Fairfield Connecticut Building Expert Directory

Vermont Supreme Court Reverses, Finding No Coverage for Collapse

May 18, 2020 — Tred R. Eyerly - Insurance Law Hawaii
The Vermont Supreme Court reversed the trial court's decision for collapse coverage. Commercial Constr. Endeavors, Inc. v. Ohio Sec. Ins. Co., 2019 Vt. LEXIS 173 (Vt. Sup. Ct. Dec. 13,2019). Commercial Construction Endeavors, Inc. (CCE) built a livestock barn. By late December 2014, the barn was partially complete, with the foundation laid, wood framing erected, and roof trusses installed. In late December, strong winds caused the structure to collapse. CCE started clearing debris and rebuilding the barn, incurring additional labor and material costs. CCE reported the collapse to Ohio Security. The policy covered loss to "Covered Property." Ohio Security determined that the loss was covered for "Off-Premises Property Damage Including Care, Custody or Control." This endorsement provided coverage for damage to real property upon which CCE was performing operations where the damage resulted from those operations. Ohio Security paid CCE $24,750, the full amount available under the endorsement, less a $250 deductible. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Condominium Association Responsibility to Resolve Construction Defect Claims

July 23, 2014 — Nicholas D. Cowie – Maryland Condo Construction Defect Law Blog
The Maryland Court of Special Appeals recently issued an opinion in Greenstein v. Council of Unit Owners of Avalon Court Six Condominium Inc. finding that an association can be sued by its unit owner members if it fails to take timely legal action against a developer. In that case, the association was aware of construction defects, but failed to take action to preserve its claim and then filed a lawsuit against the developer too late, after the statute of limitations expired. As a result, the suit against the developer was dismissed and the association was forced to assess its unit owner members for the $1 million in repair costs. Some of the unit owners then sued their association, seeking to recover the cost of their assessments on the ground that the association was negligent in failing to pursue a timely legal action against the developer. On appeal, the court was asked to decide whether state law permits owners to sue their condominium association for negligently failing to sue a developer for common element construction defects. The court, in an unpublished opinion, found that an association could be held liable to its members. The court said: “The duty to maintain, repair and replace the common elements together with the exclusive right to initiate litigation regarding the common elements [which was stated in a provision of the association’s bylaws] creates a concomitant obligation on the part of the [association] to pursue recovery from [the developer] on behalf of [the unit owners] for damage to the common elements caused by [the developer’s] negligence, breach of contract or violation of any applicable law.” Read the court decision
Read the full story...
Reprinted courtesy of Nicholas D. Cowie, Maryland Condo Construction Defect Law Blog
Mr. Cowie may be contacted at ndc@cowiemott.com

Mutual Or Concurrent Delay Caused By Subcontractors

March 23, 2020 — David Adelstein - Florida Construction Legal Updates
How are delay damages treated when two subcontractors cause a mutual or concurrent delay to the project? Assume multiple subcontractors concurrently contributed to an impact to the critical path resulting in a delay to the project. The delay caused the prime contractor to: (1) be assessed liquidated damages from the owner and (2) incur extended general conditions. The prime contractor will be looking to the subcontractors for reimbursement for any liquidated damages it is assessed along with its extended general conditions costs. There is really no great case that addresses this point when two (or more) subcontractors mutually or concurrently delay the project. It is also not uncommon, and frankly expected, that a subcontractor will point the finger at another subcontractor for the cause of the delay or that another subcontractor was concurrently delaying the project. The prime contractor should absolutely, without any exception, undertake efforts with a scheduling consultant to allocate the delay caused by subcontractors. Taking an approach that joint and several liability applies between multiple subcontractors and/or not trying to apportion delay because the subcontractors concurrently delayed the critical path at the same time is probably not the best approach. The prime contractor should have an expert render an opinion as to the allocation of the delay period amongst responsible subcontractors that delayed the critical path. Not doing so, in my opinion, is a mistake. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Congratulations 2024 DE, MA, MD, NJ, NY, and PA Super Lawyers and Rising Stars

June 17, 2024 — White and Williams LLP

White and Williams congratulates the fifteen attorneys nominated as Super Lawyers and ten attorneys named Rising Stars across our Delaware, Massachusetts, Maryland, New Jersey, New York and Philadelphia offices. Lawyers are selected through a process that takes into consideration peer recognition and professional achievement. The lawyers named to this year’s list represent a multitude of practices throughout the firm.

Super Lawyers 2024

Attorney	Super Lawyers Denoted Practice Area (s)
David B. Chaffin	Business Litigation
Robert G. Devine	Personal Injury, Employment Litigation, Products Liability
David D. Gilliss	Surety, Construction Litigation, Administrative Law

Read the court decision
Read the full story...
Reprinted courtesy of White and Williams LLP

Economy in U.S. Picked Up on Consumer Spending, Construction

October 02, 2015 — Shobhana Chandra – Bloomberg
The world’s largest economy expanded more than previously forecast in the second quarter, boosted by gains in consumer spending and construction that may help the U.S. withstand a global slowdown. Gross domestic product rose at a 3.9 percent annualized rate, compared with a prior estimate of 3.7 percent, Commerce Department figures showed Friday in Washington. The median forecast of 76 economists surveyed by Bloomberg called for a 3.7 percent gain. Strong hiring, cheaper gasoline and higher home prices will probably sustain household purchases, which account for about 70 percent of the economy. That helps bolster Federal Reserve Chair Janet Yellen’s view that the U.S. will overcome any fallout from cooling overseas markets and swings in global financial and commodity markets. Read the court decision
Read the full story...
Reprinted courtesy of Shobhana Chandra, Bloomberg

Wilke Fleury ranked in Best Lawyers’ Best Law Firms!!

December 03, 2024 — Wilke Fleury LLP
Wilke Fleury is pleased to announce its inclusion in the 2025 edition of ‘Best Law Firms’ ranked by Best Lawyers! Firms included in the 2025 “Best Law Firms” list are recognized for professional excellence with persistently impressive ratings from clients and peers. Achieving a tiered ranking signals a unique combination of quality law practice and breadth of legal expertise. Read the court decision
Read the full story...
Reprinted courtesy of Wilke Fleury LLP

HVAC System Collapses Over Pool at Gaylord Rockies Resort Colorado

June 12, 2023 — Jennifer Seward - Engineering News-Record
The collapse May 6 of the HVAC system above an indoor pool at the Gaylord Rockies Resort near Denver sent six people to local hospitals, two with life-threatening injuries. An estimated 50 to 100 people were in the water or on the pool deck as pieces of the system fell into the pool and hot tub. Reprinted courtesy of Jennifer Seward, Engineering News-Record Ms. Seward may be contacted at sewardj@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Florida Extends Filing Time for Claims Subject to the Statute of Repose

June 13, 2018 — William L. Doerler - The Subrogation Strategist
Under Florida’s construction-related statute of repose, Fla. Stat. § 95.11, actions based on the design, planning or construction of an improvement to real property are barred if not commenced within 10 years after the later of several possible dates, including the date of actual possession by the owner and the date of the issuance of a certificate of occupancy. The Florida Legislature recently amended the statute to extend the time within which defendants subject to a suit filed close to the end of the 10-year period can file claims. Under the revised law, a defendant can file “counterclaims, cross-claims and third-party claims up to 1 year after the pleading to which such claims relate is served.” Regardless of when the cause of action at issue accrued, the law applies to actions commenced on or after July 1, 2018, except that any action that would not have been barred under Fla. Stat. § 95.11(3)(c) prior to the amendment may be commenced before July 1, 2019. The revised law provides relief to defendants because, under the prior law, they had to file claims against other potentially responsible third parties before the expiration of the statute of repose. Under the new law, defendants can bring third parties into the action after the expiration of the 10-year statute of repose period. Read the court decision
Read the full story...
Reprinted courtesy of William L. Doerler, White and Williams LLP
Mr. Doerler may be contacted at doerlerw@whiteandwilliams.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES