White House Hopefuls Make Pitches to Construction Unions
May 20, 2019 —
Bruce Buckley - Engineering News-RecordAs the 2020 presidential election draws nearer, many Democratic hopefuls are beginning to seek construction unions’ support. Eight declared candidates made their pitches to members of the North America’s Building Trades Unions at the group’s legislative conference April 9-10 in Washington, D.C. Several promised a major infrastructure package of $1 trillion or more, which aligns with the trades’ legislative agenda. But many seeking endorsement will wrestle with balancing calls for a green economy and unions’ demand for traditional oil and gas sector jobs.
Read the court decisionRead the full story...Reprinted courtesy of
Bruce Buckley, ENRENR may be contacted at
ENR.com@bnpmedia.com
NJ Supreme Court Declines to Review Decision that Exxon Has No Duty to Indemnify Insurers for Environmental Liability Under Prior Settlement Agreement
November 29, 2021 —
Patricia B. Santelle & Laura Rossi - White and WilliamsOn November 1, 2021, in a single-sentence Order, the Supreme Court of New Jersey denied a request for review of a decision that ExxonMobil Corporation (Exxon) did not have to indemnify certain of its insurers over environmental liabilities as required by a previous settlement agreement. The case, entitled Home Insurance Company v. Cornell-Dubilier Electronics Incorporated, et al., has a unique and convoluted procedural history but, in short, the denial of review leaves standing a holding by the intermediate appellate court that the insurers’ “untimely notice actually prejudiced Exxon, violated the no-prejudice rule, and breached the covenant of good faith and fair dealing.” The court declined to consider the question framed by the insurers: whether the importance of enforcing settlement agreements outweighs New Jersey’s entire controversy doctrine.
The matter dated back almost thirty years, when the New Jersey Department of Environmental Protection notified the Appearing London Market Insurers (ALMI) of the potential liability of Cornell-Dublier Electronics (CDE), a former indirect subsidiary of Exxon, for pollution at a site in New Jersey. Coverage litigation followed in New Jersey, which ALMI defended under policies issued to CDE. Exxon was not named in the CDE suit nor were the policies which ALMI issued to Exxon at issue in that case; Exxon instead had its own pollution coverage case pending in New York. In June 2000, Exxon and its insurers, including ALMI, entered into a settlement agreement which (a) required Exxon to indemnify the insurers for any environmental liability claims involving its subsidiaries, and (b) provided for application of New York substantive law and litigation in New York City court for any dispute between the parties under it.
Reprinted courtesy of
Patricia B. Santelle, White and Williams and
Laura Rossi, White and Williams
Ms. Santelle may be contacted at santellep@whiteandwilliams.com
Ms. Rossi may be contacted at rossil@whiteandwilliams.com
Read the court decisionRead the full story...Reprinted courtesy of
Drafting a Contractual Arbitration Provision
February 11, 2019 —
David Adelstein - Florida Construction Legal UpdatesA recent Florida case discussing a contractual arbitration provision in a homebuilder’s contract discussed the difference between a narrow arbitration provision and a broad arbitration provision. See Vancore Construction, Inc. v. Osborn, 43 Fla.L.Weekly D2769b (Fla. 5th DCA 2018). Understanding the distinction between the two types of arbitration provisions is important, particularly if you are drafting and/or negotiating a contractual arbitration provision.
A narrow contractual arbitration provision includes the verbiage “arises out of” the contract such that disputes arising out of the contract are subject to arbitration. Arbitration is required for those claims the have a direct relationship with the contract.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin NorrisMr. Adelstein may be contacted at
dma@kirwinnorris.com
Appraiser Declarations Inadmissible When Offered to Challenge the Merits of an Appraisal Award
March 14, 2018 —
Valerie Moore and Christopher Kendrick - Publications & InsightsIn
Khorsand v. Liberty Mutual Fire Ins. Co. (No. B280273, filed 2/27/18), a California appeals court affirmed an appraisal award favorable to a homeowners insurer, ruling that it was improper to admit as evidence in opposition to a petition to confirm the award a declaration from the policyholders’ appraiser, except for the limited purpose of showing improprieties in the appraisal, bias, partiality or other improper conduct.
The homeowners had a pipe leak and submitted a claim. The insurer responded to an estimate from the owners’ adjuster by retaining an expert and paying an undisputed amount that was significantly less. Eleven months later the owners had upper deck damage and submitted another claim. Relying on the same expert, the insurer paid another undisputed amount significantly less than the owner’s estimate. The owners requested appraisal but the insurer denied the request, contending that the dispute was over coverage and outside the scope of appraisal.
The owners’ petition for appraisal was granted, with the court ordering separate listing of items the insurer disputed regarding coverage or causation. The appraisal panel issued an award stating that total damage was $132,293, of which $96,530 was contested by the insurer. The insurer filed a petition to confirm the award, which was granted despite the fact that the owners’ appraiser had refused to sign it.
Reprinted courtesy of
Valerie Moore, Haight Brown & Bonesteel LLP and
Christopher Kendrick, Haight Brown & Bonesteel LLP
Ms. Moore may be contacted at vmoore@hbblaw.com
Mr. Kendrick may be contacted at ckendrick@hbblaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Insurer Must Defend Faulty Workmanship Claims
May 02, 2022 —
Tred R. Eyerly - Insurance Law HawaiiThe court determined that the insurer improperly denied a defense for construction defect claims made against the insured. Amerisure Mut. Ins. Co. v. McMillin Tex. Homes, 2022 U.S. Dist. LEIS 40363 (W.D. Texas March 8, 2022).
McMillin was a developer, general contractor and home seller. It constructed multiple homes in various communities in the San Antonio area. After the homes were completed, homeowners observed defects in the artificial stucco exterior finish. After claims were lodged against McMillin, the various claims were tendered to Amerisure. Amerisure filed for declaratory judgment that it had to duty to defend or indemnify and moved for summary judgment.
Amerisure first argued the homeowners' faulty workmanship claims did not allege "property damage" under the policies. It argued there were no allegations that any property damage existed, but merely that the stucco suffered from construction defects. The court disagreed. Among the allegations was the statement that due to the construction defects, the homes suffered damage "not only to the exterior stucco, but also to the underlying wire lath, paper backing, house wrap, flashing, water resistive barriers, sheathing, interior walls, interior floors and/ or other property." Consequently, the underlying claims amounted to property damage.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Lewis Brisbois Successfully Concludes Privacy Dispute for Comedian Kathy Griffin Following Calif. Supreme Court Denial of Review
November 19, 2021 —
Lewis BrisboisLos Angeles, Calif. (October 18, 2021) - On October 13, 2021, the California Supreme Court declined to review a published, unanimous opinion of the Court of Appeal in favor of comedian Kathy Griffin and her husband, Randy Bick. The plaintiff-appellants claimed Ms. Griffin and Mr. Bick violated their privacy rights by using home security cameras to record “every move and every communication” in the plaintiffs’ private back yard.
Ms. Griffin and Mr. Bick maintained that the lawsuit was filed by their neighbors in retaliation after the husband directed what the Court of Appeal described as “an expletive-laden rant” at Ms. Griffin and Mr. Bick. The neighbor's rant was recorded by security cameras and reported in the media, as well as publicized during Ms. Griffin’s performances at the Dolby Theater.
In the trial court, Ms. Griffin and Mr. Bick successfully moved for summary adjudication of the plaintiffs’ privacy causes of action. In July 2021, the
Court of Appeal affirmed, calling the appellants’ claims “hyperbole.”
Read the court decisionRead the full story...Reprinted courtesy of
Lewis Brisbois
Providence Partner Monica R. Nelson Helps Union Carbide Secure Defense Verdict in 1st Rhode Island Asbestos Trial in Nearly 40 Years
December 31, 2024 —
Lewis Brisbois NewsroomProvidence, R.I. (November 22, 2024) - On November 21, 2024, a Providence County jury returned a unanimous defense verdict for Union Carbide Corporation after a nine-day trial presided over by Associate Justice Richard A. Licht. Tim McGowan of Kelley Jasons McGowan Spinelli Hanna & Reber LLP, Eric Cook of Willcox Savage, and Monica R. Nelson of Lewis Brisbois Bisgaard & Smith LLP represented Union Carbide at trial. Elliott Davis of Shook Hardy & Bacon was Union Carbide’s appellate counsel.
The plaintiffs’ lawyers, Vincent L. Greene IV, Nathan D. Finch, and Ashley Hornstein of Motley Rice LLC, represented the family of Mrs. Bonnie Bonito in the first asbestos matter to go to trial in Rhode Island in close to 40 years and requested nearly $25 million in compensatory damages for the death of Mrs. Bonito from her alleged exposure to Union Carbide’s asbestos, among many other asbestos-containing products, through the work clothes of her husband. The plaintiffs’ proffered theory of liability against Union Carbide Corporation is known as a “take-home” exposure claim.
Read the court decisionRead the full story...Reprinted courtesy of
Lewis Brisbois
Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?
January 27, 2020 —
Ted R. Gropman & Christine Z. Fan - ConsensusDocsConstruction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date.
Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved.
There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973).
Reprinted courtesy of
Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP
Mr. Gropman may be contacted at gropmant@pepperlaw.com
Read the court decisionRead the full story...Reprinted courtesy of