of West Coast Casualty’s Construction Defect Seminar; and for The Larry Syhre Commitment to Service Award, a donation to The Larry Syhre Foundation. Read the court decision
Read the full story...
Reprinted courtesy of

Subcontract Should Flow Down Delay Caused by Subcontractors

December 21, 2020 — David Adelstein - Florida Construction Legal Updates
A general contractor’s subcontract with its subcontractor should include a provision that entitles it to flow down liquidated damages assessed by the owner stemming from delays caused by the subcontractor. Such a provision does not mean the general contractor does not have to prove delays caused by the subcontractor or can arbitrarily allocate the amount or days it claims the subcontractor is liable. The general contractor still will need to reasonably establish the delays the subcontractor caused the critical path of the schedule, i.e., delayed the job. In addition to the right to flow down liquidated damages, the subcontract should also entitle the general contractor to recover its actual extended general conditions caused by the subcontractor’s delays (regardless of whether the owner assesses liquidated damages). The objective is that if the subcontractor delays the job, the subcontractor is liable for liquidated damages the general contractor is liable to the owner for in addition to the general contractor’s own delay damages. This is an important subcontractual provision so that the risk of delay caused by subcontractors is clearly flowed down to them in the subcontract. In a 1987 case, Hall Construction Co., Inc. v. Beynon, 507 So.2d 1225 (Fla. 5th DCA 1987), the subcontract at-issue contained language that stated, “The parties hereto agree that a supplier who delays performance beyond the time agreed upon in this Purchase Order shall have caused [general contractor] liquidated damages in the amount required of [general contractor] by their contract per day for each day such delay continues which sum the supplier hereby agrees to pay.” Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Repairs to Hurricane-damaged Sanibel Causeway Completed in 105 Days

February 12, 2024 — Marigo Farr - Engineering News-Record
Permanent repairs to the roadway portion of the Sanibel Causeway are substantially complete one year and four months after more than 6,000 Sanibel Island residents lost access to the mainland in the wake of Hurricane Ian. The Superior Construction and The De Moya Group joint-venture team, responsible for the work, say that all travel lanes are now permanently open to the island off Florida's southwest coast near Fort Myers. Reprinted courtesy of Marigo Farr, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

OSHA Joins the EEOC in Analyzing Unsafe Construction Environments

June 26, 2023 — Cameron S. Hill Sr. - Construction Executive
Consistent with the Equal Employment Opportunity Commission's (EEOC) Strategic Enforcement Plan (SEP) published in January 2023, which noted an increased focus on the construction industry as it relates to harassment and discrimination issues within the workplace and around hiring and the advancement of minorities, the Occupational Safety and Health Administration (OSHA) is following suit. At the end of March 2023, OSHA leaders announced another arrow in their quiver: OSHA has new authority through its Wage and Hour Division to issue certifications supporting applications for "U" nonimmigrant status and "T" nonimmigrant status visas. Reasoning that workers' immigration status, social inequalities or differences in culture can cause them to fear retaliation for identifying unsafe work environments and criminal activity, such as trafficking, murder, blackmail, extortion and other serious crimes, Assistant Secretary of Labor for Occupational Safety and Health, Doug Parker stated, "The Occupational Safety and Health Administration's top priority is to ensure workers are safe and can exercise their rights, regardless of their demographic or immigration status. A key part of that mission is expanding our work to combat workplace inequities that can create hazards and affect vulnerable workers who are likely to be exploited or victims of crimes. Our vision extends beyond setting standards, inspecting workplaces and providing training. Becoming a visa-certifying agency gives us one more tool in our wide-ranging efforts to better protect workers and their rights on the job." Reprinted courtesy of Cameron S. Hill Sr., Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Mr. Hill may be contacted at chill@bakerdonelson.com Read the court decision
Read the full story...
Reprinted courtesy of

Recovering Unabsorbed Home Office Overhead Due to Delay

May 30, 2022 — David Adelstein - Florida Construction Legal Updates
In the preceding article, I discussed the use of a retrospective as-built delay analysis in a case before the Civilian Board of Contract Appeals (CBCA). This case also discussed a damages component in certain delay claims known as unabsorbed home office overhead—a challenging damages component to recover because this deals with indirect costs as opposed to direct costs. Unabsorbed home office overhead is a damages component when the contractor is on standby, but this is NOT as easy as just claiming standby thereby you are automatically entitled to unabsorbed home office overhead. There are requirements that MUST be met.

To obtain an equitable adjustment for unabsorbed home office overhead as compensation for being on standby, [the contractor] must initially show “[1] a government-caused delay of uncertain duration,” that “[2] the delay extended the original time for performance” or precluded the contractor from finishing earlier than scheduled, and that “[3] the contractor [was] on standby and unable to take on other work during the delay period. CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022) quoting Nicon, Inc. v. U.S., 331 F.3d 878, 883 (Fed. Cir. 2003).

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES