Cambridge Massachusetts Building Expert Directory

Risk Management and Contracting after Hurricane Irma: Suggestions to Avoid a Second Disaster

September 14, 2017 — Stephen H. Reisman, Gary M. Stein & Adam P. Handfinger – Peckar & Abramson, P.C.
Peckar & Abramson attorneys have assisted contractors in the immediate aftermath of several Hurricanes, including Andrew in 1992, Wilma in 2005, Ike in 2008, and Sandy in 2012. Based on this experience, we offer some post-storm strategies for contracting and risk management in three situations:

Ongoing projects in the area directly impacted by the storm;
Projects remote from the storm-impacted areas, but which may be affected by material or labor shortages; and
Requests for assistance in recovery/clean-up/rebuild eff orts, which would be new projects.

Projects Directly Impacted By Hurricane Irma: 1. Immediately review each Owner contract to determine what notices are required for delays and/or extra costs arising from the storm. Contract notice requirements and time limits vary, whether for force majeure or other similar time and compensation rights. There is no effective one-size-fits-all solution. While the initial notice letters will likely look very similar, you should make sure that each is sent as required by the contract. Check each contract’s requirements for particulars regarding content, the form of delivery, and parties and individuals designated to receive the letters as well as carbon copy recipients like the architect. Follow-up notices and time periods differ from contract to contract and should be tracked so that if, for example, a follow-up notice is required in a week per the contract terms, it is tracked to ensure compliance. Reprinted courtesy of Haight Brown & Bonesteel LLP attorneys Stephen H. Reisman, Gary M. Stein and Adam P. Handfinger Mr. Reisman may be contacted at sreisman@pecklaw.com Mr. Stein may be contacted at gstein@pecklaw.com Mr. Handfinger may be contacted at ahandfinger@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Residential Contractors, Be Sure to Have these Clauses in Your Contracts

December 23, 2023 — Christopher G. Hill - Construction Law Musings
I have often “mused” on the need to have a good solid construction contract at the beginning of a project. While this is always true, it is particularly true in residential contracting where a homeowner may or may not know the construction process or have experience with large scale construction. Often you, as a construction general contractor, are providing the first large scale construction that the homeowner has experienced. For this reason, through meetings and the construction contract, setting expectations early and often is key. As a side note to this need to set expectations, the Virginia Department of Professional and Occupational Regulation (DPOR) and the Virginia General Assembly require certain clauses to be in every residential construction contract. DPOR strictly enforces these contractual items and failure to put them in your contracts can lead to fines, penalties and possibly even revocation of a contractor’s license. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

South Carolina Contractors Regain General Liability Coverage

May 20, 2011 — CDJ STAFF

PR Newswire reports that the Carolinas Associated General Contractors (CAGC) have successfully persuaded the South Carolina legislature to pass a bill restoring commercial general liability (CGL) coverage. Governor Nikki Hartley signed the legislation on May 17.

A South Carolina Supreme Court decision given on January 7, 2011, had ended commercial general liability coverage in the state. Senate Bill 431 addressed this decision, restoring the ability of home builders to obtain CGL coverage.

PR Newswire quotes South Carolina homebuilder, Allen Amsler: “We have seen a lot of legislation with substantial impact to our business over the years. However, I would place this in the same level of importance with the original tort reform legislation. The effects of the Supreme Court’s ruling could have been catastrophic to our industry in South Carolina had it not been for this bill. Thanks to all those in the House, Senate and the Governor’s office who assisted us.”

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

The Complex Insurance Coverage Reporter – A Year in Review

February 27, 2019 — White and Williams LLP
Welcome to CICR’s annual review of insurance cases. Here, we spotlight five (actually, seven) decisions from the last year that you should know about, and five pending cases—all before state high courts—to keep an eye on. The choices were not always easy. That is because 2018 saw a number of notable insurance coverage developments. Among them was the “Restatement of the Law – Liability Insurance,” a nearly five hundred-page document that the American Law Institute (ALI) adopted after eight years and twenty-nine drafts. Already, much has been written about the ALI Restatement, including by us. There will be more to come. Going forward, we will continue to highlight significant examples where courts address its provisions. Read the court decision
Read the full story...
Reprinted courtesy of White and Williams LLP

Biggest U.S. Gas Leak Followed Years of Problems, State Says

June 10, 2019 — Mark Chediak & Edvard Pettersson - Bloomberg
The worst natural gas leak in U.S. history, which broke out at a Sempra Energy storage field near Los Angeles almost four years ago, was caused by corrosion, according to a report commissioned by California regulators. The rupture of a 7-inch (18-centimeter) well casing at Sempra Energy’s Aliso Canyon storage complex was due to “microbial corrosion” brought on by contact with groundwater, an independent analysis conducted by Blade Energy Partners and commissioned by two state agencies found. The report also concluded there had been more than 60 leaks in the field dating back to the 1970s, and Sempra didn’t carry out detailed inspections after they occurred, the California Public Utilities Commission and Department of Conservation said in a joint statement. The company’s Southern California Gas lacked “any form of risk assessment” to manage the integrity of its wells and hadn’t established systematic practices to protect against corrosion and monitor well pressure, the agencies said. Reprinted courtesy of Mark Chediak, Bloomberg and Edvard Pettersson, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

Exploring Architects’ Perspectives on AI: A Survey of Fears and Hopes

March 19, 2024 — Aarni Heiskanen - AEC Business
RIBA, the Royal Institute of British Architects, ran a survey in late 2023 with 500 respondents on the impact of AI on their profession. The study also explored the near-term outlook for AI adoption and use. The results reveal divided opinions among architects. A popular view is that AI threatens the profession, even though a larger portion sees tools like AI as necessary in the coming years. The Present Use of AI The respondents were asked, for the projects they are currently working on, how often their practice used AI in any way. In all, 41% said that they use AI to some degree. Of those, 43% agree that AI has improved efficiency in the architectural design processes, while 24% disagree. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Direct Contractors In California Should Take Steps Now To Reduce Exposure For Unpaid Wages By Subcontractors

February 07, 2018 — Nora Stilestein, Candace Matson , and Mercedes Cook - Construction & Infrastructure Law Blog
As of January 1, 2018, direct contractors in California who make or take a contract “for the erection, construction, alteration, or repair of a building, structure, or other private work” are jointly and severally liable with their subcontractors for any unpaid wages, fringe benefits and other benefit payments or contributions owed to wage claimants. Governor Brown approved AB 1701 on October 14, 2017. The new law puts the onus on direct contractors to not only monitor their own payroll practices, but to ensure that their subcontractors and lower tier subcontractors are engaging in proper payroll practices. Reprinted courtesy of Sheppard Mullin attorneys Nora Stilestein, Candace Matson and Mercedes Cook Ms. Stilestein may be contacted at nstilestein@sheppardmullin.com Ms. Matson may be contacted at cmatson@sheppardmullin.com Ms. Cook may be contacted at mcook@sheppardmullin.com Read the court decision
Read the full story...
Reprinted courtesy of

Real Estate Trends: Looking Ahead to 2021

November 09, 2020 — Adam Weaver - Gravel2Gavel Construction & Real Estate Law Blog
2020 has been an unprecedented year, and, while there are likely more twists and turns to come before December 31, it is essential to look at how the real estate markets have changed this year and which trends are likely to continue into 2021. The COVID-19 pandemic has impacted nearly every industry, including commercial real estate, and its impact will continue to influence the market and commercial real estate long after the virus has been eradicated. Commercial Real Estate Loan Modifications As the United States’ economy stalled, shut down and slowly started to recover throughout 2020, many businesses were negatively impacted, and most property owners found themselves negotiating with both their lenders and tenants. As tenants were unable to pay rent, property owners were unable to service their debt, which led to a surge of loan modifications this year. This trend certainly will continue through the first half of 2021, as the economy continues to recover. Read the court decision
Read the full story...
Reprinted courtesy of Adam Weaver, Pillsbury
Mr. Weaver may be contacted at adam.weaver@pillsburylaw.com

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES