CAMBRIDGE MASSACHUSETTS BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?

January 27, 2020 — Ted R. Gropman & Christine Z. Fan - ConsensusDocs
Construction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date. Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved. There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973). Reprinted courtesy of Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP Mr. Gropman may be contacted at gropmant@pepperlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Insurance and Your Roof

November 13, 2013 — CDJ STAFF
Those seeking home insurance should look up. Bankrate points out that the type of roof a home has can affect how much it costs to insure it. “The roof is the first layer that wind, hail, wildfire and other hazards really begin to act on,” Tim Reinhold, the chief engineer at the Insurance Institute for Business and Home Safety, told the site. For insurers, the most problematic roof type is probably wood shakes. “Some companies won’t even insure certain roof types, such as wood shakes, in high fire-risk areas,” said Robert Hunter, the director of insurance for the Consumer Federation of America. Not that other roof types are problem-free. Metal roofs can corrode, particularly when two different metals touch. Shingles age more quickly than other roof types, becoming brittle, and they can blow off in high winds. Tile roofs are expensive, something insurers are guaranteed to factor into the insurance rates. Read the court decision
Read the full story...
Reprinted courtesy of

---

Plaintiffs In Construction Defect Cases to Recover For Emotional Damages?

March 16, 2011 — CDJ STAFF

A recent post to the Markusson, Green, Jarvis Blog reports on an important appeals decision which promises to impact construction defect litigation in Colorado.



The post provides analysis on the recovery of inconvenience damages. The focus of the piece is centered on Hildebrand v. New Vista Homes II, LLC, 08CA2645, 2010 WL 4492356 (Colo. Ct. App. Nov. 10, 2010), wherein it was held that " the plain language of Construction Defect Action Reform Act permits recovery of damages for inconvenience, and that the trial court did not err by allowing inconvenience damages to go to the jury".



According to the MGJ Blog "The Hildebrand decision is important because it provides Construction Defect Plaintiffs with a foothold for collecting emotional damages. While several questions of law remain as to who or under exactly what circumstances a Plaintiff may recover these types of damages, the Hildebrand case has clearly set forth that emotional damages may be considered as part of actual damages pursuant to CDARA."



Read Full Story...

Read the court decision
Read the full story...
Reprinted courtesy of

---

Revolutionizing Buildings with Hybrid Energy Systems and Demand Response

January 08, 2024 — Aarni Heiskanen - AEC Business
A recent study conducted by the Finnish Building Services 2030 group explores the potential technologies and business prospects for adaptable energy systems within buildings. Building Services 2030 is a Finnish consortium of Aalto University, Tampere University, and 14 industry partners. The consortium has defined a shared vision for the Finnish building service sector and researches topics that help reach the vision. My company is responsible for the group’s communication, so I eagerly read the research reports as they come out. One of the new reports I found very timely is about the energy flexibility of buildings. The authors are Senior Researcher Juha Jokisalo and Professor Matti Lehtonen from Aalto University. They highlight how the contemporary energy landscape is undergoing a significant transformation. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

---

Why Should Businesses Seek Legal Help Early On?

December 03, 2024 — Scott L. Baker - Los Angeles Litigation Blog
Most business owners are natural problem solvers. They assess the issue that lies before them and develop a strategy to overcome it. It’s a critical mindset to have, but do all business owners have the skillset to solve every issue? While it is understandable that business owners may want to attempt to resolve issues on their own, it is invariably beneficial to obtain guidance for legal issues earlier rather than later. 3 Reasons to Consult an Attorney Sooner than Later Many people might consider working with an attorney to be a last resort. Typically, this is not the case; rather, getting knowledgeable legal counsel sooner than later can help business owners because:

1. It’s Cheaper: Early legal intervention can often prevent disputes from leading to litigation, which can be expensive. Working with an attorney to resolve a conflict before it escalates into a larger issue is often a good business decision and wise investment.

Read the court decision
Read the full story...
Reprinted courtesy of Scott L. Baker, Baker & Associates
Mr. Baker may be contacted at slb@bakerslaw.com

---

Washington State Updates the Contractor Registration Statute

June 17, 2015 — Beverley BevenFlorez-CDJ STAFF
Ryan W. Sternoff of Ahlers & Cressman PLLC, analyzed SHB 1749, which recently amended RCW 18.27.010, Washington State’s legislature’s contractor’s registration statute. According to Sternoff, “a broad reading of the contractor’s registration statute, RCW Ch. 18.27, would require just about any person or entity, other than a residential homeowner, who is involved at any level in improving real property to be registered as a ‘Contractor,’ irrespective if that person or entity hired a licensed contractor to perform work on real property that they own.” SHB 1749 amended the statute “so that those who ‘offer to sell their property without occupying or using the structures, projects, developments or improvements’ are excluded from the definition of ‘contractor’ and not required to be registered, provided that the person or entity ‘contracts with a registered general contractor and does not superintend the work.’” Read the court decision
Read the full story...
Reprinted courtesy of

---

Contractor Suffolk's Hospital Project Is on Critical List After Steward Health Care Bankruptcy

January 14, 2025 — Richard Korman - Engineering News-Record
Before it was hit by troubles that now threaten to kill it, a new hospital being built by Suffolk Construction in Norwood, Mass., was shaping up as a tale of recovery. The existing hospital on the site had been forced to shut most local operations since a devastating rainfall and flood in 2020. Read the court decision
Read the full story...
Reprinted courtesy of Richard Korman, ENR

---

Private Project Payment Bonds and Pay if Paid in Virginia

January 05, 2017 — Christopher G. Hill – Construction Law Musings
One of the many items of construction law that has always been about as clear as mud has been the interaction between a contractual pay if paid clause and payment bond claims either under the Federal Miller Act or Virginia’s “Little Miller Act.” While properly drafted contractual “pay if paid” clauses are enforceable by their terms in Virginia, what has always been less clear is whether a bonding company can take advantage of such a clause when defending a payment bond claim. As always, these questions are very fact specific both under the Federal Act and the state statute. I wish that this post would answer this question, but alas, it will not. A recent case from the City of Roanoke, Virginia looked at the interaction between a payment bond and a “condition precedent” pay if paid clause as it relates to a private project that is not subject to the Little Miller Act. In the case of IES Commercial, Inc v The Hanover Insurance Company, the Court examined a contractual clause between Thor Construction and IES Commercial in tandem with the bond language between Hanover Insurance Company and Thor as it related to a surprisingly familiar scenario. The general facts are these: IES performed, Thor demanded payment from the owner for the work that IES performed and the owner, for reasons that are left unstated in the opinion, refused to pay. IES sues Hanover pursuant to the payment bond and Hanover moves to dismiss the suit because Thor hadn’t been paid by the owner and therefore Hanover could take advantage of the pay if paid language. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---