FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Presenting a “Total Time” Delay Claim Is Not Sufficient

September 12, 2022 — David Adelstein - Florida Construction Legal Updates
When presenting a delay-type of claim on a construction project, a claimant MUST be in a position to properly PROVE the claim. Trying to present a delay claim loosey-goosey is not a recipe for success. In fact, it can be a recipe for an easy loss. This is not what you want. To combat this, make sure you engage a delay expert that understands delay methodologies and how to calculate delay and do NOT present a total time claim. Presenting a delay claim using a total time approach, discussed below, makes it too easy to attack the flaws and credibility of the approach. Per the discussion of the case below, a total time claim with a contractor that used its project manager, versus a delay expert, to support its claim turned the contractor’s claim into a loss. In French Construction, LLC v. Department of Veteran Affairs, 2022 WL 3134507, CBCA 6490 (CBCA 2022), a contractor submitted a delay claim to the government for almost $400,000. The contractor was hired to construct a two-story corridor to connect hospital buildings. The contractor was required to be complete within 365 days. It was not. The contractor was seeking 419 days of delay from the government. The contractor’s “delay expert” was its project manager who compared the contractor’s as-planned schedule to an as-built schedule he prepared for the claim. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Loss Caused by Theft, Continuous Water Discharge Not Covered

September 17, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The insured's claim for loss based on theft and water leaks was not covered under the property policy. SJP Props. v. Mount Vernon Fire Ins. Co., 2015 U.S. Dist. LEXIS 97216 (E.D. Mo. July 27, 2015). SJP Properties bought and sold foreclosed properties. On July 13, 2006, it purchased at a foreclosure sale a property in St. Louis. The property was not inspected before or after the purchase, and sat vacant for more than two years. No one checked regularly on the property. The property was insured under a commercial property policy issued by Mount Vernon, effective from March 8, 2006 to March 8, 2009. The policy covered vandalism, but excluded loss caused by theft. An exception for the exclusion provided coverage for "building damage caused by the breaking in or exiting of burglars." The policy also excluded loss or damage caused by fungus, wet rot, dry rot and bacteria or water leaks for a period of 14 days or more. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Florida Duty to Defend a Chapter 558 Right to Repair Notice

July 30, 2015 — Scott Patterson – CD Coverage
In Altman Contractors, Inc. v. Crum & Forster Specialty Insurance Co., 2015 WL 3539755 (S.D. Fla. 2015), Altman was the general contractor for a residential condominium project. The condominium association served Altman with Chapter 558 notices. A Chapter 558 notice is a statutory prerequisite to a property owner’s construction defect lawsuit and provides the contractor with an opportunity to respond and avoid litigation. Altman demanded that its CGL insurer, Crum & Forster, provide a defense to the Chapter 558 notices by hiring counsel to represent Altman’s interests. While not disputing that the claimed defects may be covered under the policy, Crum & Forster denied any duty to defend against the notices on the basis that they did not constitute a “suit.” Altman filed suit. Read the court decision
Read the full story...
Reprinted courtesy of Scott Patterson, CD Coverage

---

Best Practices for Installing Networks in New Buildings

August 14, 2023 — Patrick Chown - Construction Executive
A previous article, "How to Install Networks in an Old Building," discussed the various challenges of implementing networking infrastructure in older spaces. The building layout, age of the building and use cases were the major challenges involved. New buildings provide an opportunity to incorporate state-of-the-art networking infrastructure from the ground up. Careful planning and foresight are essential to ensure optimal network performance and avoid future issues. In new buildings, including corporate offices, multifamily residential complexes, hospitals, educational institutions and retail spaces, the potential use cases and users can vary significantly. Each of these spaces comes with its unique networking requirements. Regardless of the specific network applications, there are fundamental frameworks and best practices that can be employed to build a solid network foundation. By following these guidelines and adapting them to the specific needs of your new building, you can ensure a robust and flexible network infrastructure that accommodates ever-evolving technological demands. Reprinted courtesy of Patrick Chown, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

---

The Road to Hell is Paved with Good Intentions: A.B. 1701’s Requirement that General Contractors Pay Subcontractor Employee Wages Will Do More Harm Than Good

November 02, 2017 — Steven M. Cvitanovic & Omar Parra - Haight Brown & Bonesteel LLP
Tales of subcontractors who close up shop before paying their employees are not all that uncommon, but they are certainly not common enough to require General Contractors to pay for that same labor twice. Last month, the California Legislature passed Assembly Bill No. 1701, which requires the General Contractor of a private construction project to pay all unpaid wages and fringe benefits owed to an employee of a subcontractor, irrespective of the tier, and even if the General Contractor made the payment. With the Governor’s recent signature, Assembly Bill No. 1701 is now the law of the land. Here is what you need to know:

• It applies to all private (but not public) construction contracts entered into on or after January 1, 2018;
• It gives a subcontractor’s employee a direct cause of action against the General Contractor for any unpaid wages and fringe benefits, even if the General Contractor has fully paid the subcontractor;
• It gives a third party owed fringe or other benefits a cause of action against the General Contractor;
• All actions by the employee or third party must be filed within one year of the earliest of the recordation of the notice of completion, the recordation of the notice of cessation of work, or the actual completion of the work;
• The General Contractor cannot contract to avoid the liability imposed by Assembly Bill No. 1701, but it can seek indemnity from the subcontractor; and
• At the General Contractor’s request, the subcontractor shall provide the General Contractor with its payroll records.

Reprinted courtesy of Steven Cvitanovic, Haight Brown & Bonesteel LLP and Omar Parra, Haight Brown & Bonesteel LLP Mr. Cvitanovic may be contacted at scvitanovic@hbblaw.com Mr. Parra may be contacted at oparra@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Notes from the Nordic Smart Building Convention

June 29, 2017 — Aarni Heiskanen - AEC Business
The first Nordic Smart Building Convention took place in Helsinki on June 14 and 15, 2017. It was an inspiring event with great keynotes, tech talks, and an exhibition of smart building products and services. The event was organized by HUB13, a leading co-working space provider in Finland. I had met with the producer of the convention, Sjoerd Postema, when he was planning the event. He asked for my ideas on possible topics and presenters. Later, he invited me to host a workshop and a roundtable at the convention. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at info@aepartners.fi

---

Duuers: Better Proposals with Less Work

July 21, 2018 — Aarni Heiskanen - AEC Business
Small contractors, consultants, and design professionals have a love–hate relationship with responding to RFPs. Duuers, a Finnish startup, wants to turn this struggle into an inspiring experience. “We followed a day in the life of a hand-picked group of entrepreneurs,” says Paula Viinamäki, co-founder of Duuers. “We were flies on the wall, observing how small business owners wrestle with their daily tasks. Proposal-writing seemed to be an especially painful and time-consuming, yet vital, job.” Defining the Scope through Experiments After discovering this poorly supported but essential job that had to be done, Viinamäki and Jussi Paanajärvi, the other co-founder of Duuers, realized that they might be onto something. Consequently, they decided to start working on a prototype app for proposal-writing in the spring of 2017. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

---

Important New Reporting Requirement for Some Construction Defect Settlements

April 17, 2019 — Ian Williamson - Gordon & Rees Construction Law Blog
In response to a tragic balcony collapse incident where the public later learned the contractor had paid millions to settlement defect cases in the preceding years, the California legislature passed, the state contractor’s license board is now implementing, a public disclosure requirement for certain construction defect claims. The disclosure requirement is triggered by a judgment (which is not a new requirement), an arbitration award, or a settlement of certain construction defect claims. These requirements are codified at California Business & Professions Code sections 7071.20-22. What types of Projects: This requirement applies only if all of the following apply:

A) Residential B) Multi-Family; and C) Rental property

Limitations on Claims – The reporting requirement only applies if all of the following are true:

A) The claim is against a CSLB licensee (not a design professional) acting in the capacity of a contractor; B) The claim is for a structural defect; C) The total claim is valued at $1 million (not including investigation costs); D) SB800 does not apply; E) The action was filed after January 1, 2019; and F) If a lawsuit, the case was designated complex by the courts (which may not apply if only contractor is sued).

Read the court decision
Read the full story...
Reprinted courtesy of Ian Williamson, Gordon & Rees
Mr. Williamson may be contacted at igwilliamson@grsm.com

---